HomeMy WebLinkAboutO-2000-2400
.
e
ORDXHANCE HO. 2000- Z L/ 00
AN ORDXHANCE APPROVXHG AND AUTHORXZXHG A COHSTRUCTXOH CONTRACT
BETWEEH THE CXTY OF LA PORTE AND R. HASSELL BUXLDERS, XHC., FOR THE
COHSTRUCTXOH OF THE LA PORTE COMMUHXTY LXBRARY; APPROPRXATXHG
$2,591,900.00, TO FUND SAXD COHTRACT; MAKXHG VARXOUS FXHDXHGS AND
PROVXSXOHS RELATXHG TO THE SUBJECT; FXHDXHG COMPLXANCE WXTH THE
OPEH MEETXHGS LAW; PROVXDXHG AN EFFECTIVE DATE HEREOF.
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF LA PORTE:
Section 1. The City council hereby approves and authorizes
the contract, agreement, or other undertaking described in the
title of this ordinance, in substantially the form as shown in the
document which is attached hereto and incorporated herein by this
reference. The City Manager is hereby authorized to execute such
document and all related documents on behalf of the City of La
Porte. The City Secretary is hereby authorized to attest to all
such signatures and to affix the seal of the City to all such
documents.
City Council appropriates the sum not to exceed
$2,591,000.00 from the City of La Porte Development Corporation
Fund Account No. 038 to fund said contract.
section 2.
The City Council officially finds, determines,
recites, and declares that a sufficient written notice of the date,
hour, place and subject of this meeting of the City council was
posted at a place convenient to the public at the City Hall of the
City for the time required by law preceding this meeting, as
required by the Open Meetings Law, Chapter 551, Texas Government
Code; and that this meeting has been open to the public as required
by law at all times during which this ordinance and the subject
matter thereof has been discussed, considered and formally acted
upon.
The city Council further ratifies, approves and confirms
such written notice and the contents and posting thereof.
"'
e
e
ORDXHANCE HO. 2000-~qoO
PAGE 2
section 3. This Ordinance shall be effective from and after
its passage and approval, and it is so ordered.
PASSED AND APPROVED, this loth day of April, 2000.
By:
CITY OF LA PORTE
~~
Mayor
ATTEST:
~~
ha A. Oil ett,
ty Secretary
Q?;;;:/;:
Knox w. Ask~ns,
City Attorney
e
1997 EDITION
e
AlA DOCUMENT Al01-1997
.St~"~~~fl1: fo~",:"".of 4greement Between Owner and Contractor
where the basis of payment is a STIPULATED SUM
........:,...... '.,
,;. -:: ; ,~. . :.
. \.
A G R E E MEN T made as of the
in the year Two Thousand
(In words. indic~te day, month and year)
BE TWE EN the Owner:
(Name, address and other information)
and the Contractor:
(Name. address and other information)
The Project is:
(Name and location)
/
The Architect is:
(Name. address and other information)
'lWentieth (20th)
day of "April
Ci. ty of La Porte
604 W. FainlDnt Parkway
P. o. Box 1115
La Porte, Texas 77572-1115
R. Hassell Builders, Inc.
P. O. Box 690767
"Houston, Texas 77269-0767
12211 Duncan Rd.
Houston, Texas 77066
La Porte Cormnuni ty Library
600 South Broadway
La Porte, Texas 77571
Hall/Barnum Architects, Inc.
2727 Weslayan
Houston, Texas 77027
The Owner and Contractor agree as follows.
Copyright 1915, 1918. 1925. 1937. 1951. 1958, 1961, 1963, 1967, 1974, 19n, 1987, iD 1997 by The American Institute of
Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission
of the AlA violates the copyright laws of the United States and will subject the violator to legal prosecution.
"'ARNING: Unlicensed photocDpylna violates U.s. copyrlaht laws and will subject the violator to lea_I prosecutlon.
This document has impor-
tant legal consequences.
Consultation with an
attorney is encouraged
with respect to its
completion or modification.
AlA Document A201-1997,
General Conditions of the
Contract for Construction, is
adopted in this document by
reference. Do not use with
other general conditions
unless this document is
modified.
This document has been
approved and endorsed by
The Associated General
Contractors of America.
.P'.
.~.~-
..;~ii~,-
-
iDI997 AlAe
AlA DOCUMENT A10l-ltt7
OWNER-CONTRACTOR
ACiREEMENT
The American Institute
of Architects
1735 New York Avenue, N.W.
Washington. D.C. 20006-5292
e
e.
ARTICLE 1 THE CONTRACT DO:CUMENTS
The Contract Documents consist of this Agreement, Conditions of the Contract (General,
Supplementary and other Conditions), Dra~gs, Specifications, Addenda issued prior to
execution of this Agreemept, other documents listed in this Agreement and Modifications issued
after execution of this Agreement; these form the Contract, and are as fully a part of the Contract
as if attached to this Agreement or repeated herein. The Contract represents the entire and
integrated agreement between the parties hereto and supersedes prior negotiations, representa-
:.;;::::.::-,::- ,:,:" ::; ::-: tions or agreements. .either written or oral: An enumeration of the 'Contract Documents, 'other
~'" ,';:... ,:.'.: ;.;., . :'. ;'''th ,. . di' .fi - . . '..' ,.' . h_. .cl '
,:/;;.:/, '::.:;..: :::.'.;,:, an M~,. Fa~ons~ appears m Arti e 8. .
~~~~~~~~{2 :)-:'~F'.: ';;\.j <(~~:~~l~;":,; ~:i,::) ,
~. ..' .
. a .'
.. "...
ARTICLE 2 THE WORK OF THIS CONTRACT
'The Contractor shall fully eXecute the Work described in th~ Contract Documents, except to the
. extent spec~~~ally indicated in the Con~ct Documents to b~ the responsibility C?f others. '.
~ ..~. ':". .,
-:. ....
ARTICLE lDATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION
3.1 The date of commencement of the Work shall be the date of this Agreement unless a
different date is stated below or provision is made for the date to be fixed in a notice to proceed
issued by the Owner. .' '
. '(Insert the date of commencement if it differs from the date of this Agreement or, if applicable, state that the
date will be fIXed in a notice to proceed.)
, Date' of camnencement will be May 11, 2000.
If. prior to the commencement of the Work. the Owner requires tin;te to file mortgages, mechan-
ic's liens and other security inte~ests, the Owner's time requirement shall be as follows:
3.2 The Contract Time shall be measured from the date of commencement. '
3.3 The Contractor shall achieve Substantial Completion of the entire Work not later than
365 'days from the date of commencement. or as follows:
(Insert number of calendar days. Alternatively. a calendar date may be used when coordinated with the date of
commencement. Unless stated elseWhere in the Contract Documents, insert any requirements for earlie~
Substantial Completion of c~rtain portions of tft.e Work.)
. subject to adjustments of this Contract Time as provided in the Contract Documents.
(Insert provisions, if any. for liquid,ated damages relating to failure to complete on time or for bonus payments ,
for early completion of the Work.) . " :' . , ' , .
We further' agree to pay as liquidated damages, in addition to other ft
.'daJn.iges as : stiPulated 'in the ConstJ;uction Contract, the sum of $500~0 "II ,
~or ea~h ,'fay ~t, tPe Work shall rema.1~ substantially incanplet~ ': ~ :
after expJIation of the ~ki.ng days specified and any extend,ed days oo.e.ao
a1lo~ by.the City's. representat:iye in accordance with the Specifi- ' ~
cations, not as a ,pei1a.lty, but as liquidated damages and ,added Cl1997 AlAe
: expense . fC?J; sUPervision .and delay in obtaining use of the Work. AlA DOCUMENT Al01-1997
'.. :'. ':~: :', . " ',. OWNER-CONTRACTOR
..' , AGREEMENT
-' .."
The American Institute
. of Architects
1735 New York Avenue. N. W.
Washington. D.C. 20006-5292
I
e
e
ARTICLE 4 CONTRACT SUM
4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's
performance of the Contract. The Contract Sum shall be T\\1O Million, Fi ve ~undred Ninety-one
Thousand, Nine Hundred Dollars(s 2,591 ,900. ),
subject to additions and ~ductions as provided in the Contract Documents. '
4.2 The Contract Sum is based upon the following alternates, if any, which are described in the
::;' c': ;:'i,: ~'_ ,', ,.:;;Con~lI:ct Documents and are hereby accepted by the Owner:
::::::/' ;/('::,' : ;::(Slate lh~_iau~rs or other identification of accepted allernates. If decisions on other alternates are to be made
i~;;~~~;'.~~::',-'. : ' :'i:bji.t!te. C?Wner ~ubsequent to't!ze execution of lhisAgreement, attach a schedule of such other alteTlUltes showing
:::-:-:. ':.;,'..... " . r.the amount for each and the date when lhat amount expires.)
:;-:',7-: '."'. . '. c. Alternate No. one: T\\1O (2) Monument Signs $ 19,200.
:;..-~: ~' ,Alternate No~ ~: Furniture Package $216,700.
.i"
4.3 Unit prices, if any, are as follows:
Allowance No. One: $15.00 per square yard installed for carpet
Allowance No. ~ ': $4,000.00 for interior signage installed
ARTICLE 5 PAYMENTS
5.1 PROGRESS PAYMENTS
5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and
Certificates for Payment issued by the Architect, the Owner shall make progress payments on
account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract
Documents.
5.1.2 The period covered by each Application for Payment shall be one calendar month
ending on the last day of the month. or as follows:
5.1.3 Provided that an Application for Payment is received by the Architect not later than the
third (3rd) day of a month, the oWner shall make payment to the Contractor not
. later than the fifteenth' (15th) day of the same month. If an '
Application for Payment is received by the Architect after the application date fixed above. pay-
. ment shall be made by the Owner not later ~an"twel ve (12) days after the Architect
receives the Application for Firment. '
5.1.4 Each Application for ~ayment shall be baSed on the most recent schedule of values submit-
.ted by the Contractor in accomance with the Contract Documents. The schedule of values shall
allocate the entire Contract Sum among the ~otis portions of the Work. The schedule of values
. " . shall be prepare~ in such form and supported by such data to substantiate its accuracy as the
, Architect may require. This schedule, unless objected to by the Architect, shall be used as a basis
for reviewing the Contractor's Applications for Payment.
I
.
oo.e.ao
c::::::::::J
C1997 AlAe
AlA DOCUMENT Al0l-l!J!J7
OWNER-CONTRACTOR
AGREEMENT
The American Institute
of Architects
1735 New York Avenue. N.W.
Washington, D.C. 20006-5292
e
e
5.1.5 Applications for Payment shall indicate the percentage of completion of each portion of the
Work as of the end of the period covered by ~e Application for Payment. .
5.1.6 Subject to other provisions of the Contract Documents, the amount of each progress pay-
ment shall be computed as follows:
. .1 Take that portion of the Contract Sum properly allocable to completed Work as deter-
mined by multiplying the percentage completion of each portion of the Work by the
l'4;; "".~:.E';:~;:;'~:.~::,~:,... . <'share of the Contract Sum allocated to that portion of the Work in the schedule of val-
M -......c -.... .. ~.' -.
f~ .';''; .,...~~-?;;;:fk:.;:,:';" ues, l~sS retainage of ten percent ( 10 %). Pending final determi-
1.fy~1~),~~~'-::~'\J"~':i:' :~.na:tioi1 of cost to the Owner of changes in the Work, amounts not in dispute shall be ,
""...::;..~..,_..... .::''';.7''.'".-'. "iricluded as provided in Subparagraph 7.3.8 of AlA Document A201-1997;
~I:~;:,:{~;:. ...., . ';:.::; ;'"i "Add that .portion. of the Contract Sum properly allocable to materials and equipment
~::::::~r' . ..: '.. . . delivered and suitably stored at the site for subsequent incorporation in the completed
...., ... . ' " '. 'constru~on (or, if approved in advance by. the Owner, suitably stored off the site at a
"J ~.::~,~ . location agreed upon in writing), l~ss retainage of ten percen,t ( 10 %);
..3 Subtract the aggregate of previous payments made by the Owner; and
.4 Subtract amounts, if any, for which the Architect has withheld or nullified a Certificate
for Payment as provided in Paragraph 9.5 of AlA Document A201-1997.
5.1.1 The progress payment amount determined in accordance with Subparagraph 5.1.6 shall be
further modified under the following circumstances:
.1 Add, upon Substantial Completion of the Work, a sum sufficient to increase the total pay-
ments to the full amount of the Contract Sum, less such amounts as the Architect shall
determine for incomplete Work, retainage applicable to such work and unsettled claims;
and (Subparagraph 9.805 of AlA Document A2oJ-J997 requires release of applicable retainage upon
Substantial Completion of Work with consent of surety. if any.)
.2 Add, if final completion of the Work is thereafter materially delayed through no fault of
the Contractor, any additional amounts payable in accordance with Subparagraph 9.10.3
of AlA Document A20l-1997.
5.1.8 Reduction or limitation of retainage, if any, shall be as follows: None.
(If it is intended, prior to Substantial Completion of the entire Work. to reduce or limit the retainage resulting
from the percentages inserted in Clawes 5.J.6.J and 5.J.6.2 above. and this is not explained elsewhere in the
Contract Documents, insert here provisions for such reduction or limitation.)
/
~....:. .
.... .
5.1.9 Except with the Owner's prior approval, the Contractor shall not make advance payments
. to suppliers for materials or equipment which have not been delivered and stored at the site.
"-'.' .
5.2'. FINAL PAYMENT
...,~.~.,1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made
. .:by .the Owner to the Contractor when: . .
,".;..>,~ .:: ..1 the Contractor has fully Performed the Contract except for the Contractor's responsibil-
ity to correct \\'<:>rk as provided. in Subparagraph 12.2.2 of AIA Document A20l-19'!17, and
to satisfy. other requirements, if any, which extend beyond final payment; and
.2 a final Certificate for Payment has been issued by the Architect.
I
8'11.
Q D
o. .:0
0..--..0
"0 a::::a ~
c::=:::J
01997 AlAe
AlA DOCUMENT A101-1997
OWN ER-CONTRACTOR
AGREEMENT
The American Institute
of Architects
1735 New York Avenue. N.W.
Washington, D.C. 20006-5292
I
e
e
5.2.2 The Owner's final payment to the Contractor shall be made no later than 30 days after the
issuance of the Architect's final Certificate for Payment, or as follows:
Refer to Specifications Section. 01027-Applications for Payment, 1-1 SUmmary,
M. Final Payment Application. . ' .'
ARTICLE 6 TERMINATI.ON OR SUSPENSION
6.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14-
of AlA Document A201-1997.
~!ft~~.;:~...:":':~~ .:'~. .' : ':'. n,'"..;;. ':~'. ." '.
~..;:,:~:;,/ :~.. '-., -. 6:2.' : The' 'Work may be' suspended by the Owner as provided in Article 14 of AlA Document
Jf;:~(F~/':~,~~{~i997.:: :... . '. ~.- .
~.: ~":.':-::. -.'
ARTICLE 7 MISCELLANEOUS PROVISIONS
7.1 Where reference is made in this Agreement to a provision of AlA Document A201-1997 or
another Contract Document, the reference refers to that provision as amended or supplemented
by other provisions of the Contract Documents.
7.2 Payments due and unpaid under the Contract shall bear interest from the date payment is
due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time
at the place where the Project is located.
(Insert rate of interest agreed upon, if any.)
Ten Percent (1 0%) per annum.
(Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit
laws and other regulations at the Owner's and Contractor's principal places of business, the location of the
Project and elsewhere may affect the validity of this provision. Legal advice should be obtained with respect to
deletions or modifications, and also regarding requirements such as written disclosures or waivers.)
7.3 The Owner's representative is:
(Name, address and other information)
Robert T. Herrera, City Manager
City of Ia. Porte
P. O. Box 1115
It4 Pofh\e~o~r's JJr~le~TJl1\~~s:
(Name, address and other information)
~ K. Tauriello, Vice President
R. Hassell Builders, Inc.
P. O. Box 690767
Houston, Texas 77269-0767
7.5 Neither the Owner's nor the Contractor's representative shall be changed without ten days'
written notice to the other party.
7.6 Other provisions:
t_ _ ul_I_..__ II. _--I...... I......... ._~ ...111................ "''''''''PIft 1....1 ft~
I
.
00.5.00
c:::=I
01997 AIAGD
AlA DOCUMENT AI0I-IJJ7
OWNER-CONTRACTOR
AGREEMENT
The American Institute
of Architects
1735 New York Avenue. NoW.
Washington, D.C. 20006-5292
e
e
. ARTICLE 8 ENUMERATION OF CONTRACT DOCUMENTS
8.1 The Contract Documents, except for Modifications issued aft~r: execution of this
Agreement, are enumerated as follows:
8.1.1 The Agreement is this executed 1997 edition of the Standard Form of Agreement Between
Owner and Contractor, AlA Oocument Al01-1997. '
,,"':::'C:'. :': - ,:.8.1.2 ..Th~.General Con~tions are the 1997 edition of the General Conditions of the Contract for
.;'. Z.:.+,:.:.- ". ':ConstiUction;A.rA DOcuinent A201-1997. ',..
~ri~~f'~''- ";'::?~~."'-,"-;;;' :::f::>.>:~'.~;~'''",: >.: . .
. ..' . '8.1.3 The .Supplementary and other Conditions of the Contract are those contained in the Project
..,. " ....~anual date4 ~~ 1, 2000 ' and are as follows:' .
. Document
Section 00800
Title Pages
SUpplementary Conditions' 2
8.1.4 The Specifications are those contained in the Project Manual dated as in Subparagraph 8.1.3,
and are as follows: ,.'
, (Either list the Specifications here or refer to tUI exhibit attached to this Agreement.)
Section
Title
Pages
Re: Exhibit "A"
8.1.5 The Drawings are as follows, and are dated
different date is shown below:
(Either list the Drawings here or refer to an exhibit attached to thisAgreement.J
unless a
Number
Title
Date
Re: Exhibit "Bn
_ ~ _ ...I _ _ _IN _uLI__ aL..... .........1__. ... '-.1 __......a.u.
I
-
ft
Oo.5"QO
t:::::=I
01997 AIAGD
AlA DOCUMENT A101-1997
OWNER-CONTRACTOR
AGREEMENT
The American Institute
of Architects
1735 New York Avenue. N.W.
Washington. D.C. 20006-5292
e
e
8.1.6 The Addenda, if any, are as follows:
Number
One
Two
Date
Pages
23
2
March 20, 2000
March 23, 2000
. . ..' ~. ~~:.,,:. ':.,:.:. ..' ..-:.:.:.';_...:.~-.,-;;::':..:.~.:;.';.:..~'....,:!_......:.;......,:..~:...
t~!~i{~:>> . ".. ".
'~}ir,":' :. .... . <;,>.;/.:.:')/~:..:
'":;,,
.~.~., ':..
Portions of Addenda relating to bidding requirements are not part of the Contract Documents
unless the bidding requirements are also enumerated in this Article 8.
8.1.7 Other documents, if any, forming part of the Contract Documents are as follows:
. (List here any additional documents that are intended to form part of the Contract Docum~nlS. AlA Document
JUOl-lfJfJ7 provides that bidding requirements such as advertisement or invitation to bid. Instructions to Bidders.
sample forms and the Contractols bid are not part of the Contract Documen~s unless enumerated in this
Agreement. They should be listed here only if intended to be part of the Contract Documents.)
The bid. received fran R. Hassell Builders, Inc. in the arrount of
TwO .Million, Three Hundred Fifty-Six Thousand Dollars ($2,356,000.)
plus.Alternate No.1 Monument Signs $19,200. and Alternate No.2
Furniture Package $216, 700., dated and sealed on March 28, 2000.
This Agreement is entered into as of the day and year first written above and is executed in at least
three original copies, of which one is to be delivered to the Contractor. one to the Architect for use
in the administration of the Contract. and the remainder to the Owner.
Q~~ T, ~~
OWN E R (Signature)
I~~
CONTRACTOR(~atu~
Robert T. Herrerra
(Printed name and title)
City Manager
City of Ia Porte
T. K. Tauriello
(Printed name and title)
Vice President
R. Hassell Builders, Inc.
CAUTION: You should sign an original AlA document or a licensed reproduction. Originals contain the AlA logo
printed in red: licensed reproductions are those produced in accordance with the Instructions to this document.
\&IUlI'lI", 11..11........1 IlMtamawlfttt vlcIlahll u.s. CODYriRhr Iawllnd wlIIsubJIICt 1M vlolafar fa leall pl'lllacutlon.
I
-
...,.
.~.~.
...,.~,.
-
Cl997 AIA4D
AlA DOCUMENT AIOI.IS97
OWNER-CONTRACTOR
AGREEMENT
.The American Institute
of Architects .
1735 New York Avenue. N.W.
Washington. D.C. 20006-5292
LA PORTE CO~ ~IBRARY
.99-02
EXHIBIT. A
e
TABLE OF CONTENTS
SECT. NO.
SECTION TITLE
PAGE
BIDDING REQUIREMENTS, CONTRACT FORMS, AND CONDmONS OF nm CONTRACT
NOTICE TO BIDDERS
00030 ADVERTISEMENT FOR BIDS
00100 INSTRUCTIONS TO BIDDERS
00220 GEOTECHNICAL REPORTS
00300 BID FORMS
00500 CONTRACT AGREEMENT
00701 GENERAL CONDITIONS
0800 SUPPLEMENTARY CONDITIONS
1
2
6.
27
3
1
1
6
DMSION 1 - GENERAL REQUIREMENTS
01010 SUMMARY OF WORK
01020 ALLOWANCES
01027 APPLICATIONS FOR PAYMENT
01030 ALTERNATES
o 1035 MODIFICATION PROCEDURES
01045 CUTrING AND PATCHING
01200 PROJECT MEETINGS
01300 SUBMfITALS
01400 QUALITY CONTROL
01421 REFERENCE STANDARDS AND DEFINITIONS
01500 CONSTRUCTION FACILITIES AND TEMPORARY CONTROLS
01600 MATERIALS AND EQUIPMENT
01631 SUBSTITUTIONS
01700 CONTRACT CLOSEOUT
01740 WARRANTIES
1
2.
4
1
.2
3
3
5
3
3
7
4
2
4
3
DMSION 2 - SITEWORK
02230 SITE CLEARING
02260 EXCAVATION SUPPORT AND PROTECTION
02300 EARnIWORK
02361 TERMITE CONTROL
02466 DRILLED PIERS
02511 HOT-MIXED ASPHALT PAVING
02530 SANITARY SEWERAGE
02630 STORM DRAINAGE
02832 ORNAMENTAL IRON RAILING
02930 HYDROMULCHING
2
2
5
3
3
.4
6
6
2
2
TABLE OF CONTENTS
TOC 1
LA PORTE COMMUN~LmRARY
99-02
e
DMSION 3 - CONCRETE
03300 CAST-IN-PLACE CONCRETE
DMSION 4 - MASONRY
04720 CAST STONE
04810 UNIT MASONRY ASSEMBLIES
DMSION 5 - METALS
05120 STRUCTURAL STEEL
05210 STEEL JOISTS
05310 STEEL DECK
05400 COLD-FORMED METAL FRAMING
05500 METAL FABRICATIONS
6
3
7'
4
2
3
4
4.
DMSION 6 - WOOD AND PLASTICS
06100 ROUGHCARPENTRY
06200 FINISH CARPENTRY
06402 INTERIOR ARCHITECTURAL WOODWORK
3
2
5
DMSION 7 - THERMAL AND MOISTURE PROTECTION
07161 BITUMINOUS DAMPPROOFING
07210 BUILDING INSULATION
07411 MANUFACTURED ROOF PANELS
07533 THERMOPLASTIC SINGLE-PLY MEMBRANE ROOFING
07620 SHEET METAL FLASHING AND TRIM
07841 THROUGH-PENETRATION FIRESTOP SYSTEMS
07900 JOINT SEALANTS
2
2
4
4
2
3
4'
DMSION 8 - DOORS AND WlNDOWS
.,
08110 STEEL DOORS AND FRAMES
08121 INTERIOR ALUMINUM DOOR AND GLAZING FRAMES
08215 PLASTIC LAMINATE CLAD FLUSH WOOD DOORS
08331 OVERHEAD COILING DOORS
08410 ALUMINUM ENTRANCES AND STOREFRONTS
08520 ALUMINUM WINDOWS '
08711 DOOR HARDWARE
08800 GLAZING
DMSION 9 - FINISHES
09220 PORTLAND CEMENT PLASTER
09260 GYPSUM BOARD ASSEMBLIES
09310 CERAMIC TILE
095 II ACOUSTICAL PANEL CEILINGS
4
3
3
2
7
3
11
4
6
5
5
4
TABLE OF CONTENTS
TOC2
" e
LA PORTE COMM~LlBRARY
99-02
09651 RESILIENT TILE FLOORING 3
09680 CARPET 3
09841 TACKABLE WALL PANELS 2
09861 GRAFFm RESISTANT COATINGS 4
09900 PAINTING 12
09921 MULTICOLORED INTERIOR COArlNGS 5
DMSION 10 - SPECIALTIES
10100 VISUAL DISPLAY CASES 2,
10101 MARKERBOARDS AND TACKBOARDS 3
10156 TOILET COMPARTMENTS 3
10265 CORNER GUARDS 2 ','
10350 FLAGPOLES 2
10425 SIGNS 2
10437 PLAQUES 1
10520 FIRE-PROTECTION SPECIALTIES 3
10531 ALUMINUM W ALKW A Y COVER 3
10800 TOILET AND BA 11-1 ACCESSORIES 3
DMSION 11 - EQUIPMENT
11050 LmRARY EQUIPMENT 2
11132 PROJECTION SCREENS 2
11451 RESIDENTIAL APPLIANCES 2
DMSION 12 - FURNISHINGS
12505 LIBRARY FURNISHINGS 33
12511 HORIZONTAL LOUVER BLINDS 3
12520 SHADES 3
DMSION 13 - SPECIAL CONSTRUCTION - NOT USED
DMSION 14 - CONVEYING SYSTEMS - NOT USED
"
TABLE OF CONTENTS
TOC3
LA PORTE COM~& fY LIBRARY
99-02
e,
"
DIVISION 15 - MECHANICAL
SECTION DESCRIPTION PAGES
15010 GENERAL PROVISION FOR MECHANICAL WORK 1-17
15070 VIBRATION ISOLATION 1-6
15075 MECHANICAL IDENTIFICATION 1-2
15082 DUCTWORK INSULATION 1 - 5
15084 EQUIPMENT INSULATION 1-4
15086 PIPING INSULATION 1-8
15105 HYDRONIC PIPING 1-10
15120 HYDRONlC SPECIALTIES 1-6
15125 EXPANSION TANKS 1-2
15130 PUMPS 1-4
15188 CHEMICAL WATER TREATMENT 1-4
15400 PLUMBING SYSTEMS, FIXTURES AND TRIM 1-10
15411 NATURAL GAS PIPING SYSTEMS 1-3
15510 BOILER - GAS FIRED 1-4
15672 AIR COOLED CONDENSING UNITS 1-3
15722 AIR HANDLlNG UNITS 1-3
15785 MOTORS AMD CONTROLERS 1-6
15818 DUCTWORK 1-7
15838 POWER VENTILATORS 1-3
15862 AIR FILTERS 1-3
15910 DIRECT DIGITAL CONTROL SYSTEM 1-15
15950 TESTING, ADJUSTING AND BALANCING (TAB) J - 10
Division 15 - Mechanical
15000-t
LA PORTE CO~~ I V LIBRARY
99-02
e
DMSION 16 - ELECTRICAL
. SECTION DESCRIPTION PAGES
16010 GENERAL PROVISIONS FOR ELECTRICAL WORK 1-18
16050 BASIC ELECTRICAL MATERIALS AND METHODS 1-5
16060 GROUNDING 1-2
16070 HANGERS AND SUPPORTS 1-3
16075 ELECTRICAL IDENTIFICATION 1-5
16140 WIRING DEVICES 1-4
16400 SERVICE AND DISTRIBUTION 1-11
.'
16500 LIGHTING FIXTURES 1-2
16720 FIRE ALARM SYSTEM 1-5
16740 TELEPHONE SYSTEM 1
16910 HEATING, VENTILATION AND AIR CONDITIONING 1-3
CONTROL WIRING
16950 TESTING OF ELECTRICAL SYSTEM 1-2
Division 16 - Electrical
16000- 1
e
~~~EX.I:IIBlr .B.. ;_..__
""IDEX TO DRAWINGS
COVER SHEET
G1.00 INDEX / ACCESSIBILITY STANDARDS
C~Vfl DPU\\i!IINJGS:
c 1. 0 SITE SURVEY
C2.0 GRADING PL';N
C .3.0 UTILITY PLAN
C 4.0 GENERAL NOTES
0:5.0 MISCELLANEOUS DETAILS
C5.0 MISCELLANEOUS DETAILS
C/.G JOINT LAYOUT
C5.0 PAVING OET.;!LS
LAN~SC~?E DRi~\f~tINGS:
_1.01 LANDSCAPE PLAN
_1.02 IRRIGATION DEiAILS
.~j~OH(TIECTURAL DRAWINGS:
~".o, SITE PLAN
ll, L02 SITE DETAILS
~.2,ljl FLOOR PLAN
~2 ." ': fURNiTuRE/FINISH PLAN
~~. REflECTED CEILING PLAN
~2.21 ROOf PLAN/ DETAILS
~2.31 ENLARGED fLOOR PLANS/ ACCESSORIES SCHEDULE
:"3.01 PARTITION TYPES/ fiNISH SCHEDULE
~3." DOOR TYPES/ DOOR SCHEDULE/ DETAILS
~3.12 WINDOW TYPES/ DETAILS
~.4.01 BUILDING ELEVATIONS
~5.01 BUILDING SECTIONS.
1,5.02 WALL SECTIONS
..5.0.3 WALL SECTIONS
1.5.04 WALL SECTIONS
\6.01 PLAN DETAILS
\7.01 INTERIOR ELEVATIONS
,7.02 INTERIOR ELEVATIONS
;7.03 INTERIOR ELEVATIONS
.7.04 INTERIOR ELEVATIONS
.7.05 INTERIOR ELEVATlONS/ MIUWORK DETAILS
e
STRUCTURAL DRAW5NGS:
51.1 GENERAL NOTES
52.1 FOUNDA TlON PLAN
52.2 ROOf fRAMING PLAN
53.1 TYPICAL DETAILS
53.2 TYPICAL DETAILS
5~.1 TYPICAL DETAILS
54.2 TYPICAL DETAILS
55. 1 BRACING
MECH.lIEILEC./FLUM8. DRAWING.
'\~EPv:OO MEP SITE PLAN
1.1.2.00 HVAC PLAN
1J,3.00 HVAC DETAILS
!.~4.00 HVAC DETAILS
!.~ 5. 00 HVAC SCHEDULES
,
ELECTRICAL liGHTING PLAN
ELECTRICAL POWER PLAN
ELECTRICAL DETAILS
ELECTRICAL DETAILS
FIRE ALARM PLAN
PLUMBING FLOOR PLAN
PLUMBING DETAILS
PLUMBING ROOf PLAN
PLUMBING DETAILS
PLUMBING SCHEDULES
::2.C'O
E3.00
E4.00
E5,QQ
E5.00
P2.00
P3.00
P4.00
P5.00
F6.DO
e e.
IMP 0 R TAN T NOT ICE
TO OBTAIN INFORMATION OR MAKE A COMPLAINT;
YOU MAY CONTACT THE TEXAS DEPARTMENT OF
INSURANCE TO OBTAIN INFORMATION ON COMPANIES;
COVERAGES, RIGHTS OR COMPLAINTS AT:
1-800-252-3439
YOU MAY WRITE THE TEXAS DEPARTMENT OF INSURANCE:
P.O. BOX 149104
AUSTIN, TEXAS 78714-9104
FAX # (512) 475-1771
PREMIUM OR CLAIM DISPUTES:
SHOULD YOU HAVE A DISPUTE CONCERNING YOUR PREMIUM OR ABOUT A
CLAIM YOU SHOULD CONTACT THE AGENT OR COMPANY FIRST. IF THE
DISPUTE IS NOT RESOLVED, YOU MAY CONTACT THE TEXAS
DEPARTMENT OF INSURANCE.
ATTACH THIS NOTICE TO YOUR POLICY
THIS NOTICE IS FOR INFORMATION ONLY AND DOES NOT BECOME A
PART OR CONDITION OF THE ATTACHED DOCUMENT.
e
e-
AlA Document A3l2
Bond No.
61 BCSAK1591
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
Performance Bond
CONTRACTOR (Name and Address):
R. Hassell Builders, Inc.
P.O. Box 690767
Houston, Texas 77269-0767
SURETY (Name and Principal Place of Business):
Hartford Fire Insurance Company
P.O. Box 4611
Houston, Texas 77210-4611
OWNER (Name and Address):
City of La Porte
P.O. Box 1115
La Porte, Texas 77572-1115
CONSTRUCTION CONTRACT
Date: April 20 2000
Amount: Two Million Five Hundred Ninety One Thousand Nine Hundred and noI100--($2,591,900.00)
Description (Name and Location): La Porte Community Library, 600 S. Broadway, La Porte, TX 77571
BOND
Date (Not earlier than Construction Contract Date): April 20 2000
Amount: Two Million Five Hundred Ninety One Thousand Nine Hundred and no/1 00--($2,591 ,900.00)
Modifications to tins Bond:
-')NTRACTOR AS PRINCIPAL
mpany: R. Hassell Builders, Inc. (Corporate Seal)
Signature:C'V~ .
Name and Title: -r. jtt:. IAUA!-l el/o 0 G4 ,qze~J.I/:!I~
(Any additional signatures appear on page 2.)
(FOR INFORMA nON ONLY - Name, Address and
Telephone) AGENT or BROKER: (281) 540-1 555
Elsey & Associates Surety/Insurance
8820 Will Clayton Pkwy., Humble, TX 77338
1 The Contractor and the Surety, jointly and severally, bind themselves,
their heirs, executors, administrators, successors and assigns to the Owner
for the perfonnance of the Construction Contract, which is incorporated
herein by reference.
2 If the Contractor perfonns the Construction Contract, the Surety and
the Contractor shall have no obligation Wlder this Bond, except to
participate in conferences as provided in Subparagraph 3.1.
3 If there is no Owner Default, the Surety's obligation WIder this Bond
shall arise after:
3.1 The Owner has notified the Contractor and the Surety at its
address described in Paragraph 10 below that the Owner is considering
declaring a Contractor Default and has requested and attempted to
arrange a conference with the Contractor and the Surety to be held not
later than fifteen days after receipt of such notice to discuss methods of
perfonning the Construction Contract. If the Owner, the Contractor and
the Surety agree. the Contractor shall be allowed a reasonable time to
SURElY 5026 16-921
S-1852/GEEF 7/96
Page 1 of 2
~ None
SURETY
Company: Hartford Fire Insurance
Co ny
D See Page 2
(Corporate Seal)
n
l'
Signature:
Name and Tit e:
OWNER'S REPRESENTATIVE (Architect, Engineer or other
party): Hall/Barnum Architects, Inc.
2727 Weslayan
Houston, Texas 77027
perfonn the Construction Contract, but such an agreement shall
not waive the Owner's right, if any, subsequently to declare a
Contractor Default; and
3.2 The Owner has declared a Contractor Default and fonnally
tenninated the Contractor's right to complete the contract. Such
Contractor Default shall not be declared earlier than twenty days
after the Contractor and the Surety have received notice as
provided in Subparagraph 3.1; and
3.3 The Owner has agreed to pay the Balance of the Contract
Price to the Surety in accordance with the tenns of the
Construction Contract or to a contractor selected to perfonn theeConstruction Contract in accordance with the tenns of the
contract with the Owner,
4 When the Owner has satisfied the conditions of Paragraph 3, the
Surety shall promptly and at the Surety's expense take one of the
following actions:
4.1 Arrange for the Contractor,.A lsent of the Owner, to
nerfonn and complete the Constructi~.....act; or
4.2 Undertake to perfonn and complete the Construction Contract
itself, through its agents or through independent contractors; or
4.3 Obtain bids or negotiated proposals from qualified contractors
acceptable to the Owner for a contract for perfonnance WId
completion of the Construction Contract, arrange for a contract to be
prepared for execution by the Owner and the contractor selected with
the Owner's concurrence, to be secured with perfonnance WId
payment bonds executed by a qualified surety equivalent to the bonds
Issued on the Construction Contract, and pay to the Owner the
amount of damages as described in Paragraph 6 in excess of the
Balance of the Contract Price incurred by the Owner re~lting from
the Contractor's default; or
4.4 Waive its right to perfonn and complete, arrange for completion,
or obtain a new contractor and with reasonable prompbtess under the
circumstances:
. 1 After investigation, detennine the amount for which it
may be liable to the Owner and, as soon as practicable
after the amount is detennined, tender payment therefor
to the Owner; or
.2 Deny liability in whole or in part and notifY the Owner
citing reasons therefor.
5 If the Surety does not proceed as provided in Paragraph 4 with
reasonable promptness, the Surety shall be deemed to be in default on this
Bond f1fteen days after receipt of an additional written notice from the
Owner to the Surety demanding that the Surety perfonn its obligations
under this Bond. and the Owner shall be entitled to enforce WlY remedy
available to the Owner. If the Surety proceeds as provided in
Subparagraph 4.4, and the Owner refuses the payment tendered or the
Surety has denied liability, in whole or in part, without further notice the
Owner shall be entitled to enforce any remedy available to the Owner.
6 After the Owner has tenninated the Contractor's right to complete the
Construction Contract, and if the SurelY. elects to act WIder Subparagraph
4.1,4.2, or 4.3 above, then the responsibilities of the Surety to the Owner
shall not be greater than those of the Contractor under the Construction
Contract, and the responsibilities of the Owner to the Surety shall not be
- ~'lter than those of the Owner under the Construction Contract. To the
t of the amount of this Bond, but subject to commitnlent by the Owner
'n dte Balance of the Contract Price to mitigation of costs and damages on
the Construction Contract, the Surety is obligated without duplication for:
6.1 The responsibilities of the Contractor for correction of defective
work and completion of the Construction Contract;
6.2 Additional legal, design professional and delay costs resulting
from the Contractor's Default, and resulting from the actions or
failure to act of the Surety under Paragraph 4; and
6.3 Liquidated damages, or ifno liquidated damages are specified in
the C<>nstruction Contract, actual damages caused by delayed
perforn,ance or non-perfonnance of the Contractor.
MODIFICATIONS TO TInS BOND ARE AS FOLLOWS:
7 The surea .ot be liable to the Owner or others for obligations
of the Contractor tho.. dre unrelated to the Construction Contract, WId the
Balance of the Contract Price shall not be reduced or set ofT on account of
any such unrelated obligations. No right of action shall accrue on this
Bond to any person or entity other than the Owner or its heirs, executors.
administrators or successors.
8 The Surety hereby waives notice of any change, including changes of
time, to the Construction Contract or to related subcontracts, purchase
orders and other obligations.
9 Any proceeding, legal or equitable, under this Bond may be
instituted in any court of competent jurisdiction in the location in which
the work or part of the work is located and shall be instituted within two
years after Contractor Default or within two years after the Contractor
ceased working or within two years after the Surety refuses or fails to
perfonn its obligations under this Bond, whichever occurs first If the
provisions of this Paragraph are void or prohibited by law, the minimum
period of limitation available to sureties as a defense m the jurisdiction of
10 Notice to the Surety, the Owner or the Contractor shall be mailed or
delivered to the address shown on the signature page.
11 When this Bond has been furnished to comply with a statutory or
other legal requirement in the location where the construction was to be
perfonned, any provision in this Bond conflicting with said statutory or
legal requirement deleted herefrom and provisions confonning to such
statutory or other legal requirement shall be deemed incorporated herein.
The intent is that this Bond shall be construed as a statutory bond WId not
as a common law bond.
12 DEFINITIONS
12.1 Balance of the Contract Price: The total amount payable by
the Owner to the Contractor under the Construction Contract after all
proper adjustments have been made, including allowance to the
Contractor of any amounts received or to be received by the Owner
in settlement of insurance or other claims for damages to which the
Contractor is entitled, reduced by all valid and proper payments
made to or on behalf of the Contractor under the Construction
12.2 Construction Contract: The agreement between the Owner
and the Contractor identified on the signature page, including all
Contract Docwnents and changes thereto.
12.3 Contmctor Default: Failure of the Contractor. which has
neither been remedied nor waived, to perfonn or otherwise to comply
with the tenns of the Construction Contract.
12.4 Owner Default: Failure of the Owner. which has neither been
remedied nor waived, to pay the Contractor as required by the
Construction Contract or to perfonn and complete or comply with the
other tenns thereof.
(Space is provided below for additional signatures of added parties, other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company:
'lature:
. ...me and Title:
Address:
S.1852/GEEF 7/96
Page 2 of 2
(Corporate Seal)
Signature:
Name and Title:
Address:
e
AlA Document A312
e
Payment
Bond
Bond. No.
61BCSAK1591
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where
CONTRACTOR (Name and Address):
R. Hassell Builders, Inc.
P.O. Box 690767
Houston, Texas 77269-0767
SURETY (Name and Principal Place of Business):
Hartford Fire Insurance Company
P.O. Box 4611
Houston, Texas 77210-4611
OWNER (Name and Address):
City of La Porte
P.O. Box 1115
La Porte, Texas 77572-1115
CONSTRUCTION CONTRACT
Date: April 20 2000
Amount: Two Million Five Hundred Ninety One Thousand Nine Hundred and no/1 00--($2,591 ,900.00)
Description (Name and Location): La Porte Community Library, 600 S. Broadway, La Porte, Texas 77571
BOND
Date( Not earlier than Construction Contract Date): April 20 2000
Amount: Two Million Five Hundred Ninety One Thousand Nine Hundred and no/1 00--($2,591,900.00)
Modifications to this Bond:
"t')NTRACTOR AS PRINCIPAL
mpany: R. Hassell Builders, Inc. (Corporate Seal)
~_(Y~.
Name and Title: -r;jt::. lAu"e,el/o Vice ~,eu-r
(Any additional signatures appear on page 2.)
(FOR INFORMATION ONLY - Name, Address and
Telephone) AGENT or BROKER: (281) 540-1555
Elsev & Associates Surety/Insurance
8820 Will Clayton Pkwy., Humble, TX 77338
1 The Contractor and the Surety, jointly and sevemlly, bind themselves,
their heirs, executors, administrators, successors and assigns to the Owner
to pay for labor, materials and equipment furnished for use in the
perfonnance of the Construction Contract, which is incorporated herein by
reference.
2 With respect to the Owner. this obligation shall be null and void if the
Contractor:
2.1 Promptly makes payment, directly or indirectly, for all sums due
Claimants, and
2.2 Defends, indemnifies and holds hannless the Owner from claims,
demands, liens or suits by any person or entity whose claim, demand,
lien or suit is for the payment for labor, materials or equipment
furnished for use in the perfonnance of the Construction Contract,
provided the Owner has promptly notified the Contractor and the
Surety (at the address described in Paragraph 12) of any claims,
demands, liens or suits and tendered defense of such claims, demands,
liens or suits to the Contractor and the Surety, and provided there is
no Owner Default.
SURETY 5026 16-921
5-1853/GEEF 6/96
Page 1 of 2
~ None
SURETY
Company: Hartford Fire Insurance
pany
D See Page 2
(Corporate Seal)
OWNER'S REPRESENTATIVE (Architect, Engineer or other
party): Hall/Barnum Architect!';, Inc.
2727 Weslayan .~
Houston, Texas 77027
3 With respect to Claimants, this obligation shall be null and void if
the Contractor promptly makes payment, directly or indirectly, for all
sums due.
4 The Surety shall have no obligation to Claimants under this Bond
Wltil:
4.1 Claimants who are employed by or have a direct contract
with the Contractor have given notice to the Surety (at the
address described in Paragraph 12) and sent a copy, or notice
thereof, to the Owner. stating that a claim is being made under
this Bond and, with substantial accuracy, the amowlt of the
4.2 Claimants who do not have a direct contract with the
Contractor:
.1 Have furnished written notice to the Contractor and sent a
copy. or notice thereof, to the Owner, within 90 days after
having last perfonned labor or last furnished materials or
equipment included in the claim stating, with substantial
accuracy, the amount of the claim and the name of the party
to whom the materials were funtished or supplied or for
whom the labor was done or perfontled; and
.2 Have either received a rejectie bole or m part from the
Contractor, or not received within. -,0 days of fumishing the
above notice any colmmmication from the Contractor by which
the Contractor has indicated the claim will be paid directly or
indirectly, and
.3 Not having been paid within the above 30 days, have sent a
written notice to the Surety (at the address described in
Paragraph 12) and sent a copy, or notice thereof, to the Owner
stating that a claim is beirig made ooder this Bond and
enclosing a copy of the previous written notice fumished to the
Contractor.
5 If a notice required by paragraph 4 is given by Owner to the
Contractor or to the Surety. that is sufficient compliance.
6 When the Claimant has satisfied the conditions of Paragraph 4, the
Surety shall promptly and at the Surety's expense take the following
actions:
6.1 Send an answer to the Claimant, with a copy to the Owner,
within 45 days after receipt of the claim, stating the amounts
that are undisputed and the basis for challenging any amowlts
that are disputed.
6.2 Payor arrange for payment of any oodisputed amowlts.
7 The Surety's total obligation shall not exceed the amooot of this Bond,
and the amount of this Bond shall be credited for any payments made in
good faith by the Surety.
8 Amooots owed by the Owner to the Contractor ooder the Construction
Contract shall be used for the perfonnance of the Construction Contract
and to satisfy claims, if any, under any Construction Perfonnance Bond.
By the Contractor furnishing and the Owner accepting this Bond, they
agree that all foods earned by the Contractor in the perfonnance of the
Construction Contract are dedicated to satisfy obligations of the Contractor
and the Surety under this Bond, subject to the Owner's priority to use the
funds for the completion of the work.
9 The Surety shall not be liable to the Owner, Claimants or others for
obligations of the Contractor that are unrelated to the Construction
""ntract. The Owner shall not be liable for payment of any costs or
::nses of any Claimant ooder this Bond, and shall have ooder this bond
11... obligations to make payments to. give notices on behlllf of, or otherwise
have obligations to Claimants ooder this Bond.
10 The Surety hereby waives notice of any change, including changes of
time, to the Construction Contract or to related subcontracts, purchase
orders and other obligations.
11 No suit or action shall be commenced by a Claimant ooder this Bond
other than in a court of competent jurisdiction in the location in which
MODIFICATIONS TO TIllS BOND ARE AS FOLLOWS:
the work or ~ work is located or after the expiration of one year
from the date (I) II.. which the Claimant gave the notice required by
Subparagraph 4. lor Clause 4.2.3, or (2) on which the last labor or service
was perfonned by anyone or the last materials or equipment were
furnished by anyone under the Construction Contract, whichever of (I) or
(2) first occurs. If the provisions of this Paragraph are void or prohibited
by law, the minimum period oflimitation available to sureties as a defense
in the jurisdiction of the suit shall be applicable.
12 Notice to the Surety, the Owner or the Contractor shall be mailed or
delivered to the address shown on the signature page. Actual receipt of
notice by Surety, the Owner or the Contractor, however accomplished,
shall be sufficient compliance as of the date received at the address shown
on the signature page.
13 When this Bond has been furnished to comply with a statutory or
other legal requirement in the location where the construction was to be
perfonned, any provision in this Bond conflicting with said statutory or
legal requirement shall be deemed deleted herefrom and provisions
confonning to such statutory or other legal requirement shall be deemed
incorporated herein. The intent is that this Bond shall be construed as a
statutory bond and not as a common law bond.
14 Upon request by any person or entity appearing to be a potential
beneficiary of this Bond, the Contractor shall promptly fumish a copy of
this Bond or shall pennit a copy to be made.
15 DEFINITIONS
15.1 Claimant: An individual or entity having a direct contract
with the Contractor or with a subcontractor of the Contractor to
furnish labor, materials or equipment for use in the perfonnance of
the Contract. The intent of this Bond shall be to include without
limitation in tenns "labor, materials or equipment" that part of
water, gas, power, light, heat, oil, gasoline, telephone service or
rental equipment used in the Construction Contract, architectural
and engineering services required for perfonnance of the work of the
Contractor and the Contractor's subcontractors, and all other items
for which a mechanic's lien may be asserted in the jurisdiction where
the labor. materials or equipment were fUOlished.
15.2 Construction Contract: The agreement between the Owner
and the Contractor identified on the signature page, including all
Contract Documents and changes thereto.
15.3 Owner Default: Failure of the Owner, which has neither
been remedied nor waived, to pay the Contractor as required by the
Construction Contract or to perfonn and complete or comply with
the other tenns thereof.
(Space is provided below for additional signatures ofadded parties, other than those appearing on the cover page.)
CONTRACfOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company:
lUlture:
. .c.&IJle and Title:
Address:
S-1853/GEEF 6/96
Page 2 of 2
(Corporate Seal)
Signature:
Name and Title:
Address:
. rFORD FIRE INSURANCE CO. NY
Hartford, Connecticut
POWER OF ATTORNEY
Know all men by these Presents, That HARTFORD FIRE INSURANCE COMPANY, a corporation duly organized under the laws 01 the State 01 Connecticut, and having its
pro .I office in the City 01 Hartford, County 01 Hartford. State of Connecticut, does hereby make, constitute and ape.,int
BRUCE C. Def/ART, EDWARD L MOORE. D.-HI/D R. GROPPELL, REGINA C. DOWLING,
ROSALYN D, HASSELL and NANCY TANKO of HUMBLE, TEXAS
its true and lawful Attomey(s)-in-Fact, with lull power and authority to each 01 said Attomey(s)-in-Fact, in their separate capacity il more than one is named above, to sign, execute and
acknowledge any and all bonds and undertakings and other writings obligatory in the nature thereol on behall 01 the Company in its business 01 guaranteeing the lidelity 01 persons
holding places of public or private trust; guaranteeing the performance of contracts other than insurance policies; guaranteeing the performance of insurance contracts where surety
bonds are accepted by states and municipalities, and executing or guaranteeing bonds and undertakings required or permilled in all actions or proceedings or by law allowed, and to
bind HARTFORD FIRE INSURANCE COMPANY thereby as fully and to the same extent as il such bonds and undertakings and other writings obligatory in the nature thereof were
signed by an Executive Officer 01 HARTFORD FIRE INSURANCE COMPANY and sealed and attested by one other of such Officers, and hereby ratifies and conlirms all that its said
Allorney(s)-in-Fact may do in pursuance hereof.
This Power of Allorney is granted under and by authority 01 the By-Laws of HARTFORD FIRE INSURANCE COMPANY, (-~he Company") as amended by the Board of Directors at a
meeting duly called and held on July 9, 1997, as follows:
ARTICLE IV
SECTION 7. The President or any Vice President or Assistant Vice-President, acting with any Secretary or Assistant Secretary shall have power and authority to sign and
execute and allach the seal 01 the Company to bonds and undertakings, recongnlzances, contracts of indemnity and other writings obligatory in the nature thereof, and such instruments
so signed and executed, with or without the common seal, shall be valid and binding upon the Company.
SECTION 8. The President or any Vice-President or any Assistant Vice President acting with any Secretary or Assistant Secretary, shall have power and authority to appoint,
lor purposes only 01 executing and allesting bonds and undertakings and other writings obligatory in the nature thereof, one or more resident Vice Presidents, resident Assistant
Secretaries and Attorneys-in-Fact and at any time to remove any such resident Vice-President, resident Assistant Secretary, or Attorney-in-Fact, and revoke the power and authority
given to him.
Resolved, that the signatures 01 such Officers and the seal 01 the Company may be affixed to any such power 01 allorney or to any certificate relating thereto by facsimile, and
any such power 01 attorney or certilicate bearing such lacsimile signatures or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified
by facsimile signatures and facsimile seal shall be valid and binding upon the Company in the luture with respect to any bond or undertaking to which it is attached.
In Witness Whereof, HARTFORD FIRE INSURANCE COMPANY has caused these presents to be signed by its Assistant Vice-President, and its corporate seal to be
hereto affixed, duly attested by its Secretary, this 14th day of May, 1999.
1>' ~O
Ot,~
Paul A. Bergenholtz, Assistant Secretary
STATE OF CONNECTICUT}
ss.
COUNTY OF HARTFORD
Hartford
HARTFORD FIRE INSURANCe COMPANY
/q
Robert L Post, Assistant Vice President
On this 14th day of May, A.D. 1999, before me personally came Robert L. Post. to me known, who being by me duly sworn, did depose and say: that he resides in the County of
Hartford, State of Connecticut; that he is the Assistant Vice-President 01 HARTFORD FIRE INSURANCE COMPANY, the corporation described in and which executed the above
instrument; that he knows the seal 01 the said corporation; that the seal affixed to the ;:::: :~3!rument is such corporate seal; that it was so affixed by order of the Board 01 Directors of
said corporation and that he signed his name ther,,!o by Iik~ 'rC9r.
G~ ~:::~
/ -- Notary Public
My Conunission Expires June 30, 2004
I, the undersigned, Secretary 01 HARTFORD FIRE INSURANCE COMPANY, a Connecticut Corporation, DO HERc6Y CERTIFY that the foregoing and allached POWER OF
ATTORNEY remains in lull force and has not been revoked; and furthermore, that Article IV, Sections 7 and 8 01 the By-Laws of HARTFORD FIRE INSURANCE COMPANY, set forth
in the Power of Allorney. are now in lorce.
Signed and sealed at the City 01 Hartford,
Dated the
20th
~w LlLf^MJ^-'
Richard L. Marshall. Jr., Assistant Secretary
1:'"..", C;L'1..::.n-LQ 1J.1J;"\ u..:n,.,I;n 11 c;: .4..
day of
April
2000
~.d~C
J. Dennis Lane, Assistant Vice President
.~~. A.CORD.... ~r'fj:Etll:rft~I?'.. ':'.'~:lbtl:F.f;ll~II::,::[!n.!!trli~t ....'.'1~lm:lljnif:&:tt{;}4k. ....... ........ ..
DATE (MMlDDNY)
04/19/00 :
PRODU!':ER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
Elsey & Associates ONLY ANa CONFERS NO RIGHTS UPON THE CERTIFICATE
Surety/Insurance Aqency, Inc. HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
8820 Will Clayton Pkwy. ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW,
Ible 'l'X 77338 COMPANIES AFFORDING COVERAGE
James L. Honeycutt COMPANY
A National American Insurance
Phone No. 291-540-1555 Fax No. 2&1-540-7419
INSURED COMPANY
B Zurich Insurance Company
R. Hassell & Co. , Inc. , COMPANY
R.Hassell Builders, Inc. et al C
P.O. Box 690767 COMPANY
Houston 'l'X 77269-0767 D
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS,
CO TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS
LTR DATE (MMlDDNY) DATE (MMlDDNY)
GENERAL LIABILITY GENERAL AGGREGATE $ 2 ,000 ,000
I--
A X ~MERCIAL GENERAL L1ABIUlY MP2377042D 04/01/00 04/01/01 PRODUCTS-COMPIDPAGG s 1,000,000
~. CLAIMS MADE ~ OCCUR PERSONAL & ADV INJURY $ 1,000,000
~ OWNER'S & CONTRACTOR'S PROT EACH OCCURRENCE S 1,000 ,000
X Aqq Per Project ARE DAMAGE (Anyone fire) S 100,000
X Contractual XCU INCLUDED MED EXP (Anyone person) $ 5,000
AUTOMOBILE LIABILITY
--- COMBINED SINGLE LIMIT S 1,000,000
A ~ ANY AUTO At12209442D 04/01/00 04/01/01
~ ALL OWNED AUTOS BODILY INJURY
$
SCHEDULED AUTOS (Per person)
f--
~ HIRED AUTOS BODILY INJURY
S
~ NON-OWNED AUTOS (per accident)
- PROPERTY DAMAGE S
~RAGE LIABILITY AUTO ONLY - EA ACCIDENT S
ANY AUTO OTHER THAN AUTO ONLY: ~f:~ ::.t.::::..~~/\~.;.:.:.~::.:..:.:. ';
-
- EACH ACCIDENT S
AGGREGATE S
EXCESS LIABILITY EACH OCCURRENCE S 10,000 ,000
A M UMBRELLA FORM MB2194742D ~4/01/00 04/01/01 AGGREGATE s 10 ,000 ,000
OTHER THAN UMBRELLA FORM S
WORKERS COMPENSATION AND X IWCSTATU- I IOTH- ~t~.}:r1~:j~~f~;~{: :;:~:' :::~.;: 1.i: i.~' .:': ..::~
TORY LIMITS ER
EMPLOYERS' LIABILITY S 1,000,000
EL EACH ACCIDENT
A THE PROPRIETOR! pq INCL CW2694042D 04/01/00 04/01/01 EL DISEASE. POLICY LIMIT S 1,000,000
PARTNER~CUT1VE
A OFFICERS ARE: EXCL CW2694042D 04/01/00 04/01/01 EL DISEASE - EA EMPLOYEE $ 1,000 ,000
OTHER
A Contractors Equip MP2377042D 04/01/00 04/01/01 Owned Leased/Rent
B Builders' Risk ECA55861976 11/19/99 11/19/00 Reportinq 3,000,000
DESCRIPTION OF OPERATlONSlLOCATlONSlVEHICLESlSPECIAL ITEMS
Re: L1porte Community L1braryl CLP Project #99-2201-Cert holder & architect
(Hall Barnum Architects Inc. are named as additional insured on all
~olic1es {except WC). Waiver of subroqation and 30 Day Notice of contract.
ancellat10n applies to all policiies. All as reqgired by written
*or material Iv chanqed
::CE.~;Trf,{9.~!gJ{9:~RDff:t:n}:;:;;J:j;j;;~'.Ir!::J{.::/I?rIn:::~:tn\:W:I;mIrtI!?}:'t:<:!gwP.~rm~W~}lg~?:tHj{I.I/!WiJ\?IJHtt:r:??:::j;}Jt:\<(}'::i\lt-::::!;:.:;:::::;r-r.; :,.,..;..:;: ;
CITLOOl SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL MAIL
City ~ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
of LaPorte GU~II .IQ:RQ~ ell"ll! If IPse!! I IS eBLI~el4 eR L1ABILffV
P.O. Box 1115
LaPorte 'l'X 77572-1115 '~NT'r. · IL_-"N' .
J L. Honeycutt
.:A~q8Q:.~.~~;C~i~$f=:;:: ::;Nr~.'j}:}.U.:.;::::':.i::l}.:;I;:t::.I::: f.g?Hl.\JVz.ft.\~ t~~::j}Shir))\Ui.,::t/:f:::.::n:\i::::: ::::::.:::t)t~fW~lt:j:~~;f:::: j>:::}jq:6jJ:f)f/;,fV:t).::ij'qPR'D.J~Q8.F,f:~J~AJIP~J;~Q8
Project: JOB#,
LaPorte Community Library
600 South Broadway
LaPorte, TX 77571
Gen'l Superintendent, Chuck Gilbert.
Ai'Ct.._~
Hall/Barnum Architect
2727 Weslayan
Houston, TX 77027
Contact, Bill Hall
I. EARTHWORK
R HASSELL BUILDERS, INC.
POBOX 690767
HOUSTON. 7n69
281-586-0565
FAX 281-893-6053
8. METAL ROOF/UNDERLAMENT
KIRTLEY SHEET METAL
14830 BOUDREAUX ROAD
TOMBALL. 77375
281.351-1022
FAX 281-351-4304
CONTACT, DARREL KIRTLEY
9. JOINT SEALANTS
FOUR SEASONS WATERPRFNG
POBOX 36082
HOUSTON, 7n36-6082
281-286-5443
FAX 713-666-0458
CONTACT. GARY SMITH
10. HOLLOW METAL DOORS.
SOUTHERN SYSTEMS, INC.
2129 CLINTON DRIVE
GALENA PARK. 77547
713.646-0378
FAX 713-676-0436
CONTACT, BILL BARNHILL
II. ALUMINUM FRAMES
ATLAS INTERIOR PRODUCTS
130 I GREENGRASS DRIVE
HOUSTON, 77008
713-863-0275
FAX 713-863-1627
CONTACT, ABBIE MCNALLY
12. PLASTIC LAMINATE DOORS
AUNSON, INC.
203 BLUE BELL
HOUSTON, 77037
281-260-7800
FAX 281-26G-7878
CONTACT, All POONAWALA
13. COILING DOORS
OVERHEAD DOOR CO OF HOU
11533 SOUTH MAIN
HOUSTON, 77025-5987
713-667-1757
FAX 713-667-9451
CONTACT, JOAN SKIPPER
14. ALUM WINDOW/GLASS/GLAZING
OLD SPRING GLASS
1919 SPRING CYPESS
SPRING. 77383
281-350-6733
FAX 281-35G-1447
CONTACT, RAYFORD/SHELLY
2. SITE PAVING, LIME STABILIZATION
R HASSELL 81 COMPANY
POBOX 690767
HOUSTON, m69
281-586-0565
FAX 281-893-6053
3. ASPHALT
I E CHANCE CONTRACTING
519 GOODSON LOOP
PINEHURST, 77362-2565
281.440.1674
FAX 1/281-356-3076
CONTACT, ELEANOR/ISAAC
4. TERMITE/PEST CONTROL
HILL 81 HILL EXTERMINATORS, INC.
6965 GRIGGS ROAD
HOUSTON, 77023
713-921-2193
FAX 713-921-2195
CONTACT, STEPHEN BREWER
S. STRIPING
ACTION PARKING AREA MAINTENANCE
POBOX 2144
PEARLAND, 77588
713-433-9548
FAX 281-997-7902
CONTACT, DICK MANN
6. DRILLED PIERS
COASTAL FOUNDATION DRILLING, INC.
45 10 SAUNDERS
HOUSTON, 77093
713-691.0977
FAX 691-0974
CONTACT, MIKE CAMPBELL
7. MILLWORK
ADVANTAGE AMERICA
9032-0 SWEElWATER
HOUSTON, 77073
281-260-8226
FAX 281-26G-8248
CONTACT, JAMES GRIMM
e.
e
LAPORTE COMMUNITY LIBRARY, JOB# 0200 (PAGE 2 OF 2)
15. LATH & PLASTER
GOLDENWEST ENTERPRISES, INC.
333 NORTH BELT, SUITE 205
HOUSTON, 77060
281-820.9600
FAX 281-820-9699
CONTACT, PHILIP LUlTRELL
16. DRYWALL
K C SERVICES
14518 HEMPSTEAD, #5E
HOUSTON. 77040
713.895-7788 (CELL 281-235.9243)
FAX 713-895-7799
CONTACT, DEAN KELLY
17. CERAMIC TILE
K V TILE, COMPANY
16838 1-10 EAST
HOUSTON. 77530
281-457.6363
FAX 281-457-6512
CONTACT, MIKE C.
18. STONE FLOORING
NATIONAL TERRAZZO & TILE
5728 HOOD
HOUSTON, 77023
713-923-8600
FAX 713-923-1043
CONTACT, JAMES LANGLEY
19. ACOUSTICAL CEILINGS
LASER ACOUSTICS
3939 HILLCROFT, SUIE 170
HOUSTON, 77057
713-953-0555
FAX 713-953-1828
CONTACT, DENNIS GELDER
22. FLAG/FLAG POLE
GARDNER MARTIN, INC.
2900 BELTWAY 8 EAST
PASADENA, 77503
281-487-8889
FAX 281-487-8884
CONTACT, DIANE HARRISON
23. ALUMINUM WALKWAY
E L BURNS COMPANY, INC.
POBOX 19160
SHREVEPORT. LA 71149
318-636-2722
FAX 31 S-636-5052
CONTACT, JAMES FAUST
24. PLUMBING/STORM SEWER
H C B MECHANICAL
13215 WEIMAN
HOUSTON, 77041
713-983-0500
FAX 713-983-0555
CONTACT, JIM/TEMPLE
25. ELECTRICAL
MITCHELL ELECTRIC
12722 GALVESTON ROAD/HWY 3
HOUSTON, 77598
281-480-0388
FAX 281-486-7461
CONTACT, ROBERT MITCHELL
26. H V A C
LAKEWOOD MECHANICAL
3748 DOVER STREET
HOUSTON. 77087
713-644-7744
FAX 713-644-1800
CONTACT, MARK STRICKLER
20. CARPET & RESILIENT BASE
NATIONS FLOORING SERVICE, INC.
710 EAST HIGHWAY 6
ALVIN. 775 II
281-331-3742
FAX 281-331-4280
CONTACT, RANDY
21. PAINTING
R HASSELL BUILDERS, INC.
POBOX 690767
HOUSTON, 77269
281-586-0565
FAX 281-893-6053
CONTACT,
07/03/99 SAT 13:12 FAX ~
TEXAS GENERAL SE.C~S
III 001
PREVAILING WAGE RATE DETERMINATION
BUILDING CONSTRUCTION TRADES
COUNTY NAME: HARRIS
Date Printed: April 16, 1997
CLASSIFICAnON Rate Health PensIon Vaoation Total Wage
ASSESTOS WORKER $9.00 $0.00 $0.00 $0.00 $9.00
CARPENTER $16.23 $2.15 $1.17 $0.00 $19.56
CARPET LA YERIFLOORING INSTALLER $8.00 $0.00 $0.00 $0.00 $8.00
CONCRETE FINISHER $10.00 $0.05 $0.25 $0.04 $10.34
DATA COMMUNICATIONlTELECOM INSTALLER $11.99 $0.18 $0.00 $0.06 $12.23
DRYWALL INSTAUERlCEILlNG INSTALLER $11.00 $0.00 $0.00 $0.00 '11.00
ELECTRICIAN $13.27 $0.79 $0.27 $0.41 $14.75
ELEVATOR MECHANIC $18.02 $3.85 $2.19 $1.50 $25.56
FIRE PROOFING INSTALLER $11.00 $0.00 $0.00 $0.00 $1 1 .00
GLAZIER - $0.79 $0.00 $0.72
$12.53 $14.04
HEAVY EQUIPMENT OPERATOR $13.48 $0.14 $0.16 $0.02 $13.79
!NSULA TOR $15.78 $3.0El $1.84 $1.00 $21.48
IRON WORKER $13.37 $0.00 $0.00 $0.00 $13.37
LABORERIHELPER $8.12 $0.32 $0.07 $0.06 S8.58
LATHE~LASTERER $15.10 $2.12 $1.00 $0.00 $18.22
liGHT eQUIPMENT OPERATOR $11.46 $0.30 $0.35 $0.02 $12.13
MASON $14.55 $0.48 $0.24 $0.00 $15.27
METAL BUILDING ASSEMBLER $10.00 $0.00 $0.00 $0.00 $10.00
MILLWRIGHT $15.91 $1.63 $1.00 $0.00 $18.54
PAINTERlWALL COVERING INSTALLER $11.83 $0.87 $0.43 $0.18 $13.10
PIPEFITTER $18.38 $3.25 $2.06 $0.00 $23.69
PLUMBER $19.33 $2.40 $1.45 $0.54 $23.72
ROOFER $10.00 SO.oo $0.00 $0.00 $10.00
SHEET METAL WOAKER $14.56 $1.19 $0.62 $0.14 $16.52
SPRINKLER FITTER $18.25 $3.40 $2.24 $0.00 $23.89
TERRAZZO WORKER $0.00 SO.OO SO.OO SO.OO SO.OO
TILE SETTER $10.00 $0.00 $0.00 $0.00 $10.00
WATERPROOFE~CAULKER $11.52 $0.00 $0.00 $0.00 $11.52
.
SO.OO In the rate field Indicates Insufficient data was received to determine a prevailing wage rate for
this classification. Govemment Code Title 10, Section 2258.029, paragraph C states: · A contractor
or subcontractor does not violate this section if a pUblic body awarding a contract does not determine
the prevailing wage rates and specify the rates In the contract as provided in Section 2258.022:
Property Clf General ServlcltS Commls8lon
Based on 1996 SUNey Results
07/03/99 SAT 13:12 FAX ~ ,
TEIA~ GENERAL SWCES
1aJ002
Gener-al Services Commission
1711 San lKinto - P.O. Box 1;J047
AUlitin. Texas 78711-3047 \
Web Site: www.gsC..5lale.ll(.us
(S (2) 463.3035
Pertinent Information to All Public Entities Using Prevailing Wage Rate Deterniinations
Produced by the General Services Commission
1. The contracting entity awarding any contract for non-federally funded, public works constnJctIon projects
(regardless of size or dollar value) shall include in bid specification documents and contract documents a
prevailing wage rate determination of per diem wages for the locality in which the work is to be performed,
. for each craft or type of workman or mechanic needed to execute the contract. The Prevailing Wage Rate
Determination is defined as (1) the Prevailing Wage Rate Detennlnatlon Information sheet (documenl
.' nUmbi!r WR1001), (2) the Prevailing Wage Rate Determination for Building Construction Trades, and (3)
the Department of Labor (DOL) Heavy Highway Determination. The DOL Heavy Highway rates are to be
p~d to workers engaged In sile work detennlned to be fIVe (5) feet beyond the building, extending to the
property boundary. '
2. It shall be the responsibility of the contracting entity to ensure that the General Contractor posts the
applicnble Prevailing Wage Rate Detennlnation in a prominent. ~ accessible place al the work site.
3. It shall be the responsibility of the contracting entity to ensure that nolless than the posted, sp~cjfied ratos
are paid to all classifications of workmen, mechanics and laborers employed by the General Contractor
and/or Subcontractors, In the execution of their contract with the contracting entlly, and to ensure that all
workers fit Into one of the listed worker classifications for work of a similar character. For example,
welders are to be paid the rate of pay for the trade they are working for.
4. It shall be the responsibility of the contracting entity to take cognlnnce of wage rate disputes andlor
compluints of all violations of the provisions of Chapter 2258 Texas Government Code Tille 10.
5. It shall be the responsibility of the contracting entity to address the issue of fringe benefits in the bid
specification documents and contract documents. The Prevailing Wage Rate Deteonlnatfons produced by
the General Services Commission include fringe benefits in the total Wages. The bid specfflcation
documents and cxmtract documents need to specify whether the contracting entity Is requiring that fringe
benefi!s be paid.
6. It shall be the responsIbility of the contracting entity to address the Issue of the use of apprentices and
their payment rate In the bid specification documents and contract documents. The rales specified in the
Prevailing Wage Rate Detennlnatlon produced by the General Services CommIssion are Journeyman
rates. Historically, the apprentice rate Is commensurate with the experience and skill of the workor. For
example, on GSe projects, apprentices are paid at a rate of not more than 60% of the journeyman's wage.
Also on GSC projects, at no time shall a journeyman supervise more than one (1) apprentice.
Note: The terms joumoyman and apprentice apply to both union and Independent workers, and are not
Intended to imply that these positions are union workers only.
1. Some Prevailing Wage Rate Detannlnatlons for Building Cons(ruction Trades may Indicate $0.00 in the
-Total Wage- column, rather than a dollar amount. In such cases, The General Services CommIssion did
not reCc~ive sufficient survey data to tabulate a prevailing wage for this worker classification, In the
specified area, and can not provide a prevailing wage rate for this classification. Where this occurs, .
General Contractors and Subcontractors shall not be bound 10 a prevailing wage rale for the clss:Jlflcatlon
in question. .
WR10l.0 MltdI ,,,.
~ . ............
..__,^""""""""'c_
01/03/99 SAT 13:13 FAX ~
~s GE~L S1jCES
iJ003
General Services Commission
J711 San Jacinta - P.o. BOle 1~047
Auslln. TexIS 7871 J -3047
Web Sile: www.gsc.statC.IX.U5
(5 (2) 463-30),5
"
f',
Prevailing Wage Rate Determination Information
The following information ftOm Chapter 2258 Texas Government Code ntle 10 should be included in your bid
specificallon documents and contract documents:
2258.021. Duty of Governmental Entity to Pay Prevailing Wage Rates
(a) The state or any polJtl~r subdivision of the state shall pay a worker employed by It or on behalf of It:
(1) not ress than the general prevailing rate of per diem wages for work of a similar character in the
locality in which the work Is pelfonned; and
(2) nat ress than the general prevafllng rate of per diem wages for regal holiday and overtime work.
(bJ Subsection (a) does not apply to maintenance work.
(c) A worker Is employed on a public work for the purposes of this section If the worker Is employed by a
contractor or subcontractor In the execution of a contract for the public work with the state, a political
suhdlvlslon of the state, or any officer or public bOdy of th~ state or a political subdivision of the state.
2258.023. Prevailing Wage Rates to be Paid by Contractor and Subcontractor; Penalty
(a) The contractor who is awarded a contract by a public body or a subcontractor of the contractor shall
pa)' not less than the rates determIned under Section 2258.022 to a worker' employed by it in the
execution of the contract.
(b) A contractor or subcontractor who violates this section shall pay to the state or a political subdivision of
tho state on whose behalf the contract is made, $60 for each worker employed for each calendar day
or part of the 'day that the worker Is paid less than the wage rates stipulated In the contract. A pUblic
body awarding a contract shall specify this penalty in the contract.
Note: This penalty applies even if the oontractor or subcontractor and the worker come to an
agmement on the underpaid wages (see Attorney General Opinion DM-469).
ec) A contractor or subcontractor does not violate this section if a pUblic body awardIng a contract does not
detennlne the prevafflng wage rates and specify the rates In the oontract as provfded by Section
2258.022. .
Cd) 111e pUbUc body shan use any money collected under this sectlon to offset the costs incurred in the
administration of this chapter.
(e) A municipality Is entiUed to collect a penalty under this section only if the municipality has a population
of more than 10.000.
2258.051. Duty of PUbllo Body to Hear Complaints and Withhold Payment
(a) A public body awardtng a contract. and an agent or officer of the public body, shaff:
(1) take cognizance of complaints of all violations of this chapter: committed in tho execution of the
contract; and
(:2) withhold money forfeited or required to be withheld under this chapter from the payments to the
contractor under the contract, except that the public body may not withhold money from other
than the tlnal payment without detennination by the public body that there Is good causa to
belleve that the contractor has violated this chapter.
WRIOOI MudlIIlDI
a -c,...,,.. "'-vI''''___
...."....,~l1'~
07/03/99 SAT 13:13 FAX 4It
~~ GE~RAL ~.CES
I4J 004
Asbestos Worker WOrker who removes al'ld disposes of asbestos ma~Qrials.
Carpenter Worker who ~uilds wood structures, or structures of any material which has
replaoc~ wood. Includes rough and. finish carpentry, hardware and trim.
Carpet LaycrlFlooring Inslaller Worker who lns~lls carpet andlor fl60r coverings. vinyf til~.
Concrete Finisher Worker who floats, trowels, and finishes concrete.
Data CommunJcatlonlTelecom Instnl/er Workor who installs datallelephone and tolevision cable and associated
equipment and accessories.
Drywall In:.taller/Ceiling Installer Worf<er who installs metal framed walls and ceilings, drywall coverings, ceiling
grids and ceifings. :
Electrician . Sldlled oraftsman who Installs or repairs electrical wiring and devices. Includes
fire alarm systems, and HV AC electrical controls.
Elevator Mechanic Craftsman skilled In the Installation and maintenance of elevators.
Fire Proofing Installer Worker who sprayS or applies fite pl'OOfing materials.
Glazier Worker who Installs glass, glazing and glass framing.
Heavy Equipment Operator Includ~ but not 6mited to all Cat tractors, afJ derrfck..powered. all power operated
cranes, back hoe, back filler, power operated shovel, wfnch truck, all trenching
. machines.
Insulator Worker who applies, sprays, or installs insulation.
Iron Worker Skilled craftsman who erects structural steel framing and installs structural
concrete Rebar.
l.8bol'8rlHelper Worker qualified for only unskilled or semi-skilled work. Uftlng, canyfng materials
and tool!;, hauling, digging, clean-up.
latherlPlaslerer Worker who installs mOlal framing and lath. Worker WhO appnes plastor 10 lathing
and inst.dls associated accessories.
Ught Equlpmenl Operator InclUdl)$ but not limited 10 air compressors, truck crane drivor, flex plane, building
elevator, form grader, concrete mixer (less than 14 01), conveyor.
Mason Craftsman who works with masonry products, stone, brick, block. or any material
substituting for those materials and accessories. '
Metal 8UlIcfrog Assembler Worf<er who assembles pre-made metal bundlngs.
Millwright Mechanic specfaflzlng In the installation of heavy machinery, cxmveyanoe,
wrenches, clock levelers, hydraulic lifts and alfgn pumps.
PaJnterlWall Covering Installer Worl<or who prepares wall surfaces and applies palr.:t and/or wan coverings. tape
and bedding.
Piperltter TlllIned'Worker who InstallS pipIng systems. chilled water piping and hot water
(boiler) piping, pneumatic tUbing controls, ohfllers, boilers, and associated
mec:hanlcal equipment
Plumber Skilled craftsman who Instafls domestlo hot and cold water piping, waste piping,
storm system piping. waler closels, sinks, urinals and related work.
Roofer Worker who installs roofing materials, Bltuman (asphalt and cofd tar), felts,
llashings, all types roofing membranes and associated products.
Sheet Metal Worker Worker ;"0 Installs sheel metal products. Roof metal, flashings, and curbs,
ductwork, mechanical equipment. and associated metals.
Sprinlder Fltte( Worker who Installs fire sprinkler systems and nre protection equipment.
Terrazzo Wor1<er Craftsman who places and finishes Terrazzo.
"ire Settor Worker who prepares wall and/or floor surfaces and applies ceram~c tiles to thClsCI
surfaces.
Waterproofer/Caulker Worker who applios wate.. proofing material to buildings. Producl$ Include h
sea/ant, c.lulk, sMet mombrane, liquid membranes, sprayed. rolled, or I.)lUS ed
on.
.
. Worker Classification Definition Sheet
BID TABULATION
LA PORTE COMMUNITY LIBRARY
CITY OF LA PORTE, TEXAS
HALUBARNUM ARCHITECTS PROJECT NO. 9902
BID OPENING: MARCH 28, 2000
/
TOTAL.e
ALT NO.2
ALT. NO.1
BASE BID
BID BOND DAYS
BID FORM
BIDDER
2,591,900
216,700
19,200
2,356,000
365
yes
yes.
INC.
R. HASSEll BUilDERS,
1
2,775,500
214,500
17,000
2,544,000
300
yes
yes
COMEX CORPORATION
2
2,778,000
214,000
18,000
2,546,000
yes
2.824.300
216.90q
216.000
16,400
000
2.591
300
285
2,858,400
17.400
2.625.000
2.947.000 e
2.911.500
301.000
14.000
2.632.000
365
215.000
16.500
2.680,000
240
2,957,200
3,015,202
219.700
233.950
18.500
19.299
2,719.000
,953
2,761
390
yes
yes
yes
yes
yes
yes
yes
3 FROST CONSTRUCTIONS, INC.
yes
GASKEY CONSTRUCTION
4
yes
DUROTECH, INC.
5
yes
6 PAISAN CONSTRUCTION
yes
COMMODORE CONSTRUCTION
7
yes
yes
ALLIANCE CONSTRUCTION
HULL & HULL CONSTRUCTION
8
9
BID TABULATION
LA PORTE COMMUNITY LIBRARY
CITY OF LA PORTE, TEXAS
HALUBARNUM ARCHITECTS PROJECT NO. 9902
BID OPENING: MARCH 28, 2000
e
e
TOTAL
2,591,900
2,775,500
2,778,000
2,824,300
2,858,400
2,947,000
2,911,500
2,957,200
3,015,202
ALl NO.2
ALT. NO.1
BASE BID
BID FORM BID BOND DAYS
BIDDER
216,700
214.500
214,000
19,200
2.356,000
365
yes
yes
R. HASSELL BUILDERS. INC.
1
'7.000
2.544.000
300
yes
yes
COMEX CORPORATION
2
18.000
2.546.000
yes
yes
FROST CONSTRUCTIONS. INC.
3
216,900
16,400
2,591,000
300
yes
yes
GASKEY CONSTRUCTION
4
216,000
301,OO~
l'
215,000
17,400
2,625,000
285
yes
yes
DUROTECH. INC
5
14,000
2,632,000
365
yes
yes
.1 .
yes
PAISAN CONSTRUCTION
6
16,500
2,680,000
240
yes
COMMODORE CONSTRUCTION
7
219,700
.
233,950
18,500
19,299
2,719,000
2,761,953
390
yes
yes
yes
yes
ALLIANCE CONSTRUCTION
HULL & HULL CONSTRUCTION
8
9
e
e
PREQUALIFIED CONTRACfoRs/BmDERS FOR
CONSTRUCI'ION OF CITY OF LA PORTE COMMUNITY LmRARY
. ,
PRE-Bm CONFERENCE, TuESDAY, MARCH 21,2000
SIGN IN SHEET
1. Alliance Construction
2. Coma: Corporation
3. eommodore Construction eorporation
4. Durotech, Inc.
s. Frost Constructors, Ine.
6. Gaskey Construction Corporation
7. R. Hassell Builders, Ine.
8. Hun & Hull Construction
9. Jordan eonstruction
10. Moore & Moore General Contractors
11. Paisan eonstruction eompany
12. R.T.G~ Building Company
~{tWlia/l\ Gt fa. c:.e... .
~,.. u/1Ih Itt~
cD;IJ\L I A:a ~L.M.<<:7L--
JDHN
Be~es
S IJ)HE$H I<.AI<O])'I<.AR.-
.scoi\ t! tJ..:J W 1A-J
,
J4~ ~I~
. . (} ()) &,/~ ISP(
~Ic...~ ttlJC-c...- q Co~ ~.s.
~L. -7 ~!-
R.OM ~oo leE
rutjt i fJL
e
e
PREQUALlFIED CONTRACfORSIBIDDERS FOR
CONSTRUCfION OF CITY OF LA PORTE COMMUNITY LIBRARY
Bms DUE TuESDAY, MARCH 28, 2000 AT 2:00 P.M.
1. Alliance Construction 9. Jordan eonstruction
P.O. Box 7886 1509 Emerald Parkway, Suite 105
The Woodlands, Texas 77387-7886 -- College Station, Texas 77845
281-367-0091 281-367-0092 fax 409-696-0500 409-696-0601 fax
2. eomex Corporation 10. Moore & Moore General Contractors
P. O. Box 862 P. O. Box 1517
Deer Park, Texas 77536 La Porte, Texas 77572-1517
281-479-2322 281-479-2069 fax 281-471-0145 281-471-0601 fax
3. Commodore Construction Corporation 11. Pais an Construction Company
55 Lyerly, Suite 100 6343 Skyline
Houston, Texas 77022 Houston, Texas 77057
713-694-9371 713-694-0714 fax 713-974-3500 713-974-1724 fa."
4. Durotech, Inc. U. R.T.G. Building eompany
11931 Wickchester, Suite 300 P. O. Box 0753
Houston, Texas 77043 Seabrook, Texas 77586
281-558-6892 281-496-5637 fax 2~1-838-1113 281-838-1003 fax
s. Frost eonstructors, Inc. PLAN HOLDERS
8810 Will Clayton Parkway, Suite C 1. Associated General 'Contractors
Humble, Texas 77338 3825 Dacoma
281-446-6522 281-446-0552 fax Houston, Texas 77092
713-843-3700 713-843-3701 fa"
6. Gaskey eonstruction eorpor:ation
11422 Craighead z. Dodge Reports
Houston, Texas 77025 3131 Eastside
713-349-0080 713-349-0090 fa" Houston, Texas 77098
713-529-4895 713-524-7639 fax
7. R. Hassell Builders, Inc.
P. O. Box 690767 3. Association of Minority Contractors of
Houston, Texas 77269-0767 Houston, Tnc.
281-586-0565 281-893-6053 fax 55 lOW. Ridgecreek Drive, Suite G
Houston, Texas 77053
281-835-5278 281-835-4628 fax
8. Hull & Hull Construction
2223 Kelley 4. Construction Market Data Plan Room
Houston, Texas 77026 10900 N.W. Freeway, Suite 124
713-699-2577 713-699-2581 fax Houston, Texas 77092
713-263-8214 713-263-821 S fax
e
e
OWNER
ARCmTECT
CONTRACTOR
FIELD
OTHER
[.~ l
[xl
[xl
[ l
[ l
Change Order
AlA Document G701 -
Electronic Format
THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS
COMPLETION OR MODIFICATION. AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AlA DOCUMENT MAY BE MADE BY USING AlA
DOCUMENT 0401.
PROJECT:
(name, address)
La Porte Community Librarv
600 South Broadwav
La Porte. Texas 77571
TO CONTRACTOR;
CHANGE ORDER NUMBER: Ql
DATE: 6-12-2000
ARCmTECT'S PROJECT NO: nla
CONTRACT DATE: 20 Aoril2000
(name, address)
R Hassell Builders. Inc CONTRACT FOR: New Library Building
P.O. Box 690767
Houston. Texas 77269-0767
The Contract is changed as follows:
Add to Change Structural Deck Profile from 1.5F 22 Ga. To 1.5B 22 Ga. G90 to meet F.M. SDec'S.
Not valid until signed by the Owner, Architect and Contractor.
The original (Contract Sum) (Guaranteed maximum Price) was
Net change by previously authorized Change Orders
The (Contract Sum) (Guaranteed Maximum Price) prior to this Change Order was
The (Contract Sum) (Guaranteed Maximum Price) will be (increased) (decreased)
(unchanged) by this Change Order in the amount of
The new (Contract Sum) (Guaranteed Maximum Price) including this Change Order will be
The Contract Time will be (increased) (decreased) (unchanged) by zero (Q) days.
The Date of Substantial Completion as of the date of this Change Order therefore is unchanged
NOTE: This summary does not reflect changes in the Contract Sum, Contract Time or Guaranteed maximum Price which have
been authorized by Construction Change Directive.
$ 2.591.900.00
$ 0.00
$ 2.591.900.00
$ 1.104.00
$ 2.593.004.00
OWNER
City of La Porte
ARCIDTECT
HalllBarnum Architects. Inc.
CONTRACTOR
R Hassell Builders. Inc.
BY:
DATE: 6-12-00
AlA DOCUMENT G701 . CHANGE ORDER. 1987 EDITION. AlA . COPYRIGHT 1987. THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK
AVENUE, N.W., WASHINGTON, D.C., 20006-5292. WARNING: Unlicensed photocopying violates U.S. copyright laws and is subjeclto legal prosecution. This
document was electronically produced with permission of the AlA and can be reproduced without violation until the date of expiration as noted below.
. Electronic Format - G701-1987
User Document: G701.CON -- 6/1212000. AlA License Number 105382, which expires on 7/612000 -- Page #1
e
e
R. HASSELL BUILDERS, INC.
....................................................................................................................11......................................................................................................................
P.O. Box 690767
Houston, Texas 77269'
281-586-0565
Fax 281-893-6053
June 12,2000
La Porte Community Library
Change Order #01 Cost Breakdown
1. Add to Change Structural Decking from I.5F 22Ga. To 1.5B 22 Ga. G90 to meet
Factory Mutual Spec's.:
Henderson Fabrication:
RHBI 5% Overhead:
RHBI 10% Fee:
Total Change #01:
$ 960.00
$48.00
$96.00
$1,104.00
.
e
REC"-- ...,. -..;-::;:..;'.::-.:.-
k:~ it ..~~ ~ ~~. ~.L-j
HENDERSON FABRICATION, INC.
MAY 3 0 2000
BY:
Reauest For Change Order
To: R. Hassell Builders, Inc.
Houston. TX
Date: May 26, 2000
Attn: Terry Tauriello
Re: La Porte Community Library
Job No. 0200
Change Deck Profile From 1.5F 22 Ga. G90 To 1.58 22 Ga. G90
Add: $960.00
Please send documentation indicating your acceptance.
Respectfully,
JpJl~
Lloyd H. Henderson
President
3107 Nichols Ave. P.O. Box 659 Bay City, TX 77404 (979) 245-5350
hendfab@WCnet.net
Fax (979) 245-5000