O-2001-2465 - Laserfiche WebLink

Browse Search

e e 3.1.3. Services resulting from significant changes in the scope, extent or character of the portions of the Project designed or specified by ENGINE~R or its design requirements including, but not limited to, changes in size, complexity, OWNER's schedule, character of construction or method offmancing; and revising previously accepted studies, reports, Drawings, Specifications or Contract Documents when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to the effective date of this Agreement, or are due to any other causes beyond ENGINEER's control. 3.1.4. Providing renderings or models for OWNER's use. 3.1.5. Preparing documents for alternate bids requested by OWNER for Contractor's work which is not executed or documents for out-of-sequence work. 3.] .6. Undertaking investigations and studies including, but not limited to, detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flQw and economic evaluations, rate schedules and appraisals; assistance in obtaining financing for the Project; evaluating processes available for licensing and assisting OWNER in obtaining process licensing; detailed quantity surveys of materials, equipment and labor; and audits or inventories required in connection with construction performed by OWNER. 3.1.7. Furnishing services of ENGINEER's Subcontractors for other than Basic Services; and furnishing data or services of the types described in paragraph 4.4 when OWNER employs ENGINEER to provide such data or services in li~u of furnishing the same under paragraph 4.4. 3:] .8. Services during out-of-town travel required of ENGINEER other than visits to the site or OWNER's office as required by Article 2. 3.1.9. Preparing for coordinating with, participating in and responding to structured independent review processes, including, but not limited to, Construction Management, Cost Estimating, Project Peer Review, Value Engineering and Constructability Review requested by OWNER; and performing or furnishing services required to revise studies, reports, Drawings, Specifications or Contract Documents as a result of such review processes. 3.] .10. Preparing to serve or serving as a consultant or witness for OWNER in any litigation, arbitration or other legal or administrative proceeding involving the Project (except for assistance in consultations which is included as part of Basic Services under paragraph 2.1.2). 3.].] ]. Other Special Services performed or furnished by ENGINEER in connection with the Project, including services which 'are to be furnished by OWNER under Article :4, and services not otherwise provided for in this Agreement. ARTICLE 4 - OWNER'S RESPONSIBILITffiS Except as otherwise provided in Exhibit A, OWNER shall do the following in a timely manner so as not to delay the services of ENGINEER and shall bear all costs incident thereto: 4.1. Designate in writing a person to act as OWNER's representative with respect to the services to be performed or furnished by ENGINEER under this Agreement. Such person will have complete authority to transmit instruc- tions, receive information, interpret and define OWNER's policies and decisions with respect to ENGINEER's services for the Project. 4.2. Provide all criteria and full information as to OWNER's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and furnish copies Page 4 Prof Design Services 3/2000