Laserfiche WebLink
<br />.-J <br />.. <br /> <br />days. Claims not made in accordance with this Subparagraph shall be deemed <br />waived. <br /> <br />Add the following Clause 4.3.5.1 to Subparagraph 4.3.5: <br /> <br />.1 No increase in the Contract Sum will be granted for delays caused by or resulting <br />from normal or abnormal weather conditions. <br /> <br />Add the following Clauses 4.3.7.3 and 4.3. 7.4 to Subparagraph 4.3.7. <br /> <br />.3 Claims for increase in the Contract Time shall set forth in detail the circumstances <br />that form the basis for the Claim, the date upon which each cause of delay began to <br />affect the progress of the Work, the date upon which each cause of delay ceased to <br />affect the progress ofthe Work and the number of days increase in the Contract Time <br />claimed as a consequence of each such cause of delay. The Contractor shall provide <br />such supporting documentation as the owner may require including, where <br />appropriate, a revised construction schedule indicating all the activities affected by <br />the circumstances forming the basis of the Claim. <br /> <br />.4 The Contractor shall not be entitled to a separate increase in the Contract Time for <br />each one of the number of causes of delay which may have concurrent or interrelated <br />effects on the progress of the Work, or for concurrent delays due to the fault of the <br />Contractor. <br /> <br />4.4 RESOLUTION OF CLAIMS AND DISPUTES <br /> <br />Delete the entire section, Subparagraphs 4.4.1 through 4.4.8, inclusive, and replace with the <br />following: <br /> <br />4.4 RESOLUTION OF CLAIMS AND DISPUTES <br /> <br />4.4.1 The General process for dispute resolution shall be: <br /> <br />· Architect renders a decision <br />. Semor Representatives meet to resolve dispute <br />. Mediation <br />. Arbitration <br /> <br />4.4.2 Decision of Architect. Claims, submitted in writing, including those alleging an error or <br />omission by the Architect shall be referred initially to the Architect for decision. An initial <br />decision by the Architect shall be required as a condition precedent to the meeting of Senior <br />Representatives, mediation, or arbitration of all claims between Contractor and Owner arising <br />prior to the date final payment is due, unless thirty (30) days have passed after the claim has <br />been referred to the Architect with no decision having been rendered by the Architect. The <br />Architect will not consider disputes between the Contractor and persons or entities other than the <br />Owner. <br /> <br />10 <br />