12-10-12 Regular Meeting of La Porte City Council

Browse Search

111212012 ABC Home and Commercial Services 8448N.Sam Houston Parkway West Houston, TX770G4 281~730~9500 281-653-5454 fax HONaE&xCOMMERCIAL SERVICES [�t Requirements Project start time and equipment delivery to the job site will begin within a negotiated period after recieptof project proposal approval, purchase order (if required) and payment of approximately one half the proposal price (deposit). ABC will complete the scope ofwork within anegotiated time. Costs quoted are good for thirty (3O)days from date ofquotation. Indicated project bid price includes programming and installation of hardware, functional engineering, and any hardware needed to complete the project aaapnifimd. Work not included: 1) Single phase ACpower G) Bungu(aralarm orfire alarm usage permits except for fire permit 2) Painting, patching and/or millwork aarequired byAHJ(Authority Having Jurisdiction) 3) Floor, wall orroof penetrations requiring coring 7) Lifts orother equipment unless otherwise specified 4) Fire wall penetrations 5) ConduiL.boxoe.fittings, hangers and caddy bars and/or detector rough -in Any labor costs requested ofABC Home and Commercial Services not included in this project bid should be considered a change order. A change order will result in charges of parts and labor charged at $95.00 per hour for the requested changes. Any change requires awritten approval bythe Client. Any service not covered under Warranty or Service Plan is charged at $95.00 per man-hour with aminimum charge o/two (2)hours. The Client will provide all power, telephone lines otpamel(s).grounds, equipment rack, cooling fans, back-up power supply, ^IT" networking specialist for on -site networking considerations and connections. ABC Home and Commercial Services may substitute equipmentofadiffeentbrand.00et.orapecifioationwbhvvrittenappmva|ofthe Client. The Client will not hold ABC responsible for delays, equipment substitutions, or contingencies that are beyond the control of ABC. Equipment description and technical layout may be provided at customer's request. The Client will not hold ABC Home and Commercial Services responsible for actions arising from the use of the installation of the system after completion of the system and acceptance of the system by the Client, |Dd2DlO'f'es Client shall indemnify, defend and save honn|eaa ABC Home and Commercial Semioen, its affiliated oompeniea, and their officers, Uinactona, emp|oyeae, agents epnyaontat|ven, invbeea, contractors and subcontractors ("ABC Group") from and against any and all claims, |ooeoa, damages, expenses, judgments, onu"js, costs and charges pfuvory kind, including auomey'a fQQm and expenses (collectively, "Claims"), directly or indirectly arising out of, or related to the subject matter or performance of this Agreement which claims are caused by or result from negligence of ABC Group (whether sole or concurrent, active or pooeive, simple or gross) or other legal fault including strict liability of ABC Group and agree to other terms and conditions as set forth in Commercial Agreement.