Loading...
HomeMy WebLinkAbout2000-01 CITY WIDE SIDEWALK REPAIR AND REPLACEMENT PROJECT_2000-4501REQUEST FOR CITY Agenda Date Requested: Ma 8 2001 Requested By: Dou Kneu er Department:_ Planning Report: _Resolution: Ordinance: X Exhibits: Ordinance Bid Tabulation Bidder's List COUNCIL AGENDA ITEM Aooronrfation Source of Funds: General CD' Fund Account Number: 015-9892-709-1100 Amount Budgeted: S40.000.00 Amount Requested: _ S27 935.60 Budgeted Item: ES NO Z l5� OF Z06,cr/or1 S - CC. C. SUMMARY & RECOMMENDATION As part of the PY 00-01 Budget for Capital Improvement Projects, City Council approved $40,000.00 for Sidewalk Replacement Project. This project consists of removing and replacing badly deteriorated sidewalks, and addition of new wheel chair ramps. Design and engineering were performed on this project utilizing City Staff. On April 30, 2001, the City received bids from five qualified contractors. Brooks Concrete, Inc. of Pasadena, Texas submitted the lowest bid in the amount of $ 26,605.60. Contract time for completion shall be 90 consecutive calendar days after "Notice to Proceed" is issued. Staff has reviewed the bid as submitted and determined that it is a reasonable amount and Brooks Concrete, Inc. is qualified to perform this work. Staff recommends that the City Council authorize the City Manager to execute a contract with Brooks Concrete, Inc. in the amount of $26,605.60 and further authorize $1,330.00 (5%) contingency for the City -Wide Sidewalk Replacement Project. Action Required by Council: Consider approving an ordinance authorizing the City Manager to execute a contract with Brooks Concrete, Inc. in the amount of $26,605.60 and further authorizing $1,330.00 contingency for the City -Wide Sidewalk Replacement Project. Approved for City Council A ends T. Robert T. Herrera,•City Manager Date . ORDINANCE NO. 2001- WO AN ORDINANCE APPROVING AND AUTHORIZING A CONTRACT BETWEEN THE CITY OF LA PORTE AND BROOKS CONCRETE, INC. FOR THE CITY-WIDE SIDEWALK REPLACEMENT PROJECT; APPROPRIATING $ 279935.60 TO FUND SAID CONTRACT; MAKING VARIOUS FINDINGS AND PROVISIONS RELATING TO THE SUBJECT; FINDING COMPLIANCE WITH THE OPEN MEETINGS LAW; PROVIDING AN EFFECTIVE DATE HEREOF. BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF LA PORTE: Section 1. The City Council hereby approves and authorizes the contract, agreement, or other undertaking described in the title of this ordinance, in substantially the form as shown in the document which is attached hereto and incorporated herein by this reference. The City Manager is hereby authorized to execute such document and all related documents on behalf of the City of La Porte. The City Secretary is hereby authorized to attest to all such signatures and to affix the seal of the City to all such documents. City Council appropriates the sum of $27,935.60 from Capital Improvement Fund 015 to fund said contract. Section 2. The City Council officially finds, determines, recites, and declares that a sufficient written notice of the date, hour, place and subject of this meeting of the City Council was posted at a place convenient to the public at the City Hall of the City for the time required by law preceding this meeting, as required by the Open Meetings Law, Chapter 551, Texas Government Code; and that this meeting has been ORDINANCE NO. 2001-�4Ro open to the public as required by law at all times during which this ordinance and the subject matter thereof has been discussed, considered and formally acted upon. The City Council further ratifies, approves and confirms such written notice and the contents and posting thereof. Section 3. This Ordinance shall be effective from and after its passage and approval, and it is so ordered. PASSED AND APPROVED, this May 8, 2001. CITY OF LA PORTE By: /ftrmari L.-Malone-1 Mayor ATTEST: MarthaGillett, City Secretary APPROVED: 7� Knox W. Asldns, City Attorney r CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT #2000-4501 La Porte-Bayshore Chamber of Commerce FAX: 281471-1710 Brooks Concrete, Inc. 4018 Allen -Genoa Pasadena, TX 77504 PHONE: 713-947-8440 FAX: 713-947-9444 Adverb The Bayshore Sun -April 11 & April 18's 2001 Bid Notice Fared Bill McDonald Construction, Inc. 702 Underwood Road Deer Park, TX 77536 PHONE: 281479-3030 FAX: 281-474-4337 Conrad Construction Company PO Box 841134 Houston, TX 77284 PHONE: 713-937-3081 FAX: 713-937-1172 David Wight Construction Company Derk Harmsen Construction 4300 Mandale 2820 Center Street Alvin. TX 77511 Deer Park, TX 77536 PHONE: 281-331-1584 PHONE: 281-479-3400 FAX: 1-281-5854640 FAX: 281-478-5115 FORCE Corporation PO Box 1079 La Porte, TX 77572-1079 PHONE: 281-170-0550 FAX: 281-471-9627 C&D Constructors, Inc. PO Box 23264 Houston, TX 77028 PHONE: 281-442-2468 FAX: 281-442-2415 Purtis Construction 14710 Park Alameda Houston, TX 77047 PHONE: 281-433-1012 FAX: 281-433-1018 Brooks Concrete, Inc. 4018 Allen -Genoa Pasadena TX 77504 PHONE: 713-947-8446 FAX: 713-947-8444 Southern Customs 9219 Katy Freeway Houston. Texas 77024 PHONE 713-682-8807 FAX: 281-471-1710 SER Construction, Inc. 2500 Cit)-west Blvd., Ste. 1700 Houston, TX 77042 PHONE: 713-278-9890 FAX: 713-278-9892 Bluebonnet Stroder Co. 908 Perla Rd. Pasadena TX 77502 PHONE: 713-9414804 FAX: 713-9414887 Allcon Builders it Constructors PO Box 40 LaPorte, TX 77571 PHONE: 281-7254106 FAX: 281-540-0174 Follis Construction 11 I N. Broadwav La Porte, TX 77571 PHONE: 281471-6881 FAX: 281-471.6038 Jesse Vega Construction Co. 2019 Pasadena Blvd. Pasadena TX 77502 PHONE: 713473-1552 FAX: 713473-1848 Moore & Moore General Contractors Park Constructors PO Box 1517 PO Box 986 La Porte, TX 77572-1517 Rosenberg, TX 77471 PHONE: 281471-0145 PHONE: 281-342-0031 FAX: 281-471-0601 FAX: 281-342-8967 Curb Planet, Inc 1050-2 Edgebrook Houston, TX 77034 PHONE: 713-944-9119 FAX: 713-944-1006 Steven R. Hill Construction 7782 Hammerly Houston, TX ' 77055-1748 PHONE: 713-956-5861 FAX: 713-956-5817 Contractors that Picked up Plans & Specifications Follis Construction ill N. Broadway La Porte, TX 77571 PHONE: 281471-6881 FAX: 281-471.6038 Bill McDonald Construction. Inc. 702 Underwood Road Deer Park, TX 77536 PHONE: 281479-3030 FAX: 281-4794337 Curb Planet, Inc 1050-2 Edgebrook Houston, TX 77034 PHONE: 713-944-9119 FAX: 713-944-1006 Bluebonnet Stroder Co. 908 Perla Rd. Pasadena, TX 77502 PHONE: 713-9414804 FAX: 713-9414887 C&D Constructors, Inc. PO Box 23264 Houston, TX 77028 PHONE: 281-442-2468 FAX: 281-442-2415 Ideal Construction Services PO Box 2915 Sugar Land, TX 77487 PHONE: 281470-0531 FAX: 281470-0539 D.L. Davidson 19728 Saums rd Houston, TX 77084 PHONE: 281-646-0770 FAX: 281-646-7047 CITY OF LA PORTE CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY-2000/2001 CLP PROJECT #2000-4501 BID OPENING APRIL 30, 2001 2:00 P.M. BID TABULATION CONTRACTOR NAME T7 BID DAYS TO BASE BID BOND COMPLETE BROOKS CONCRETE INC CHECK 90 $ 26,605.60 IDEAL CONSTRUCTION SERVICES Y 30 $ 34,959.15 CURB PLANET Y 120 $ 57,141.00_ BILL McDONALD CONSTRUCTION Y 120 $ 60,617.60 SOUTHERN CUSTOMS INC Y 120 $ 99,620.80 P Due to the volume of this contract, a copy is available for your review in the City Secretary's Office CITY OF LA PORTE CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY-2000/2001 CLP PROJECT #2000-4501 BID OPENING APRIL 30, 20012:00 P.M. BID TABULATION CONTRACTOR NAME BID DAYS TO BASE BID BOND COMPLETE ol Cuje6 fL►9IVEr lzo 71`-l•oD 1V!c 6b N,4&i3 ca N ST- �Z o 60 6 3 7. 6 a IOfA•G coNS7 x 0 Minutes for Pre -Bid Meeting CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP #2000-4501 held at 10: 00 am on April 23, 2001 City Council Chambers, City ojLa Porte Present: 1. Carlos Martinez 2. Reagan McPhail 31 �a✓va� 1°d�� - 6Eo/tGr onn&J 1 R uVr% ,�ICARPA J_ s�i� City of La Porte 281471-5020 281-471-7168 (FAX) City of La Porte 281-842-7046 Q IULiy ONNk� Sls�PAC^ i; �3 — 941-�lFdy :�.4 /.Syo .o C",5 e-17 OK 1,4 f 97E S,q VJ CuT /°JC1 OE,UTA 2— w.C_ le. >0T7-EniTianl To O>=7,4/L Zff/ - W179-30 3v c, 133 �14 4 �l l \ °% 7-St-476. of3/ Z8/ y1/-Pozi #,*VE Ta Ag c E7- /90 /'W 4E . 3- Ep-oSI000 fg-O-r£CTIo,.J AVT 4 r 2- 500 P5 T /C.BN C. (FLY f .5A/ o �0) ` 5_ d Ma7`t rl4l j 42N 4o9 7/O CN-t ' Oracfo l' move r Gi i S�oIS'ak PICK-UP LIST FOR PLANS AND SPECIFICATIONS City of La Porte Project Name: City -Wide Sidewalk Replacement City of La Porte Project Number: CLP #2000-4501 Pre -Bid Date: loam on April 23 2001 Bid Opening Date: 2pm on April 30, 2001 Bluebonnet Stroder Co. Davis Stroder 900 Perla Pasadena Tx 77505 713-941-4804 713-9414887 Fax ogd��s SAGS. 1-713 -:"46F L3 70 r Concrete Curb, Curb Inlets Concrete Structures Headwalls S ,Junction Boxes Ramiro Pedraza Jr. Office (713) 944A119 Mobile (713) 822-6713 - .Fax (713) 944-1006 -_qw Cew :Se�wiceo A Division ot_94d 'Futiak"- 9sa.. ` + TOMMY PITTS \� ` P.O. Box 2915; _ J - OHlce.; (28)) 470-0631 r Sugar Land. TX 77487-2915� ' _ Fox - (281) 470.0539- r- DOUGLAS L. DAVIDSON 1 President D. L. Davidson w Paving Contractors, Inc. Cell: (281) 610-6009 19728 Saums Rd., PMB 125 Office: (281) 646-0770 . Houston, TX 77084 Fax: (281) 646-7047 PICK-UP LIST FOR PLANS AND SPECIFICATIONS City of La Porte Project Name: City of La Porte Project Number: City -Wide Sidewalk Replacement CLP #2000-4501 Pre -Bid Date: loam on April 23 2001 Bid Opening Date: 2pm on April 30, 2001 IIII. aru�oowuo cosaTRucrai � General Contracts x CONCRETE PAVING I ' - AVKAL&T PAVING a REPAIR 1 METALLIC BUILDINGS I ROBERT GONZALES President 702 Underwood Road P.O. Box ISO Dow Park, Texas 77538 1281)47"030 FAX 479-4337 SEWER 4 WATER EXCAVATION REMODELING Follis Construction, Inc. Design/Build General Contractors Ph.(281) 471.6881 Fax (281) 471.6038 Harvey Ross AMN19MMI Design I II N. Broadway La Porte, TX 77571 Jarrles INlttner Slope Paving Construction Repairs liINvject Manager Asphalt Paving Concrete :60UTHERN CUSTOMS, INC. C & D Constructors, Inc. HoLa Katy Freeway. Suite 130 I P.O. xas 23264 77028 Alkh,Houston, Tx 77024 I � OustOn^, �Texa�sL�77028.77228 Phone: 713be2-880e sN. D..J•P..... c•..+r•. Fax 7134U4=7 CLAY L. MELENDEZ 1 Concrete Paving F„aB: rDu� Wxa.ner -I t 3-$06-IS 1-71 1s l -442 - LsFbB Classtieds... Continued From Page 6 NOTICE TO BIDDERS A.M. the Contract Documents. in Harris County, Texas, CLP Project 5. The City of La Porte according to the map or No.2000-4501 3. Interested contractors hereby notifies all bidders Plat thereof, recorded in - may obtain plans, specifi- that in regard to any _ Volume 7, Page 10 of the cation and necessary bid- Agreement entered into Map of Records of Harris 1. Sealed bids, in dupli- ding information at no cost pursuant to this advertise - County, Texas. Cate, on the original forms, from: ment, minority business signed by an officer of the enterprise will be afforded Company, and addressed equal opportunities to sub - The applicants are re- to Martha Gillett, City Sec- CITY OF LA PORTE mit bids in response to.this questing a variance to the retary, City of La Porte, PLANNING invitation and will not be Planning & Zoning ordi- 604 W. Fairmont Parkway, DEPARTMENT discriminated against on nances to subdivide the P.O. Box 1115, La Porte, 604 W. FAIRMONT the grounds .of race, color, property, into two lots, one Texas 77572,71115 will be PARKWAY sex, age, religion, or na- lot with frontage of 65 feet received until 2:00 P.M., LA PORTE, TEXAS tional origin in considera- and second lot with front- April 30, 2001, for the on- 77571 tion for an award. age of 66.19 feet. The first struction of: (281)471-5020 lot of 65 feet to adjoin Lot 29 x 6. The Owners reserve the CITY OF LAOT11i4.fa( h PROPOSA hall right to reject any and all 1.) Lot 65' X124.55' X 65' CITY-WIDE SIDEWAbecom nied b a bids and to waive informal- back of lot. REPLACEMENT ca ier's ch ck, ce ed ities in bidding. In case of FY 2000-2001 check, or bid and fro a ambiguity or lack of clear- PROJECT2.) Lot 66.19' X 124.55 X suty comp y licensVd ness in stating the prices 152.52' back of lot X in a State of exas in an in the bid, the Owner re- 150.29 side. amount not less than five serves the right to consid- 2. Bidders are requested percent (5%) of the total er the most advantageous City of Shoreacres to attend a pre -bid confer- amount bid, as guarantee construction thereof or to - Shari Tait ence to be held in the that the 4uccessful bidder reject the bid. City Secretary Council Chambers at City will enter into a Contract' Hall, 604 W. Fairmont and execute the Bond(s) if Parkway, La Porte, Texas, required, within ten (10) CITY OFi A PORTE April 23, 2001, at 10:00 days 'after the receipt of Martha Gillett SAYSHORE - medical Center Date: Wednesday, April 18, 2001 Time: 8:30AM-4:00PM Place: Pasadena Convention Center 7902 Fairmont Parkway Registration: 8:30AM . Keynote Address —Art Linkletter: 1100AM Lunch: 12:00 Noon (Tickets for lunch will be available to those attending the keynote address) Toody Byrd; 1:00PM Free health screenings, mini -seminars, information on healthy living, travel, pets, home safety, and many more topics of interest to seniors! RESERVATIONS ARE REQUIRED PLEASE CALL (713) 359-2527 = THE BAYSHORE SUN • WEDNESDAY, APRIL 11, 2001 • Page 7 • Baseballers Win 1=0f=3 The La Porte High School varsity For his effort, Allen was named times in the third as Justin Burney baseball team recorded one win in Player of the Week by The Houston blasted a bases -loaded triple to its last three games, the victory Chronicle. score what turned out to be the only coming over Pearland by a 2-1 mar- The Dogs followed that contest La Porte runs in the game, while gin in nine innings as Jeff'Allen with one on a Saturday at Clear Brook got four more in a 6-2 win. _ pitched all nine innings and allowed Brook, and after falling behind 2-0 Then came Clear Lake on the just one run while striking out nine. in the first the Dogs scored three road, and after the Dogs fell behind 1-0 in the first they tied it up in the third when Burney walked, got to second via a passed ball and scored k R r SFallon Tr o ac ec� Alan C 's two -out sin le. g In the fourth Nick Moreno singled The La Porte High School girls Bulldogs 4 x 400 team to be the first and later scored on a Michael track team warmed up for this to qualify for the very competitive Gonzalez double as La Porte took week's District 24-5A meet by run- Texas Relays finals, where they fin- the lead, and Allen was doing a fine ning two foursomes at the Texas ished seventh.. There were teams job on the hill until a single and Relays in Austin this past. weekend.. from California and Florida, and the homer in the fifth gave Lake a 3-2 The distance medley team of GiGi field also included last year's 5A lead, and another homer in the sixth Rohmfeld (1200 meters), Waymona and 4A champs. " made it 4-2. Scott (400 meters), Krystle Clement Next up is the 24-5A meet, with The Bulldogs tried to. rally in the - (800 meters) and Nicole Warren running prelims and the 3200 final top of the seventh and a Cody Ryan (mile) ran a school record 12:30.50, Tuesday, and most finals Thursday rbi single got La Porte to within one shattering the old. mark by 12 sec- at the Bulldog Stadium track. at 4-3 before the rally fizzled. onds. And Nicole's 5:08 in the mile portion was the best time at that dis- tance this year in this region. Also, the team of Scott, LeClaire "We're Making Room For You" Ebow, Kelley Parent and Renee 1. Rice ran a 3:54.51 in the prelims of • ' You Are Invited To the 4 x 400 relay to break the 1989 held by Veronica -_ - The Grand Opening Of Our school record - Cherry (Houston Baptist), Felicia Willis, Daphne Roscoe (Southern Methodist) and Carolina Ramirez _ 0 CHRISTIAN, LIFE CENTER (steph a F-me all). .The time allowed the -Lady. - Friday, Aril 27th through Sunda Aril 29th X p g Y� P Hesse Randy W. Hesse passed away Monday, April 9, 2001. He was born May 8, 1954 in Houston, and was a loving and devoted husband, father, son and brother. Hew was a 1972 graduate of Robert E. Lee High School in Baytown, and for the last 20 years resided in La Porte and worked in the T.H.F. Unit at the DuPont Plant here. An avid fisher- man, he loved the outdoors. A memorial service was to have been given by his aunt, the Rev. Anne P. Wiser, at 11 -a.m. Wednesday, April ill, 2001 at the Paul U. Lee -La Porte Chapel. In lieu of usual remembrances, a donation can be made in his name to the "Make A Wish Foundation" at 1604 Bissonnet, Houston, 77005. Preceded in death by brother Adam. Hesse, he was survived by his wife Kim Hesse and her daugh- ter, Kristen Salmon; son Dustin Hesse; daughter Randi Hesse; mother Jean Henson and her hus- band Lester; father Don Hesse; and sisters Kelly Norton and Donna Ludtke. Richard Linda Marie Richard, 53, of Morgan's Point, passed away April 7, 2001 in Pasadena. . Born in Texas City, she was a member of St. Mary's Catholic Church and a former member of the Legion of Mary, a C.C.E. teacher and past president of the Chatos- Booster Club. She was also an employee of Houston ISD for 23 years as director of the Textbook Department. Services were held Tuesday, April 10, 2001 at St. Mary's Catholic Church, officiated by Father Eric Pitre, with Knights of Columbus serving as pallbearers. Burial was at Grand View Cemetery under the direction of the Paul U. Lee -La Porte Funeral Home. Survivors include husband James Richard of Morgan's Point; son Jason Richard of Webster; daughter Amy Richard of League City; brother George Wyllie Jr. of La Marque, and granddaughter Natalie Richard. FIRST UNITED METHODIST CHURCH PASADENA We're closer than you think, located at 1062 Fairmont Parkway (corner of Fairmont & Strawberry) For more information call the church office @ 281-487-8787 Vait our website @ www.firstumcpasadena.org Clinic 402 W. Fairmont Pkwy., La Porte 281-471-6834 All Major Credit Cards Accepted MTWF - 746 • Thurr, - 7-7 • Saturday AppfS Available Pain Management • Nutrition* Rehabilitation 42 - 281 - 8 8880 Chiropractic has been proven to help alleviate pain associated with the following -conditions for auto accident injuries and worker's compensation injuries. • Low Back or Neck Pain • Auto Accident Injuries • Headache •Arm/Leg Numbness • Sciatica • Scoliosis • Muscle Spasm • Sports Injuries • Disc Problems • Shoulder Pain • Worker's Compensation Injuries 2611 Underwood Road, La Porte, Tx Mon., Tues., Thurs., 9am - 6pm; Friday 9am-1 pm We Are Located Next to Gringo's Restaraunt -- -, i Page S • THE 1SAYStlUKE SUN • WEDNESDAY, APRIL 11. 2001 19 o dp •�. PUPPY HEALTH PACKAGE CAT ANNUAL CHECKUP Office Call/Exam.............................. $30.00 Office Call/Exam ....................... $30.00 *00 Distemper/Parvo/Corona Immunizations.................................$20.00 Rabies Immunizations ...............$151.00 Feline Leukemia/Feline �6 • Fecal analysis for intestinal worms Distemper Immunization ........... $27.50 Fecal analysis for • Deworming for hookworms intestinal worms............ $ 8.50 and roundworms ............. ................ $15.00 Total. $81.00 1 month supply of Heartgdard Heartworm Preventative $ 3.00 All the above for only •� ................. $39 95* 1 month supply of 000 Advantage Flea Control .................. $12.50 T I• ta . $89.00 All the above for only • $39.95* 0000 If you have a litter, start them off right. Our litter discount starts with 10% off the above price for three puppies and goes • up to 50% off for 7 or more puppies. Call for details. DOG ANNUAL CHECKUP Office Call/Exam...........................$30.00 �* Rabies Immunizations ...................$15.00 Distemper/Parvo Immunizations...............................$12.50 •'•• Occult Heartworm Test (the best there is) .........................$20.00 Fecal analysis for Intestinal worms .............. $8.50 Total: $86.00 "'• All the above for only $49.95 - i +ei ..A °• *Additional products and services are extra. For example, if your pet has never - been to us AND you are not getting our vaccination package your pet must be ��• examined and there is a charge for this service. If your pet is not current on vacci- nations, they will be vaccinated at the owners expense. If your surgery patient is obese, pregnant, in heat, etc, there are additional charges. Optional extras for P,664 • surgery patients include presurgical blood work and post surgical pain relief. i • s• 281. 47-1,111111111111113232 No too re Because Of Our Prices Appointments Are Highly Recommended *Additional products and services are extra WILLARD D. JONES JR., DVM` QUIT., UNION '"Yotw C m mu»tty Credit Union" i aam ii njmwwv--q. n P. i THE BAYSHORE SUN • WEDNESDAY, APRIL 18, 2001 • Page 5 Saturday, April 21,2001 struction or: cashiers check, certified serves the right to consid- First United Methodist PUBLIC NOTICES check, or bid bond from a er the most advantageous Church of LaPorte, 9601 surety company licensed construction thereof or to Fairmont Parkway. Garage CITY LA PORTE in the State of Texas in an reject the bid. Sale 8a.m.-2p.m. Car CITY-WIDE SIDEWALK ID amount not less than five Wash 8.am.-2p.m.for BID NOTICE REPLACEMENT percent (5%) of the total Donations. Fish Fry PROJECT FY 2000-2001 amount bid, as guarantee 1la.m.-1p.m. $6/Dinner. that the successful bidder CITY OF LA PORTE 121 Boats LA PORTE LS.D. IS AC- will enter into a Contract and execute the Bond(s) if Martha Gillett 1994 TIDE CRAFT 90 HP CEPTING SEALED BIDS FOR THE PURCHASE OF 2. Bidders are requested required, within ten (10) Runs great. $4,500. 281- ATHLETIC TRAINING to attend a ore -bid confer- days after the receipt of 867-4481 pager 713-764- SUPPLIES #128, UNTIL ence to be held in the the Contract Documents. 1885. MAY 3, 2001 2:00 P.M. Council Chambers at City airCheaper than you think. CHEVRON FOOD MART Saturday, April 20th- 21st 123 Miscellaneous BIDS WILL BE OPEN AT 1002 SAN JACINTO ST., Hall, 604 W. Fairmont Parkway, La Porte, Texas, - - Always Guaranteed. Dwayne, 281-470-8267 y NOW HIRING. Full time/ Part time, 10736 West 8 a.m. No Early Birds. An- ti ues, clothes, ladies size q 15X30 OVAL SWIMMING LA PORTE TX. CALL April 23, 2001, at 10:00 5. The City of La Porte NOTICE TO THE PUBLIC "t103 Services anytime. Main. Call 281-842-1484. 8-10, lots of stuff. 10936 Pool, above ground, all ac- PURCHASING 281-604- A M hereby notifies all bidders HANDYMAN SERVICES EXPERIENCED DAY Thornwood, Fairmont cessories, new liner, 7062 FOR BID FORMS OR OTHER INFORMA- that in regard to any 1 Q INDEPENDENT PAINT- Ceilingfans, storm doors CARE Teachers needed. paw $1,200 or OBO. PION. Agreement entered into La Porte Venture, Ltd. !s AND SHEETROCK installed, fence repair or Full and part time posi- GARAGE SALE: SATUR- 281-471-2824 after 2 p.m. pursuant to this advertise making application for tax .,ING fefinishing. Water dam- replacement. General re- tions. 1310 Garth Rd., DAY, April 21st, 8 till ? 3 3. Interested contractors ment, minority business credits with the Texas De - aged sheetrock, settle- pairs. 281-451-9684. Baytown 281-422-0977. families, 3418 Brookwood, FOR SALE- MAGIC CHEF may obtain plans, specifi- enterprise will be afforded partment of Housing and inent cracks, holes, etc. All MIKE'S TREE SERVICE GENERAL LABORER Brookglen subdivision. Almond refrigerator. Good cation and necessary bid- equal opportunities to sub- Community Affairs for the `totally refinished, ALL Trimming, Topping remov- Needed. LaPorte area Washer, computer, etc... shape, 3 years old, $300. Tan loveseat, great shape, NOTICE TO BIDDERS din inf mat' n at o cost g mit bids in response to this invitation and will not be Churchill Place Senior Vil- lage, to be located at 1301 TEXTURES ARE MATCH ED. Cabinets stained and al. Lowest prices. 11 ears ex P St. disc. Insur $650/ hour and u 281- p 468-2715. GARAGE SALE: SATUR- $100. Call 281-479-8265. from: - discriminated against on Broadway, LaPorte, Har- refinished or prepped and Y . ed, StumpGrinding Same 9 HELP WANTED- BAY DAY, April 21st, 9a.m.-the 4 m. 10306 Belfast, Fair- p' O ; CLIP Project No. 2000-4501. grtxu�ds of race, color, sqx, age& religion, or na- ris County, Texas. This new development is a se - painted. Complete painting services. Quality work on- Da Service. Mike Henley, Y Y Forest Golf Coarse Club mont Park central (central), be- CITY OF LAP RTE PLANNING tidal,ilrigin in considers- Nor citizens fourplex com- ly, guaranteed. Member 713-477-4145. House. Ask for Tammy 281-471-9736. tween Farrington and Val- , � 1. Sealed bids, in dupli- DEPARTMENT bon ran award. munity comprised of 72 Better Business Bureau. Call 281-471-7982. T & L REMODELING - LOCAL TRUCKING COM- leybrook. cate, on the original forms, 604 W. FAIRMONT units which will target ten - ants with income less than Painting, sheetrock, car- PANY has a full time posi- GARAGE SALE: THURS- signed by an officer of the PARKWAY ' 60% (25 units) or 50% (36 AFFORDABLE DEPEND- ABLE Lawncare. We offer pentry, misc. jobs. Melvin 281-474-2316 quality work tion in the accounting dept. faxto 281- fax DAY 19th and Friday 20th 8a.m.-4p.m. Antique Wick- 308 Apartments Company, and addressed to Martha Gillett, City See- LA PORTE, TEXAS 77571 6. The Owners reserve the units) of the area's median full service Lawncare in- at a great price. Please resume Please er- Oak- misc. Depression TOWN APARTMENTS- retary, City of La Porte, (281)471-5020 right to reject any and all bids and to waive informal- income. The number of units and proposed rents eluding mowing, bagging, hedge trimming and edg- 104 Child Care PART TIME LABORER lass, craft supplies, 9 PP household, decor, and Furnished efficiencies and 604 W. Fairmont Parkway, P.O. Box 1115, La Porte, alias g bidding. In case of for the subjectproperty's I in with a as edger. Sat 9 9 9 guaranteed. Jim- CHILDCARE DAYS AND Part-time, Needed. $7/ hour. Must work on Sundays. 281- work on Christmas items. Bayou Villa Apartments 303001d one bedrooms some util!t- ies aid. No pets. One or P P Texas 77572,-1115 will be received until 2:00 P.M., 4. Each PROPOSAL shall ambiguity or lack of clear- 9 Y ness in stating the prices Continued On Page 6 -isfaction my Smith 281-471-1781 or Single Mom rates. Dependable 29 281-47. 0224 Hwy. 146, Garages 16-19 two people only. Inquire at April 30, 2001, for the con- be accompanied by a '•in the bid, the Owner re Dave Smith 281-471-1300. years Experience. POLICE COMMUNICA- south side. 121 South Iowa, apt. 4 or DRYWALL PAINTING- References. Drop -ins. PIONS OPERAe. R xas Parks & Wildlife. Relief IN HOUSE SALE PECAN 210 South Iowa, La Porte. One day service. Will fix 6:30 a.m.- 6 P•m• shift. No experience re- Plantation M.H.P. 3203 310 Houses any holes, cracks, etc. Fairmont East. 281-471 quired. High school grad Tara Place; Thursday y _ 7653. /GED. Contact Inez Tipp 19th, 26th, Friday 20th, LEASE/ PURCHASE 3-2 e 281-842-8100 EOE. 27th, 10a.m.-4p.m. for more information 713-903- double wide set up in nice park. Reasonable. 281- Handy Man Services 0 ' J 8371 930-8641. Specializing in: - • Exterior/Interior painting. 109 Help Needed I� MOVING SALE: EVERY- SMALL 3 ROOM HOUSE. Oth v" "I bl 118 Garage Sales THING must go!!!! Fumi- Fenced a d is er ser tees oval a e. • Wood Replacement • Doors • General Carpentry • Gutters -Fences Local resident with local references Contact Mike at 281-471-8960 y r , no pe , B.B.Q lure, appliances and washer and dryer connec- CHURCH BENEFISaturday 4/21/01, T/T/ 130 more!!! April 20th- 21st, tions, suitable for 1-2 8 a.m.- 4 p.m. 9810 Char- adults. Deposit required. South 4th St. Chicken mont. 281-471.1897. fajita plates $5, - clothes, MULTI- FAMILY GIGAN- shoes, toys, golf clubs, ba TIC garage sale 4/21/01, 8 313 Other by items, misc. a.m.-? 9822 Rustic Gate 932 SOUTH BROADWAY, GARAGE SALE- FRingY_ Rd. , Underwood and Fair- La Porte 24X30 Buildin r.' WANTED 9 mont Parkway. Many -Commercial Property - items, furniture, baby $500/ month, first and last items, clothes, nick-nacks, —STORAGE-- Delivery Driver months down plus $500 Mini -Warehouses with local print shop. bicycles, toys, beds, deposit.281-470-2708. desks. I 5x10..... $30 Per Month Must be dependable, TROOP 514 GARAGE THE 1200 BUILDING lo- I 10x10.... $50 Per Month with good driving Sale, Car Wash and Fish cated at Hwy. 146 and 1 Ox36...$110 Per Month record and excellent F Annual fund raiser, Fairmont Parkway has of- ry• face space for 40x36 w/ bath ... $400 Per Month People skills. available Christian owned lease. For more informa- I c 281-471-3682 Excellent job for a col- Health Food Store tion call Cindy at 281-471- Someone who is self-motivat- lege student) 8385. LA PORTE MINI -WAREHOUSE For more information ed, neat, clean & healthy habits, great personality, tom- 201 N. 3rd St., La Porte call 281-471-4552 attentive listener, service on- 321 West Main ented, Work 20-40 hrs (some 315 Lots for Sale Sundays) 1-7:00 "Very inter- ested in increasing your SHOREACRES: 60 ft. x knowledge in a growing residential lot l field" Love &help- Fairfield ! Warehouse Space — 1 200Sf with Office Space -- 35O Sf (Optional) 5; people ed on ed n less than than ing them._ Health food_ store half a block _from - Bay. experience helpful. Monday - Friday 8am-5pm Fairmont C I" St. in Central LaPorte * Great for Business or Storage "Resumes Only" 281-471-1234 ask for San- i (281)428-0671 / (713)818-0326 K's Divine Health dra. 4928 Fairmont Parkway 3 Immediate Opportunities ® Process Technicians La Porte, TX The Dow Chemical Company, a Fortune 500 company located in LaPorte, TX, has immedi- ate opportunities with an anticipated hiring date in June for men and women to fill Process Technician jobs. Certifications for Associates Degree in Process Technology are a plus. These positions require those selected to Work rotating shift. The starting hourly rate for these positions is approximately $18.00. Dow's La Porte facility produces a variety of chemical products, and is dedicated to safety, the environment and competitive manufacturing. Applications are only accepted by Langenhennig, Inc. Specialists in oil & gas and chemical plant hiring Follow steps 1 through 4 listed below to learn about these jobs & to apply via the Internet. Free Internet access is available at most state employment offices, local libraries and schools. 1. Go to the Internet address box at the upper left hand corner of your screen and enter I .,......, leer., FF ,.,...... It is faster and more reliable not to use a search engine. 2. Then, click on "Job Vacancies." 3. Search on "Job Number 506" and complete the Internet application. 4. The deadline to apply is April 30, 2001. All applicants must apply for this position to receive consideration - regardless of previous applications:, - For technical assistance, go to www.Lstaff.com and click on Typical Questions The Dow Chemical Company and Langenhennig are Equal Opportunity Employers Service Open Saturday 8-4 `99 MERCURY SABLE ..................... `00 FORD ESCORT .......................... `00 PONHU GRAND AM ............... `00 FORD TAURV 1198 FORD CROWN VICTORIA,,,.,,,.... `00 FORD WINDSTAR...................... 'All monthly prices includes factory rebates.' rebate?Explorer. 36 t Parts Open Saturday 84 17 Homes for Sale FAIRMONT PARK: MUST See 3-2-2 brick, oversized corner lot, detached ga- rage, both formals, den, fireplace, home warranty. Reduced $99,900. Skelton Realty 281-470-1245t HOME FOR SALE BY Owner. Fairmont Park East 3-2-2 Very nice with many extras. $82,500. 281-470-8056. LA PORTE BEAUTIFUL 4- 2 1/2- 2. 8 years old 2308 sq. ft. per HCAD $127,000 Contact Friday Booth 281-479-1414 Re - max First Source. 400 Autos for Sale `93 FORD VICTORIA V-8, power, excellent condition, maroon, 84K. Call 281- 471-5265. 401 Trucks for Sale FOR SALE- '98 JEEP Cherokee Classic, 4L, 33K miles, full power, 1 owner. $14,000.281-542-6398. 2001 SUBURBAN Equipped with 5.3V8, automatic, dual air, power seats, power windows/locks, stereo/cassette/CD, and much more. limited supply. #246105 $29,995, less $1,000 owner loyalty rebate. Spencer La Porte FLEXIBLE FINANCING To fit almost any budget. regardless s of yaw credit history. See stare for details. Corvettes in Stock Millennium Yellow Coupe Pewter Convertible Find us on the web www.lesmarks.com residency restrictions may apply. MEGA SELECTION We offer a trerrundous }.tom oehetlon of new and used 7#��tAT yMkles so We eery to find the car er tmch Mace right for you. I1 W; V:1Ih 171411J ► Y17149,ig IIgill II AM I I I a II N ` 00 FORD MUSTANG CONV.rr,,........$171 '00 MERCURY GRAND MARQU►5... $17 00 FORD E RORER ......................$18, 100 FORD F150 uERm ........... $19 00 FORD F150 IN. CAB ............... $1911 `01 FORD EXPEDITION ...................$B8t 36 mo. Red Carpet Option,12K mile a yr. $3,637.53 total drive off, rpet Option, 12K mile a yr., $3,038.85 total drive off, pymnt. includes 2001 FORD EXPEDITION Comforffanvenience Group, 493 16 Cast Wheels, PER MONTH' Running Boards 101 FORD WLGRER SP11RT @001 FORD F1511 $1,500 factory rebate.IF150 rebate.Prices good day of a d 5.4 VS, Auto, AC PgJ9MOPER NTH' 36 mo. Red Carpet 0ption,12K mil only. All prices + TT&L w/ approved 000 PER MONTH' = comfort/ Convenience Group, Cassette/CD Stereo e a yr., $3,558.99 total drive off, pymnt. includes $1,000 factory credit. AArtrt for illustration purposes only. Page 6 • THE BAYSHORE SUN • WEDNESDAY, APRIL 18, 2001 Classifieds Continued... ORDINANCE SHALL BE Lomax Elementary -Honor Roll Listedix credit units for tenants APPROVED: DEEMED GUILTY OR A ; ith incomes less than PUBLIC NOTICE s/ Knox W. Askins MISDEMEMEANOR AND The following students are on the Hand, Alley Hawkins, Stephen Albert, Melissa Anderson, Leigh' 0% of the area median City Attorney SHALL UPON CONVIC- honor roll for the third nine weeks at Herndon, Kailie Hyde, Katy Knox, Ann Baker, Lynda Blanco, Brittany. icome are: ORDINANCE 1000-1-1 TION BE FINED NOT TO Lomax Elementary. John Koepke, Jacob Lozano, Dillon Browning, Stefanie Cabarubio,' EXCEED TWO THOU- On the "A" honor roll for fourth McJunkin, Marc Morris, Laura Kylie Carmichael, Jason Carter, 18) 1 bedroom 1 bath AN ORDINANCE OF THE SAND DOLLARSgrade ($2,000), AS PROVIDED ($ are: Laura Biggers, Baliegh Moss, Brooke Nelson, Lacey Olive, Emily Cashi, Thomas Cates, Derek snits for $465 monthly; CITY OF LA PORTE, APPENDIX B OF THE Bostick, Kirsti Bostick, AManda Madison Payne, Derek Scott, Holly Dampier, Tim Barracq, Tiffany, ind (18) 2 bedroom 1 bath TEXAS, AMENDING CODE OR ORDINANCES Brown, Jessica Castillo, Matthew Smith, Sarah Trlica, Kimberly DeForge, Sarai Eichenlaub, Kelly snits for $560 monthly. CHAPTER 6, SECTION 6- PUBLIC NOTICE OF THE CITY OF LA Ehlers, Brittany Ellenberg, Saba Villareal, Erica Wadham, B.J. Escamilla, Isaac Falxon, Franchesca -or tenants with incomes ass than of the area 78 OF THE CODE OF ORDINANCES OF THE PORTE; EACH DAY OF Haroon, Brittany Isbell, Katie Kroll, Williams, Corey; Williams and Fernandez, Kendra Foree, Allyssa nedian income the pro income CITY OF LA PORTE, BY ORDINANCE VIOLATION SHALL BE DEEMED A SEPARATE Layne Moore, Andrea Rodriguez, Jordan Yarbrough. Garcia, Myranda Gill, Meagan posed rent for the proper- ADDING AN AREA AT A 2001-2474-A OFFENSE; CONTAINING Megan Schoppe, Kyle Sessions, Lia .< » On the "A"'honor roll for fifth Goff, Megan Goines, Jeffery Haas,, y's tax credit units are: RESTAURANT WHERE SEVERABILITY AND RE- Snider, Chris Warner, and Ashley grade are: Blaize Abshire, Kylee and Samantha Hayes. 25) 2 bedroom 2 bath WINE AND/ OR BEER AN ORDINANCE AMEND- PEALING CLAUSES; Welch. Allen, Katy Anagnostou, Bradley Also, Devin Hemby, Shaaheed snits for $710 monthly; the development will also FOR CONSUMPTION ON THE PREMISES MAY ING CHAPTER 74, "UTIL- FINDING COMPLIANCE On the "A/B" honor roll for fourth Blackwell, Kara Buse, Chance Karabi, Elizabeth Kelly, Jorge Leal,' market rate units to BE SOLD; FURTHER PRO- (TIES", ARTICLE, "INDUS WITH THE OPEN MEET- grade are: Chase Abshire, Britney Cockrell, Candace Evans, Kaidan Val Longoria, Koehl McDaniel; :h)ffer :he general public. The VIDING A SAVING TRIAL WASTE", OF THE ING LAW; AND PROVID- BiermanKaitl n Blanchard, Brett y Hawkins, Chelsea Immin , Mae an g g Ricardo Mercado, Samantha lumber of units and pro- CLAUSE; FINDING COM- CODE OF ORDINANCE ING AN EFFECTIVE DATE HEREOF. Boettcher, Jared Bontekoe, Taylor Kannar, Zachary Krengle, Nicole Mitchell, Dana Moreno, Ashley, posed rents for the proper- PLIANCE WITH THE OF THE CITY OF LA Bray, Shelbi Bryant, Nicole Bush, Lea, Ashlee Long, Nicole Pearsall, Newberry, Travis Newman, An ty's market rate are: OPEN MEETINGS LAW; PORTS, SAID ARTICLE BEING THE INDUSTRIAL Joshua Clark, Ben DeArmond, Samantha Poperszky, Clayton Nguyen, Courtny Rogrigues, Luis (11) 2 bedroom 2 bath for $750 month) PROVIDING A SEVERA- WASTE ORDINANCE OF CITY OF LA PORTE Kristen Ford, Abel Garcia, Xylia Reichelderfer, Steven Reiss, Salas, James Savage, Susan Sexton, units Y awarded credits, it is an- BILITY CLAUSE; AND PROVIDING FOR AN EF- THE CITY OF LA PORTE, s/Norman L. Malone Garcia, Kayton Geddes, Austin Raymond Tacy, kelly Toombs, Kaz Elisha Smith, Harold Sternadel,' ticipated that the develop ti FECTIVE DATE. REGULATING THE DIS- Mayor Goodwin CourtneyGore and Jeff Wheeler, and Shelby Wilson. y Elizabeth Taylor, Core Willmoth y y ment would be ready for CHARGE OF INDUSTRI- Al WASTE INTO PUBLIC Gullet. On the "A/B" honor roll for fifth and Carrie Wilson. occupancy by November SEWER OF THE CITY OF ATTEST: Also, Emma Hamblen, Joshua grade are: Matthew Adams, Kendra 2002. For information about this housing Bevel- CITY OF LA PORTE sMorman L. Malone rthaSec Gillett P C PORTS, TEXAS, PRO- City UMULGATING REGU- City Secretary DPS Seeking Recruits opment please contact Ms Mayor Rae Fairfield, La Porte LATIONS AND ESTAB- Venture, Ltd., 11123 Katy Freeway, Houston, TX LISHING CHARGES FOR SERVICES RENDERED; APPROVED: The Texas Department of Public least 20 years of age by the time they 77079, (713)468-1500. ATTEST: s/Martha Gillett PROVIDING THAT ANY s/Knox W. Askins Safety has unveiled a new toll -free are accepted as trooper -trainees and City Secretary PERSON VIOLATING City Attorney number to facilitate recruiting as the meet certain vision requirements. THE TERMS OF THIS deadline for the next trooper -trainee Extensive screening process Alfa Bowen Has academy approaches. includes verification of written and 4 Levels Of Tanning The new number, 1-866- oral statements ;and a thorough Incldzia New Mary Kay Verb eaI andim TXTROOP (898-7667), rings direct- ly into the recruiting office at Austin background investigation. Written exams, physical agility, psychologi- 041mill, ,1�i8Silf �..: dung DPS Headquarters and is part of a cal and drug testing also required. Sales Status poster and bumper sticker campaign to bolster recruiting efforts. Grand Ada Bowen of La Porte, is one of The large bumper stickers will be 3 _ approximately 650,000 women, placed on all of the Department's r �) enjoying economic and personal black and white patrol vehicles. The �� growth with Mary Kay. stickers prominently display the toll- Bowen recently achieved the sta- free number and read: "BECOME A A p rI l 'E ,,, tus of Independent Sales Director. TEXAS STATE TROOPER. CALL " x She has discovered that a Mary NOW." The application deadline is April y T: {w 1 aH G :::: T ree Kay business allows women the freedom to build successful careers 27 for asix-month recruit school Unlh iilFe[, ` on a part-time or full -times basis that begins Sept. 3 in Austin. �`QlrLlci with unlimited income potential Anyone interested should contact 1nitf'. and flexibility. the nearest DPS office for more fl1T� 1 In preparation for her new role, information and an application pack- purChas� a � F'i�i` Bowen attended a weeklong busi- et-or log on to the DPS Web site, I1I11i1 ," $35.0 GTand'; f?�,r': ness and leadership development www.txdps.state.tx.us. "It's seminar in Dallas where she a competitive world and we a et i ;dk received education in business want to make sure people know DPS 10% Off �t1f " a,F' management, marketing strategies, is in the market for quality individu- i �;F F sales techniques and fashion �J s who want to join the ranks of one Hou trends. Of the nation's elite law enforcement FFi The Mary Kay line includes more agencies," said DPS Director Col. Mon-Thurs 9-10 than 200 products and provides Thomas A. Davis Jr. Fri 9-8 E ._, ' women with unparalleled opportu- As always, the DPS is especially y p y x�€Itt' nity for career and personal fulfill- interested in minority and women Sat 9-6 Pas&de1a, TX'7'7505 ment of owning their own business: applicants. In addition, new guide- Sun 12-5 281-991-9322 financial independence, flexibility, lines allow correctional officers'and career growth. jailers to count work experience - --- toward the 60-hour college require- � _ '- ment.�__ Two years law enforcement or mil- 100 a ✓. itary service also may be substituted for the required college hours. An applicant must be a U.S. citizen at * 0% Interest Now Available I;xxx��Ic�x��xzzixixa;��xxxxxx�lc��xxxx�K�lc1c���xxl;l;xxXix��xxxl;�K� TRANSACTION REPORT l; DATE START RECEIVER TX TIME(L)PAGES TYPE xxxxxzxx��x�x��xa;��a;xzixx�xxx� P. 01 APR-10-2001 TUE 02:49 PM Y NOTE M# DP x APR-10 02:49 PM 2814719627 45"(1) 2 SEND OK 276 Y � x TOTAL 45S PAGES: 2 x XXYXYY�XXXr��t#1;XXl;I;YXXXXXXYYYYMcYXXXXXXxxYYI<1;k�XXI;I;YXXXffiYY�XXXYXrYXYYY�KMcYIC�XXIK�t��I;Y�Xx��X�YICI;YY�XXXXXXMc PLANNING DEPARTMENT FAX TO: CC,— Co ' FROM: Carlos E. Martinez, Engineer i. Ext. 250 - Planning Department FAX: DATE: April 10, 2001 PRONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 O Urgent 1� 'nr Review ❑ Plcau COmmcnt ❑ Pease Reply ❑ Please Recycle xxxz<1<�akx�xtxxxxx�zxxxixxxxxxtxtxxxxx���x x x zt DATE START RECEIVER TRANSACTION REPORT TX TIME(L)PAGES xixt��txx�xxx�x�xx�xx����x�����xz�x�c��z<��x�xxt P. 01 APR-10-2001 TUE 02:51 PM x TYPE NOTE M# DP APR-10 02:50 PM 2814710601 55"(2) 2 SEND OK 278 x TOTAL zt xXXXI;YgXY�K#l;l;X#l;l;McgffiXriXXiXYYgg#1<1<xxxxl;�Ic�xxxXXt�Xixx�Xx#Ic��xx /. 1 qe . •City -QfLa Porte PLANNING DEPARTMENT �i FAX 55S PAGES: 2 ��xx�z���z<zrx���zr���xx�x<xxxxxx TO: M Mop FROM: Carlos E. Martinez, Engineer 1. Lxt, 250 Planning Department FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent wFZorneview ❑ Please Comment ❑ Please Reply ❑ Please Recycle TRANSACTION REPORT P,O1 X APR-10-2001 TUE 03:01 PM Y DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP K t APR-10 03:00 PM 2814785115 **'**fl(2) 0 SEND BUSY 274 X x TOTAL OS PAGES: 0 x x��xa;xxxx�x�xxx��xx���x�tx��xx��xxxzxzxat���xx�xxxx�x;xx��xxxx��l;�xzzatat���xxxzxlt�xx���xiz L14( a1! DEPARTMENT FAX TO 'l FROM: Carlos E. Martinez, Enginccr 1. Ext.250 n D_ epartment FAX: DATE: _Planning April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent ZFr Review 0 Please Comment ❑ Please Reply 13 Please Recycle P. 01 TRANSACTION REPORT APR-10-2001 TUE 03:00 PM x � x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP APR-10 02:59 PM 12815854640"(]) 0 SEND BUSY 273 � x TOTAL : OS PAGES: 0 � zt #1;Icz��:Kxxxlc�xXXYxxxxxxxXXXXXtYxxl;liMc��XXXXI;�Y�1;�Xz:KXzxXkz�Ir��xxx:Kl;�xxxl;xx�t�xxl;xzzXiMcXXz:I��X<xXx���Xxxxx Porte y '' -- PLANNI.NG DEPARTMENT FAX FROM: Carlos E. Martina., Engineer I. ^n Ext. 250 Y' , C® IJ 5 T- Planning Department FAX.- DATE: April 10, 2001 PHONE: PACES: 2 RE CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 O Urgent VFor Review O Please Comment O Please Reply 0 Please Recycle xztz�xixrtl;xixl<l;x�xx�ztxxixil<x���xixx���xxxxixxirixx���l;zxxxl<��zz�x����x�xXix���xz�x������xxix�xxixxx�xx���xx�xl<�� Y P. 01 TRANSACTION REPORT APR-10-2001 TUE 02:58 PM Y � DATE START RECEIVER TX TIME U PAGES TYPE NOTE M# DP Y APR-10 02:58 PM 2814331018 **,**" 0 SEND CANCEL 267 a TOTAL : OS PAGES ��xxXixxxx��l;�x��Xt�xxxXixriXixx�xxlixx���xxxxxxx�xXiXixx�l;xxxx�l;Xt�xXiziXt�l;Xr� F—M41 TO: _ UT� C U ci v FROM: Carlos 14. Martinez, Engineer 1. Ext.250 r �- Planninc, Department FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE, SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent F� or Review ❑ Please Comment ❑ Please Reply O Plauc Recycle P. 01 1 TRANSACTION REPORT - APR-10-2001 TUE 02:57 PM X � DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP APR-10 02:56 PM 7132789892 45"(1) 2 SEND OK 277 x TOTAL 45S PAGES: 2 X 1; x 1t#XXY�XXY�KXXXYY�XXXrdXIKYYYXICMcY�XXXXXXXrit:YXYXXXICYXYYXXr�YX�X;Y:K#It XtXXYYlK�1CMcXYXXXXYYXXXXYX;XX�KXrXX�XXXX�xxXX rl PLANNING DEPARTMENT' FAX TO: I2- FROM: Carlos F. Martinez, Engineer I. —n ) 0 J ' 1/�� T� D ," Ext.250 �. Planning Department FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 O Urgent !lB 'ar Review ❑ Please Comment ❑ Please Reply ❑ Please Recycle xxtx�z��xz��zt�xl;x�xxxxx���xxxxl<1;�xxxxx�l;at�x��xxx�xt���c�c�xxxxxixx�xl��x�zizr��x��x��xzr��x�������x�a;�zt�xrrztxx P. 01 x TRANSACTION REPORT — APR-10-2001 TUE 02:54 PM 1 DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP Y � APR-10 02:52 PM 2814794337 1'43"(2) 2 SEND OK 270 Xt � TOTAL 1M 43S PAGES: 2 Xt � x x�l;lrXrxxx��x��x�al���xxxxXiXt�xx����cxxt�xtxt��x�xx���xxx���x�x���XtXtxxxrtriXt>K�x��xXixxXiXix�xtxXix�xXi�Xt���XiXix>kXiziXt�x PLANNTNC DEPARTMENT FAX TO: 47 1J ct FROM: Carlos F. Martinez, Engineer 1. �7 Ext.250 / �• +• PlanningDepartment l` FAX: DATE: April 10, 2001 PHONE: PAGES• 2 RE: CITY-WIDE SIDEWALK- -CC.- REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent F� or Review O Please Comment O Please Reply ❑ Please Recycle �x;xxx>ti�xx��z�x�x��xx�xxxx��xx������xxx�zx��xxx��xxx�xx�x�xx�����xxxx����xx���x�ar�xz�xxzt��xt�c��xxxt:�� P. 01 TRANSACTION REPORT APR-10-2001 TUE 02:52 PM � x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP � X APR-10 02:51 PM 7139565817 39"(2) 2 SEND OK 280 TOTAL 39S PAGES: 2 x � XtY�X1;YX#XtX1;X�lKXXXXxXXxxXxXXxxYYX��YYYxI<M:Y�XXXXXXY�KXXXY�KXI;XXX�#XXXXXXXXXXMcXXXXXYMcXXXXYMcXXXYXXXXXXYYY PARTMENT F •, — �� l FAX TO: � /� 1 I (i FROM: Earl 250 Martinez, Engineer I. c'o N 5 T Planning Deparlmcat FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: - -WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent VZfor Review ❑ PIC= Comment ❑ Please Reply ❑ Please Recycle xl<xxxxxxxxl<��rirt��x�x��l;l;�xxx�z�xxxl;xxzxxix��zxx�xrt��xxtxxxxt��c���rtXtl;l;rtrtl;x�l;xl;xx�x;xxzt��xzt��x��zix;ztxzixx�xx * P. 01 TRANSACTION REPORT X APR-10-2001 TUE 02:52 PM x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP APR-10 02:51 PM 2813428967 59"(1) 2 SEND OK 279 X � TOTAL 59S PAGES: 2 x � x xl;xxzir<zt�xxzix�zrxxzztl;l;x����xxxxzzizzz�xx�xxxzixztl;��ztzixxl;�zxz<I<I;I;xxxxxx���x���x;�xxxzizt�xxzxx<zixtx;xzrl;x���x<x City of La 'or FAX TO: FROM: f Carlos E. Martinez, Engineer 1. nn Ext.250 1 C Y' CO N $ Tf -V LTA e-S Planning Department _ FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT F Y 2000-2001 _ ❑ Urgent Fly or Review 13 Pkasc Comment ❑ Pkasc Reply ❑ Please Recycle �l;��zx•�x�x�x����xxx��zt>kzt���xxx�����x��x����z����z�x��x���xxxxxxx��c�x��������xxxx��x������zx�����xx�� t P. 01 x TRANSACTION REPORT APR-10-2001 TUE 02:49 PM � x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP X X x APR-10 02:48 PM 2814716038 1'15"(2) 2 SEND OK 275 � x X TOTAL 1M 15S PAGES; 2 XYYYIr�XYY�XXXYYYX<XXXXXYYXYYYYX<YXXXXXXXYYXYYI;XXtY�I;XXYXXXXXXY�YMcXXXXXXXxXXXXXXXY�XXYMcYX�XYIKtI;XXXXXXXX FLANN1NG DEPARTMENT FAX TO: 1---o U S �,� ST FROM: CarE. O Carlos E. Martinez, Engineer I. Planning Department , FAX: DATE: April 10, 2001 PHONE: PACES: 2 RE: CITY—WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urlment V For Review ❑ Please Comment ❑ Please Reply ❑ Please Recycle xl<��xl<xxzixxx��xxz<xxxxxxxx��xxxxx��x<xxtxxxx�xxxxz<xxx�xxxxxx<xxxxl<l<xl<x<xx>kx��z<�xtxtxxxxxxxxl<xxxz<>xx�xx�z<xxxx z P. 01 TRANSACTION REPORT APR-10-2001 TUE 02:47 PM � x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP x W x APR-10 02:44 PM 713937117t81 3'01"(1) 2 SEND OK 271 x TOTAL ; 311 1S PAGES: 2 xtxxx���xxx���xtxx�>K��zt�xxxxx��zix��xztxrt��x�c�x�c���ziXt�zrxx����xxxxx���t�����xztztxx�Xix�Xtxzixtzt���ztrrzt�czrxxxxxx PLANNING DEPARTMENT FAX TO: �j y l �— Co �VQ70 A/ FROM: CarIOS F,. Martinez, Engineer 1. F•xt.250 �. Planning Department FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent W For Review 4 Please Comment O Please Reply ❑ Please Recycle x�xzixxt•�����xxixt�����x�xxx������x�xx��;�x�xx����xxx����x�x�x����� TRANSACTION REPORT DATE START RECEIVER TX TIME(L)PAGES TYPE �arx<xzxzxxx��xxx��x���x��x:l��xx���� P. 01 APR-10-2001 TUE 02:47 PM X NOTE M# DP x APR-10 02:46 PM 2815400174 38"(2) 2 SEND OK 272 TOTAL 38S PAGES: 2 XXXXYgI;XXiXI:XXXXXXIIYYMc�XXXX1;I;�XXXXX:11c�McgXXX1;XX:I�XXXXt:IX1;XXt�lI;1;YXYXXYYIKY�YXXXXJKY��XXXY�XXI;�XXXI;XXXXXXX�� PJANNING DEPARTMENT FAX TO: / fJ FROM: Carlos E. Martinez, Engineer I. F,xt.250 - �7 � (.('1 1/O fi/� S Planning De artment FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent ZFoUeyicw O Please Comment ❑ Please Rcply 0 Please Recycle �������xxxx�ztxxxxxxzixxxxxxxl;�l;x�x�z�atx�xx���xix�l;xxxx�xxx�l;xx��tx�xxtxx�xzixx�x�xx�x�l;��xxl;xl;��x��x;tl< P. 01 TRANSACTION REPORT K APR-10-2001 TUE 02:46 PM x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP x x APR-10 02:45 PM 1139478444 58"(2) 2 SEND OK 264 X X TOTAL 58S PAGES: 2 x x xXt�l;xxz�x��xXt����l;��xl;xx�l;l;��zxxlt��l;xxzxxxx�xxx�>K��xx�>Kl;��xxx�XiXiXizixl;lc��l;�x�l;Xt�l;�xl;�t�xz�xt���xxxxxxxx Qity aflaPorte DEPARTMENT PLANNING FAX TO: FROM: Carlos E. Martinez, Engineer 1. Fxt. 250 Planning De2art ent FAX: DATE: April 10, 2001 PHONE. PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent Ft� or ltiwiew ❑ Please Comment ❑ Please Reply ❑ Pleue Recycle �ztxxiz�xx�x�zix��xxxxxxxxxxixixixt������xxxxtxx���zrxxxxxrxztxxx��x����>K��xrxzix���xr���c�xtxzix��xri�zrx��x��xzr�xrcztxx P. 01 TRANSACTION REPORT APR-10-2001 TUE 02:43 PM X X DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP zt x APR-10 02:42 PM 7134731848 1'18"(2) 2 SEND OK 269 � x TOTAL iM 18S PAGES: 2 � x �xxxrzrzrxxx�xt�xiz�xtrsxxx�xt�zixzxx�xtztxxxzxixizizztl<rc�rixiziz<rl�xxtxix�xxxxxixixt�zxix��z<zr��t�r<r<zxx��>s�xz�arlczz�xzixxarar>;Izr� Cjjx of La�Ravt— PLANNING FAX TO: —I-C_S S U FROM: Carlos E. Martinez, Engineer I. Ext. 250 �. PlanningDepartment FAX:DATE; April 10, 2001 PHON.W;: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT PY 2000-2001 ❑ Urgent VFor Review ❑ Pkayc Comment ❑ Please Rcply ❑ Please Recycle P. 01 K TRANSACTION REPORT APR-10-2001 TUE 02:43 PM � x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP t APR-10 02 : 42 PM 28.144224.15----� 1' 04" (1) 2 SEND OK 268 x x TOTAL 1M 4S PAGES: 2 x x ,^ ; Porte PLANNING DEPARTMENT FAX TO: C FROM: Carlos E. Martinez, Engineer 1. Ext.250 Planning Department �s FAX: DATE: April 10, 2001 PHONE: PACES: 2 M RE: CITY-WIDE SIDEWALK CC: REPLACEM14NT PROJECT FY 2000-2001 ❑ Urgent ZFoRevicw ❑ Plcxsc Commcnt ❑ Plca.+c Rcply ❑ Please Recycle I;xxxx��I;�xxxxxx��xtxxxxx�xx�xxx�x�xtxt�xxxxxx��zt��x���x�������������I<I;zxxxxxxxxxxr�xx�x;x���x��z�l;zzx�xxx x P. 01 TRANSACTION REPORT APR-10-2001 TUE 02:41 PM DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP � x APR-10 02:40 PM 7139441006 48"(2) 2 SEND OK 266 X< TOTAL 48S PAGES !City of La Porte PLANNING DEPARTMENT FAX TO: C FROM: Carlos E. Martinez, Engineer 1. F.xt. 250 �. ► r ` Planning Oc �artment FAX: DATE: April 10, 2001 PHONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent F� or Review ❑ Plum Comment ❑ Please Reply ❑ Please Recycle �xx�x��l;�x��zxx�xxxl;�xxxxx�x� X DATE START RECEIVER TRANSACTION REPORT TX TIME(L)PAGES TYPE APR-10-2001 TUE 02:40 NOTE APR-10 02:39 PM 2814711710 59"(1) 2 SEND OK 265 � X TOTAL 59S PAGES: 2 x��xxXtl;xx���xxt�x���xxxxxxzrzrxrxxx��xl;��xrxrixx�xx�x�xx��zzix��l;xzxxxxxl;�xx��xxxxxrixx��x��c�xz�x��xzit�xxxrrxl; PLANNING DEPARTMENT FAX TO: C YAM _re D FROM: Carlos 1 . Martincz, Engineer 1. Ext. 250 Planning De artment FAX: DATE: April 10, 2001 PRONE: PAGES: 2 RE: CITY-WIDE SIDEWALK CC: REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent F� or Review ❑ Pkrse Comment ❑ Please Reply ❑ Please Recycle ����at�xtx�xxxzix�x�xxxxxxx�xrx��xx***xx�x�t<�xxzx�xxt��zxxxt�����xxxxx�x���x�atx��zrxxzt�xxtzirt�xxzzr�at>kxzrxxzt�zt� P. 01 X TRANSACTION REPORT APR-10-2001 TUE 02:39 PM I I; x DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP � x APR-10 02:38 PM 7139414887 44"(1) 2 SEND OK 263 Xt x x x TOTAL : 44S PAGES: 2 � x xxx��xxrixx�c��xxriXx�xx��Xr�XtxxxxXYx:K:K�cXtXt�cxXt�X���cXiXtXt�x�XtXtXiXix��c�c�XtxxxriX�c�c�c�xxYxXx��cxxzr�xX<X<��zt�>KXtztztXtztXtXtXtXt ' k L'PLANNING DEPARTMENT FAX TO: ( V £ (�� nl u�7 FROM: Carlos E. Martinez, Enginccr 1. Ext. 250 C, Planning Department FAX: — DATE: April 10, 2001 PHONE: - - —_ PAGES: 2--_._..__-•-- RE: CITY-WIDE, SIDEWALK __ CC: -- REPLACEMENT PROJECT FY 2000-2001 ❑ Urgent ZFurview ❑ Please Comment ❑ Please Reply ❑ Please Recycle NOTICE TO BIDDERS CLP Project No. 2000-4501 Sealed bids, in duplicate, on the original forms, signed by an officer of the Company, and addressed to Martha Gillett, City Secretary, City of La Porte, 604 W. 'Fairmont Parkway, P.O. Box 1115, La Porte, Texas 77572-1115 will be received until 2:00 PM, April 30, 2001, for the construction of: CITY OF LA PORTE CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO. 20004501 2. Bidders are requested to attend a pre -bid conference to be held in the Council Chambers at City Hall, 604 W. Fairmont Parkway, La Porte, Texas, April 23, 2001, at 10:00 AM. 3. Interested contractors may obtain plans, specifications and necessary bidding information at no cost from: CITY OF LA PORTE PLANNING DEPARTMENT 604 W. FAIRMONT PARKWAY LA PORTE, TEXAS 77571 (281)471-5020 4. Each PROPOSAL shall be accompanied by a cashier's check, certified check, or bid bond from a surety company licensed in the State of Texas in an amount not less than five percent (5%) of the total amount bid, as a guarantee that the successful bidder will enter into a Contract and execute the Bond(s) if required, within ten (10) days after the receipt of the Contract Documents. 5. The City of Porte hereby notifies all bidders that in regard to any Agreement entered into pursuant to this advertisement, minority business enterprises will be afforded equal opportunities to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, age, religion or national origin in consideration for an award. 6. The Owners reserve the right to reject any and all bids and to waive informalities in bidding. In case of ambiguity or lack of clearness in stating the prices in the bid, the Owner reserves the right to consider the most advantageous construction thereof or to reject the bid. CITY OF LA PORTE Martha Gillett Notice to Bidders Page 1 of 1 xxx��x�xx<x<��x��xxxxx����xxz�t;xxx��xx�z�xx;xx�xxx��xx��xxx�����xz�x�xxx�xx��xxxx���z;xlc�z;x:f;�z;����z<�x��x ` TRANSACTION REPORT P. 01 APR-10-2001 TUE 08:12 AM DATE START RECEIVER TX TIME(L)PAGES TYPE NOTE M# DP � Y APR-10 08:11 AM 2814715763 38"(1) 2 SEND OK 255 X # TOTAL : 38S PAGES: 2 FtawVS& To: The Bayshore Sun From Chy of La Porte — Peggy Lee Fa:a 281-471-5763 Data: 4-OM1 Phone: 281471-1234 Pages: (inc. cover) 2 Re: CC: Fax To: The Bayshore Sun From: City of La Porte — Peggy Lee Fam 281-471-5763 Date: 4-9-01 Phone: 281-471-1234 Pages: (inc. cover) 2 Re: CC: ❑ Urgent ❑ For Review ❑ Please Comment ❑ Please Reply ❑ Please Recycle Commerrts: Please publish on Wednesday, April 11"' and Wednesday, April 18, 2001. Invoice Planning Department. City of La Porte Planning Department 604 W. Fairmont Pkwy. LaPorte, TX 77572-1115 Phone: (281) 4715020 Fax: (281)471-7168 r NOTICE TO BIDDERS CLP Project No.2000-4501 Sealed bids, in duplicate, on the original forms, signed by an officer of the Company, and addressed to Martha Gillett, City Secretary, City of La Porte, 604 W. Fairmont Parkway, P.O. Box 1115, LaPorte, Texas 77572-1115 will.be received until 2:00 PM, April 30, 2001, for the construction of: CITY OF LA PORTE CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO.2000-4501 2. Bidders are requested to attend a pre -bid conference to be held in the Council Chambers at City Hall, 604 W. Fairmont Parkway, La Porte, Texas, April 23, 2001, at 10:00 AM. 3. Interested contractors may obtain plans, specifications and necessary bidding information at no cost from: CITY OF LA PORTE PLANNING DEPARTMENT 604 W. FAIRMONT PARKWAY LA PORTE, TEXAS 77571 (281)471-W20 4. Each PROPOSAL shall be accompanied by a cashiers check, certified check, or bid bond from a surety company licensed in the State of Texas in an amount not less than five percent (5%) of the total amount bid, as a guarantee that the 'successful bidder will enter into a Contract and execute the Bond(s) if required, within ten (10) days after the receipt of the Contract Documents. 5. The City of Porte hereby notes all bidders that in regard to any Agreement entered into pursuant to this advertisement, minority business enterprises will be afforded equal opportunities to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, age, religion or national origin in consideration for an award. 6. The Owners reserve the right to reject any and all bids and to waive informalities in bidding. In case of ambiguity or lack of clearness in stating the prices in the bid, the Owner reserves the right to consider the most advantageous construction thereof or to reject the bid. CITY OF LA PORTE' Martha Gillett Notice to Bidders Page 1 of 1 Project Schedule C L'OS Project Title: CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Project Number: 20004501 03\16\01 04\02\01 04\06\01 04\09\01 04\09\01 04\09\01 04\09\01 04\09\01 04\09\01 04\09\01 04\09\01 04\09\01 04\09\01 04\11\01 04\18\01 04\23\01 TEA E Engineering Review Specs/Plans Inspections Review Prelim Approval by Doug Copies of Plans No. Copy/Bind Specs No. Doug — sign & stamp Specs & Plans Martha — sign Notice to Bidders (NTB) Reserve Council Chambers (pre -bid and bid opening) Copy of NTB to: Martha, John, Susan Kelly, Reagan, Doug Copy of NTB to Peggy (ad in paper) Copy of specs to City Attorney for prelim approval Develop List of Bidders/Chamber of Commerce Fax NTB to List 1st Advertisement to Bid 2nd Advertisement to Bid (week after 1st ad) Pre -Bid Meeting (> week after 1st ad) -10:00 AM 04\09\01 List of Contractor's and Faxed NTB to Martha 04\30\01 7 Bid Opening (15 days after 1st ad) - Mondays at 2:00 PM 05\07\01 Council Agenda Packet to Martha (Mon. before CC mtg.) 05\14\01 City Council Action - 6:00 PM 05\15\01 Notice of Award & 5 copies of Contract Does to Contractor 05\18\01 Signed Contract Docs from Contractor 05\18\01 Contract Docs to City Attomey 05\18\01 Contract Docs from City Attomey-final approval 05\18\01 Contract Does to City Manager 05\18\01 Contract Docs back from City Manager Permit from Inspections 05\21 \01 Issue Notice to Proceed (plus two copies) @ Pre -Construction Mtg. -RE-l)E(A) �� =6.�1 `��i�1rj' ���� -rAbi , J)OU4,a)-- ACot1�j TECHNICAL SPECIFICATIONS 4. PAYMENT 4.1 All work performed_ as required herein and as provided under "Measurement' will be paid for at the unit price bid per linear feet, which payment shall be full compensation for furnishing all labor, tools, equipment, hauling and disposal of broken concrete and all other incidentals necessary to complete the work No payment shall be made for removal of curb but shall be considered incidental. 4.2 Saw cut will be paid for at the unit price bid per linear feet. All saw cut shall be made to the full depth of materials that are required to be cut. This shall include all existing curb to be removed for handicap ramps. Technical Specifications Page 2 of 19 TECHNICAL SPECIFICATIONS ITEM II FOUR FOOT CONCRETE SIDEWALK REPLACEMENT 1. DESCRIPTION 1.1 This section covers the furnishing of all equipment, superintendence, labor, and materials necessary in construction of concrete sidewalks including handicap ramps in accordance with the plans and specifications. 2. MATERIALS 2.1 Concrete shall conform with requirements specked in Technical Specification "Concrete for Structures". 2.2 , An approved type of commercial pre -molded expansion joint (3/4" thick) or redwood (1" thick) shall be placed. 2.3 Reinforcing steel shall be #3 bars at e ch way or #4 @ 24" O.C. E.W. 2.4 Cushion sand shall be clean and well graded and free of clay and humus material. 3. CONSTRUCTION METHODS J\ QPPe�`� 3.1 Stripping: All grass and humus material shall be stri d and removed from the area of the sidewalk. 3.2 Grading: After stripping and removing of grass, humus material, and tree roots, any soft or otherwise unsuitable material within the sidewalk area shall be removed and replaced with approved fill materials and compacted. The grade shall then be brought up to the bottom of the proposed level of the sidewalk with a maximum of four inches (4") of bank sand fill. 3.3 Forms: The sidewalk shall be formed and braced with forms of wood or metal, straight, free from warp and of a nominal depth of four inches (4') prior to pouring of concrete. The forms shall be braced so that no horizontal or vertical displacement occurs during the concrete pour or during the period for curing. 3.4 Expansion joints shall have a maximum spacing of thirty feet (30') between joints or as shown on the plans and according to this specifications or as directed by the Owner's Representative. Expansion joints shall be required where all sidewalks intersect with existing driveways, existing roadway pavement, and at all saw cuts locations unless otherwise directed by the Engineer. In locations where the new concrete is to tie to existing concrete, the old expansion joint material shall be removed and replaced with new expansion joints. Technical Specifications Page 3 of 19 TECHNICAL SPECIFICATIONS ITEM V ADJUSTMENT OF METER BOXES, VALVE BOXES, AND MANHOLE RINGS AND COVER DESCRIPTION 1.1 This section shall govern the adjustment of meter boxes, valve boxes, manhole rings and covers, etc. to the proposed finished grade of roadway paving, sidewalks, parking lots, or other paved surfaces as indicated on the plans or, in the opinion of the Owner's Representative, requiring an adjustment. The work covered in this section consists of furnishing all plant equipment, labor, materials, and performance of all operations for the required adjustments. 2. CONSTRUCTION METHODS 2.1 After the existing pavement is removed, the existing water meter box, valve box, or manhole ring and cover shall be excavated around in a sufficient manner to allow for the required adjustment in grade. The adjustment of water meter boxes and valve boxes shall be made without adjustment in grade on the water line or service lines. If, in the opinion of the Owner's Representative, an adjustment in the service line or system line is required, he may direct the contractor to do so under extra work items or the work may be performed by City of La Porte personnel. The adjustment of manhole rings and covers shall be accomplished by removal or addition of materials necessary to bring the top to grade and may be poured as an integral part of the proposed pavement. 3. MEASUREMENT 3.1 The adjustment of the water meter boxes, valve boxes, and manhole rings and covers shall be measured by each. 4. PAYMENT 4.1 Payment for complete adjustment of water meter boxes, valve boxes, and manhole rings and covers will be made at the unit price bid for each. Technical Specifications Page 13 of 19 TECHNICAL SPECIFICATIONS ITEM VI CONCRETE DRIVEWAY REPLACEMENT 1. DESCRIPTION 1.1 This section covers the furnishing of all material and construction of concrete driveways in accordance with the drawings and these specifications. 2. MATERIALS 2.1 Concrete shall conform with requirements specked in the specification "Concrete Pavement Water Cement Ratio". The concrete shall be 5 sacks per cubic yard. 3. CONSTRUCTION METHOD 3.1 Stripping: All grass and humus material shall be stripped and removed from the area of the driveways. 3.2 Grading: After stripping and removing of grass and humus material, any soft or otherwise unsuitable material within the sidewalk area shall be removed and replaced with approved fill materials and compacted to a depth of four inches (4"). 3.3 Forms: The driveways shall be formed and braced with suitable material prior to pouring of concrete. 3.4 Concrete shall not be placed when the temperature is below 40 degrees F. and falling, but may be placed when the temperature is 35 degrees F. and rising, the temperature shall be taken in the shade and away from artificial heat. 3.5 Concrete shall not be placed before time of sunrise, and shall not be placed later than will permit the finishing of the pavement during sufficient natural light. 3.6 Workers will not be permitted to walk in the concrete with earth or foreign material on their boots or shoes. Repeated failure to clean their boots or shoes when walking in the concrete shall be deemed sufficient cause for removing or replacing such workers. 3.7 Any concrete not placed as herein prescribed within thirty (30) minutes after mixing, shall be rejected and disposed of as directed by the Owner's Representative. 3.8 Concrete shall be distributed to such a depth that when consolidated and finished, the slab thickness required by plans will be obtained at all points and the surface shall not, at any point, be below the established grade. Special care shall be exercised in placing and spading concrete against forms at all joints to prevent the forming of honeycombs or voids. _ ,, Q-0 Technical Specifications Page 14 of 19 TECHNICAL SPECIFICATIONS 4. FINISHING 4.1 Hand Finishing: The concrete shall be struck off with an approved strike -off screed to such an elevation that when consolidated and finished the surface of the pavement shall conform to the required section and grade. The strike template shall be moved forward with a combined transverse and longitudinal motion in the direction the work is progressing, maintaining the template in contact with the forms and maintaining a slight excess of material in front of the cutting edge. The concrete shall then be tamped with an approved tamping template to compact the concrete thoroughly, and eliminate surface voids, and the surface screeded to required section. 4.2 After completion of a strike -off, consolidation, and transverse screeding, hand -operated longitudinal float shall be operated to test and level the surface to the required grade. Workers shall operate the float from approved bridge riding on the forms and spanning the pavement. The longitudinal float shall be operated with short longitudinal strokes while being passed from one side of the pavement to the other. 5. CURING 5.1 Immediately after finishing operations have been completed, the entire surface of the newly laid concrete shall be covered and cured in accordance with the THD Specifications, Item 360.9. 5.2 Failure to provide sufficient cover material of the type the contractor elects to use, failure to maintain saturation in wet curing methods, lack of water to adequately take care of both curing and other requirements, or other failure to comply with curing requirements shall be cause for immediate suspension of concreting operations. 6. PROTECTION OF CONCRETE DRIVEWAYS 6.1 The contractor shall erect and maintain the barricades required by the plans and such other standard barricades and approved devices as will exclude the use of the driveway for a period of time as directed by the Owner's Representative. 7. OPENING DRIVEWAY TO OWNER ' 7.1 The driveway shall be closed to all traffic vehicles u til the con cte is at least two (2) days old. This period of closure to all traffic may be extended, if in the opinion of the Owner's Representative, whether or not conditions make it advisable to provide an extension of the time of protection. 7.2 The Owner's Representative may require the opening of the driveway to traffic prior to the minimum time speed above under conditions of emergency which, in his opinion, require such action in the interest of the public or homeowner. 8. MEASUREMENT 8.1 Concrete driveways will be measured for payment by the square yard of surface area of completed and accepted work. Technical Specifications Page 15 of 19 TECHNICAL SPECIFICATIONS 9. PAYMENT 9.1 Concrete driveways will be measured as provided under "Measurement' and will be paid for at the unit price bid per square yard of completed and accepted work, which price shall be full compensation for excavation and fine grading the driveway, including furnishing and installing sand cushion, all reinforcing steel, hauling and handling all concrete ingredients, mixing and placing concrete, finishing, curing, cleaning, and sealing joints; and placing longitudinal, reinforcing steel and all incidentals necessary to complete the work. Technical Specifications Page 16 of 19 This section deleted. TECHNICAL SPECIFICATIONS ITEM VIII ST. AUGUSTINE BLOCK SODDING Technical Specifications Page 18 of 19 �A TECHNICAL SPECIFICATIONS ITEM IX CEMENT STABILIZED SAND DESCRIPTION 1.1 The work covered by this section consists of furnishing all plant equipment, labor, materials, and performance of all operations for cement stabilized sand backfill it trench excavation as ordered by the Engineer. 2. MATERIALS 2.1 Sand: The sand shall be a river sand free from roots and other objectionable matter. 2.2 Portland Cement: Cement used shall be a standard brand of Portland Cement. It shall conform to the latest specifications of ASTM Designation C-150, Type I. 2.3 Water: Water used in the send -cement mixing operation shall be approved by the Owner's Representative and tested in accordance with AASHO T-26. 3. PROPORTIONAL AND MIXING 3.1 Mixture shall have not less than 2 sacks of Portland cement per cubic yard. Add required amount of water and mix thoroughly in an approved mix type mixer. Design sand -cement mixture to produce a minimum unconfined compressive strength of 100 pounds per square inch in 48 hours when compacted to 95% in accordance with ASTM D 698. 4. CONSTRUCTION METHOD 4.1 Cement stabilized sand shall be placed at optimum moisture content at the location as shown on the plans in not more than 6 inch layers, loose measure, and compacted with mechanical tamps or other approved equipment, to at least 95 percent of standard AASHO T-99 density. 5. MEASUREMENT 5.1 Cement stabilized sand will be measured for payment by the ton. 6. PAYMENT 6.1 Cement stabilized sand backfill will be paid by the unit price bid per ton. " END' 1� Technical Specifications Page 19 of 19 )11 CLP Project No. 2000-4501 �Dc�tz c_atis rR<.�ri au Proposal of SErzv,cc-s (hereinafter called "Bidder")' a corporation, organized and existing under the laws of the State of * a partnership, or an individual doing business as-�bar,- 1'az,,'Ce6to the City of La Porte, Texas (hereinafter called "Owner"). Ladies and Gentlemen: The Bidder, in compliance with your invitation for bids for the construction CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 99-00 per plans and specifications prepared by the City of La Porte, and having examined the plans and specifications with related documents and the site of the proposed work, and being familiar with all of the conditions surrounding the construction of the proposed project including the availability of materials and labor, hereby proposes to furnish all labor, materials and supplies and to construct the project in accordance with the contract documents, within the time set forth therein, and at the prices stated in the attached Bid Schedule. These prices are to cover all expenses incurred in performing the work required under the contract documents, of which this proposal is a part. Bidder hereby agrees to commence work under this contract on a date to be specified in written "Notice to Proceed" of the Owner and to fully complete the project within 30 consecutive calendar days thereafter as stipulated in the specifications. Bidder further agrees to pay as liquidated damages, the sum of $100.00 for each consecutive calendar day thereafter as provided in Paragraph SC-0 of the Supplementary Conditions of the Agreement. Bidder acknowledges receipt of the following addendum: DATE: 307zco 1 Bid Proposal Page 1 of 4 M 1 BASE BID PROPOSAL BASE PROPOSAL: Bidder agrees to perform all further described in the specifications for the sum of y IL�-Vaao N"/� k)iw.'5 ^VDL-*25 Ww )5,�c1='e dollars ($ 34 959. /6" ). (Amount shall be shown in of discrepancy, the amount shown in words will govern.) of the work shown on the plans In case Bidder understands that the Owner reserves the right to reject any or all bids and to waive any informalities in the bidding. The bidder agrees that this bid shall be good and may not be withdrawn for a period of thirty (30) calendar days after the scheduled closing time for receiving bids. Upon receipt of written notice of the acceptance of this bid, bidders will execute the formal contract attached within ten (10) days and deliver a Surety Bond or Bonds as required. by the General Conditions. The bid security attached in sum of Acc % � All � 14-10ery dollars ($ 4 90o = ) is to become the property of the Owner in the event the contract and bond are not executed within the time above set forth, as liquidated damages for the delay and additional expense to the Owner caused thereby. Respectfully su _ n ed BY: (Signature of/Authorized Person) (Print Narhe of AuthorizedPerson) (SEAL) ��/iSiu.� irA6c92 (Title) �0.•30� 2g15- (Business Address) (City) (State) (Zip Code) 215Y-470-66'39 (Telephone Number) Bid Proposal Page 2 of 4 J l STATEMENT OF MATERIALS AND OTHER CHARGES MATERIALS INCORPORATED INTO THE PROJECT: ALL OTHER CHARGES: TOTAL: This total must agree with the total 'Total Amount Bid" figure shown on the bid sheet. For purposes of complying with the Texas Tax Code, the Contractor agrees that the charges for any material incorporated into the project in excess of the estimated quantity provided for herein will be no less than the invoice price for such material to the Contractor. r 1 Bid Proposal Page 3 of 4 BID SCHEDULE CLP Project No. 20004501 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 200-2001 Item Description Unit Estimated Unit Total No. Quantities Price 1.0 Concrete Sidewalk Removal LF 1979.8 So So complete in place 2 41 9f - @ /eJo L%ma0CS 4n�n �F,71 674'r per ,G 2.0 4' wide concrete sidewalk LF 1387.1 6 complete in place ZGCZJFC� �Du-A/1S ,PN.O %-/�l� �S per LIC i 3.0 Wheelchair ramps EA 39 complete in place @ A64OAC27 /�ocA23 AX4 KJD C�r.�73 per 4W 4.0 Extra Bank Sand (ordered by city) TN complete in place per 5.0 Extra Sod (ordered by city) SY complete in place //�� — @ �/lc5e A o,-R/LS An-o /moo ors per S y J i Total 30 Bid Proposal Page 4 of 4 I,•>OOO IJmJlIIOzIO Iu"—`16.L0PiuJ IO=Vl;Ul L400S:emu ldd t002-5-rloi ACORD CERTIFICATIL JF LIABILITY INSUR1.:, +cE 1)1/05/2001 RDOUCER C254)699-7100 FAX (254)699-6680 ii 9 ham Kl sewer Chapman & Watts 2100 Trilmllier. Suite 100 P. 0. Box 996 Killeen, TX 76S40-0996 THIS CERTIFICATE 15 ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NSURED IDEAL CONSTRUCTION SERVICES, INC. P.O. BOX 2277 SUGARLAND, TX 774$7 INSURER a COMMERCIAL UNION INSURANCE CO INSURERS, POTOMAC INSURANCE CO INSURERG. VILLANOVA INSURANCE CO wsuRERv INSURER E THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REOUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECTTO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY?ERTAIN. THE INSURANCE AFFORDED BY THE POLICIES OESCR18ED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS ISR TYPE OF INSURANCE POLICY NUMBER DA M N Iv uYIID�D N LIMITS A GENERAL LIABILITY X COWERCINL GENERAL LINSILOY CLAWS MADE O OCCUR RR 513458 12/31/2000 12/31/2001 EACH DCCURRENCE $ 1, 000 DO FLREDAMAGE(A�.) 3 300,00 ,RED EXIP (AIry w olra) E 5 0 06ASONAL 3 AOV INJURY S 1,000,00c GENERAL AGGREGATE 3 Z1000100 GENL AGGREGATE LWITAPPVES PER- X POLICYECT LOG PRODUCTS. COMPIOP ADO 3 2,000,000 B AUTOMOBILE IJAGLJTY ANY Aura ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS NON-0WNED AUTOS G 50991-01 ` I I I 12/31/2000 12/31/2D01 COMSWED ENGLE LIMm ¢A acoPlYYl S 1.000.00( X BOOBY RtJURY (PHI PIFFa') 3 X BODILYINJURY3 X PROPERTY DAMAGE I?w:cotcM} 3 GARAGE UABUII' ANY AUTO 'I AUTO OwLv - EA ACCIDENT S OTHER THAN EA ACC AUTO ONLY: AGO i S A EXCESS LIABILITY X OCCUR CLAIMS MAIZE DEDUCTIBLE RETENTION 3 RDW 34531 - 12/31/2000 12/31/2001 EACH OCCURRENCE $ 4 D00,00 AGGREGATE 3 4,0G0,00 -S S A C WORKERS COMPENSATION AND '. EMPLOYERS' LIABILITY C21570888 1 /� y •' 12/31/2000 12/31/2001 X TOOY LWrzS ER EL EACH ACCIDENT 3 1000000 E L DISEA6E E4 EMPLOYE S 100000 E.L DISEASE • POLICY LIMIT 6 100000 A TN LAID MARINE QUIPMENT POLICY R 643140 % 12/31/2000 12/31/2001 TOOLS 520,000 LEASED EQUIP S501000 DESCRIPTION OF OPERATIONS(LOCATIONSMEHICLIWIiXCLUSIONS ADDED BY ENDORSEMENTISPECIAL PROVISIONS CERTIFICATE HOLDER I I ADDITIONAL INSURED'. INSURER LETTER: SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL _ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO WE LEFT, BUT FAILURE TO MAD. SUCH NONE SHALL IMPOSE NO OBUGATI N OR LLAMTY OF ANY, D UPON THE COMPANY. ITS AGENTS O P NT i91-d 10 d M-1 089S-889492 30NYmNi S11YM NAIdYHO 83M311H RYH918-9Ud VW80:S0 10-SO-NYf CLP Project No. 2000-4501 Proposal of C z ,Z O� �f (hereinafter called "Bidder")" a corporation, organized and existing under the laws of the State of ," a partnership, or an individual doing business as to the City of La Porte, Texas (hereinafter called "Owner"). Ladies and Gentlemen: The Bidder, in compliance with your invitation for bids for the construction CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 99-00 per plans and . specifications prepared by the City of La Porte, and having examined the plans and specifications with related documents and the site of the proposed work, and being familiar with all of the conditions surrounding the construction of the proposed project including the availability of materials and labor, hereby proposes to furnish all labor, materials and supplies and to construct the project in accordance with the contract documents, within the time set forth therein, and at the prices stated in the attached Bid Schedule. These prices are to cover all expenses incurred in performing the work required under the contract documents, of which this proposal is a part. Bidder hereby agrees to commence. work under this contract on a .date to be specified in written "Notice to Proceed" of the Owner and to fully complete the project within 4;2 Q consecutive calendar days thereafter as stipulated in the specifications. Bidder further agrees to pay as liquidated damages, the sum of $100.00 for each consecutive calendar day thereafter as provided in Paragraph SC-0 of the Supplementary Conditions of the Agreement. Bidder acknowledges receipt of the following addendum: DATE: 4 - 3'0 -01 Bid Proposal Page 1 of 4 BASE BID PROPOSAL BASE PROPOSAL: Bidder agrees to perform all of the work shown on jhe plans and further described in the specifications for the sum of T�h/ sew ocsci.,cP in—,, Q,.- ,✓z!. Z. 'V ems_._ '-9-S_ dollars,($ 9-71�/. ©o 'T. (Amount shall be shown in both words and figures. In case of discrepancy, the amount shown in words will govern.) Bidder understands that the Owner reserves the right to reject any or all bids and to waive any informalities in the bidding. The bidder agrees that this bid shall be good and may not be withdrawn for a period of thirty (30) calendar days after the scheduled closing time for receiving bids. Upon receipt of written notice of the acceptance of this bid, bidders will execute the formal contract attached within ten (10) days and deliver a Surety Bond or Bonds as required by the General Conditions. The bid security attached in sum of. dollars ($ ) is to become the property of the Owner in the event the contract and bond are not executed within the time above set forth, as liquidated damages for the delay and additional expense to the Owner caused thereby. Respectfully submittp BY: 'off JJ Jignature of Authorized Person) not Name of Authorized Person) (SEAL) (Title) 9-3S 4?(/.94'Y (Business Address) -/&./fTo�/, 7 . 770J� (City) (State) (Zip Code) (7/3-9li9. (Telephone Number) Bid Proposal Page 2 of 4 STATEMENT OF MATERIALS AND OTHER CHARGES, MATERIALS INCORPORATED INTO THE PROJECT: ALL OTHER CHARGES: TOTAL: $ ai3aa•40. $ $ S"7/�/• ©c7 . This total must agree with the total 'Total Amount Bid" figure shown on the bid sheet. For purposes of complying with 'the Texas Tax Code, the Contractor agrees that the charges for any material incorporated into the project in excess of the estimated quantity provided for herein will be no less than the invoice price for such material to the Contractor. Bid Proposal Page 3 of 4 BID SCHEDULE CLP Project No. 2000-4501 CITY-WIDE SIDEWALK REPLACEMENT PRO, Item Description Unit Estimated Unit Total No. Quantities Price 1.0 Concrete Sidewalk Removal LF 1979.8 complete in place 5-00 �A per L 2.0 4' wide concrete sidewalk LF 1387.1 complete in place do a 7711-.1- Co per 3.0 Wheelchair ramps EA 39 complete in place' �Gr�.Qp /%SHOO. oe per' ERCC 4.0 Extra Bank Sand (ordered by city) TN complete in place .S'0 • ca @i�jper 5.0 Extra Sod (ordered by city) SY complete in place C2-9S @ lc 10 �Oatcfgr d- per Total `X1 y S,, vim, prig /z,,6&,5/2" e--7J- ($ 9-7/1,t/- ©O I& - Bid Proposal Page 4 of 4 CLP Project No. 2000-4501 Proposal ofBill McDonald Cons t�pgike &Merl(Wed 'Bidder")' a corporation, organized and existing under the laws of the State of Texas " a partnership, or an individual doing business as to the City of La Porte, Texas (hereinafter called "Owner"). Ladies and Gentlemen: The Bidder, in compliance with your invitation for bids for the construction CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 99-00 per plans and specifications prepared by the City of La Porte, and having examined the plans and specifications with related documents and the site of the proposed work, and being familiar with all of the conditions surrounding the construction of the proposed project including the availability of materials and labor, hereby proposes to furnish all labor, materials and'supplies and to construct the, project in accordance with the contract documents, within the time set forth therein, and at the prices stated in the attached Bid Schedule. These prices are to cover all expenses incurred in performing the work required under the contract documents, of which this proposal is a part. . Bidder hereby agrees to commence work under this: contract on a date to be specified in written "Notice to Proceed" of the Owner and to fully complete the project within 120 . consecutive calendar days thereafter as stipulated in the specifications. Bidder further agrees to pay as liquidated damages, the sum of $100.00 for each consecutive calendarday thereafter as provided in Paragraph SC-6 of the Supplementary Conditions. of the Agreement. . Bidder acknowledges receipt of the following addendum: N/A DATE: 4/30/01 Bid Proposal Page 1 of 4 BASE BID PROPOSAL BASE PROPOSAL: Bidder agrees to perform all of the work shown on the plans and further described in the specifications for the sum of sixty Thousand six Hundred aouars ($ 6o, 637. 6o ). (Amount snail De snown in of discrepancy, the amount shown in words will govern.) case Bidder understands that.the Owner reserves the right to reject any or all bids and to waive any informalities in the bidding. The bidder agrees that this bid shall be good and may not be withdrawn for a period of thirty (30) calendar days after the scheduled closing time for receiving bids. Upon receipt of written notice of the acceptance of this bid, bidders will execute the formal contract attached within ten (10) days'and deliver a Surety Bond or Bonds as required by the General Conditions. The bid security attached in sum of Three Thousand Thirty One Dollars contract and bond are not executed" within the time above set forth, as liquidated damages for the delay and additional expense to the Owner caused thereby. Respectfully submitted BY: (Signature utho ' Person) . Robert Gonzales rent Name of Authorizedarson (SEAL) President (Title) 702 Old Underwood (Business Address) Deer Park TX. 77536 (City) (State) (Zip Code) 281-479-3030 (Telephone Number) Bid Proposal Page 2 of 4 STATEMENT OF MATERIALS AND OTHER CHARGES MATERIALS INCORPORATED INTO THE PROJECT: ALL OTHER CHARGES: TOTAL: $ 14,500.00 $ 46,137.60 $ 60,637.60 This total must agree with the total 'Total Amount Bid" figure shown on the bid sheet. For purposes of complying with the Texas Tax Code, the Contractor agrees that the charges for any material incorporated into the project. in excess of the estimated quantity provided for herein will be no less than the invoice price for such material to the Contractor. ri 0 Bid Proposal Page 3 of 4 BID SCHEDULE CLIP Project No. 2000A501 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 200-2001 Item Description Unit Estimated Unit Total No. Quantities Price 1.0 Concrete Sidewalk Removal LF 1979.8 complete in place 9.00 17, 818. 20 @ Nine nnllarc per T'noar Fnnr 2.0 4' wide concrete sidewalk LF 1387.1 complete in place 14.00 19, 419.40 @ Fourteen Dollars per Linear Foot 3.0 Wheelchair ramps EA 39 complete in place 600.00 23, 400.00 @ Six Hundred Dollars per Fah 4.0 Extra Bank Sand (ordered by city) TN complete in place 18.00 @ _Filghtapn nnllara per Ton 5.0 Extra Sod (ordered by city) SY complete in place 5.00 @ Five Dollars per Square Yard Total 41 xty Thcrosand Six Hundred Thirty ($ 60, 637. 60 ) Seven Dollars and Sixty Cents Bid Proposal Page 4 of 4 ^i CLP Project No. 2000-0501 Proposal of A44(;r1UW eRI1oNS/11G (hereinafter called "Bidder")` a corporation, organized and existing under the laws of the State of rfxas ,' a partnership, or an individual doing business as to the City of L_a Porte, Texas (hereinafter called "Owner"). Ladies and Gentlemen: The Bidder, in compliance with your invitation for bids for the construction CITY-WIDE SIDEWALK, REPLACEMENT. PROJECT FY 99-00 per plans and specifications prepared by the City of La Porte, and having examined the plans and specifications with related,documents and the. site of the proposed work, and being familiar with all of the conditions surrounding the construction of the proposed project including the availability i � .e riar1 ;id labW, hai el,y prtip`9ses to,fLunish-all labor, matenals Vntf ar,4 �'�•{� 'ib�nldOClltG � Oad=tlmwlltc8ntsVA in. Vg' it:TtE .CK-, . forth therein, and, at the prices `stated in the attached Bid Schedule. These.prices are to cover all expenses incurred in performing the work required under the contract documents, of which this proposal is a part. Bidder hereby agrees to commence work under this contract on a date to be 04 specified in written "Notice to Proceed" of the -Owner and to fully complete the project within / 6O consecutive calendar days thereafter as stipulated in the specifications. Bidder further agrees to pay as liquidated damages, the sum of $100.00 for each consecutive calendar day thereafter as provided in Paragraph SC-0 of the Supplementary Conditions of the Agreement. Bidder acknowledges receipt of the following addendum: —� — DATE: Bid Proposal Page 1 of 4 BASE BID PROPOSAL BASE PROPOSAL: Bidder agrees to perform all of the work shown on the plans - and further described in the specificatiops for the sum of .rix 7W41 s.�.✓v dollars ($ Y 4. L 70. 8o ). (Amount shall be shown in both words and figures. In case of discrepancy, the amount shown in words will govern.) Bidder understands that the Owner reserves the right to reject any or all bids and to waive any informalities in the bidding. The bidder agrees that this bid shall be good and may not be withdrawn for a period of thirty (30) calendar days after the scheduled closing time for receiving bids. Upon receipt of written notice of the acceptance of this bid, bidders will execute the formal contract attached within ten (10) days and deliver a Surety Bond or Bonds as required by the General Conditio ns _.. t . Ifie bid.•seeurity attached i dollars ($ ) is to become the property of the Owner in the event the —J contract and bond are not executed within the time- above set forth, as liquidated damages for the delay and additional expense to the Owner caused thereby. Re5jaectfully submitted - BY (Signature of Authorized P n) DA✓IO RAIII&cOY not Name of Authorized arson (SEAL) P09" /owr ' (Title) 9217 KA7Y Fv Y ,Surd /30 (Business Address) M"SAW TX 77oZy (City) (State) (Zip Code) 713 4C62. - 9,90 8 (Telephone Number) Bid Proposal Page 2 of 4 iSTATEMENT OF MATERIALS AND.OTHER CHARGES c MATERIALS INCORPORATED INTO THE PROJECT: $ sy 9� ALL OTHER CHARGES: , $ TOTAL: $ .4 This total must agree with the total'Total Amount Bid" figure shown on the bid sheet. Ror purpnsEs' of .compfyrn '. il�l� 1. Trx i „Tax Code, the C6ritractor,'agreea•_ that, thu chargesforc any :m.^ter. vrlCrpt �titc: tiie project in osss: of the -�ss�fAted. quantity provided,for herein will be no less than the invoice price'for such material to the Contractor. ti Bid Proposal Page 3 of 4 i BID SCHEDULE CLIP Project No. 2000-4501 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 200-2001 Item Description Unit ' Estimated Unit Total No. Quantities Price 1.0 Concrete Sidewalk Removal LF 1979.8 complete in place 9 te 47-78 @ ; Tctn/ Dv GG irzs a per c Ni:c• Fod7 2.0 4' wide concrete sidewalk LF 1387.1 complete in place @ 1r emir,## ao GG� s ., per r ' i.(J„a Yyiiaei riirrasnps . - I. - 39 Per 4.0 Extra Bank Sand (ordered by city) TN :> complete in place @ T/4127Y f%cLLAyQ�S 5.0 Extra Sod (ordered by city) SY complete in place „ o. per SLi ✓,4,'tC YWY-O q J Total Bid Proposal Page 4 of 4 City of La forte Established 1892 June 4, 2001 Mr. Ramiro Pedraza Curb Planet, Inc. 835 Arvana Houston, Texas 77034 RE: Notice of Non -Award CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO. 20004501 Dear Mr. Pedraza: The City of La Porte has awarded the above referenced project to Brooks Concrete of Pasadena, Texas. Thank you for your time and efforts in preparing your proposal for this project. I would like to encourage your participation in future projects. Sincerely, Carlos E. Martinez, Engineer I Planning Department cc: Doug K. Kneupper, P.E. — Director of Planning Reagan McPhail, Public Improvements Coordinator Correspondence file 0 604 W. Fairmont Pkwy. • La Porte, Texas 77571 • (281) 471-5020 - ---- City of La Porte Established 1892 rEXAS June 4, 2001 Mr. Robert Gonzales Bill McDonald Construction, Inc. 702 Old Underwood Deer Park, Texas 77536 RE: Notice of Non -Award CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO. 2000-4501 Dear Mr. Gonzales: The City of La Porte has awarded the above referenced project to Brooks Concrete of Pasadena, Texas. Thank you for your time and efforts in preparing your proposal for this project. I would like to encourage your participation in future projects. Sincerely, Carlos E. Martinez, Engineer I Planning Department cc: Doug K. Kneupper, P.E. — Director of Planning Reagan McPhail, Public Improvements Coordinator Correspondence file 604 W. Fairmont Pkwy. # La Porte, Texas 77571 - (281) 471-5020 I �o�i':i 1 rt�rt`pO City of La Porte F Established 1892 L' TEXA$ June 4, 2001 Mr. David Brinkley Southern Customs, Inc. 9219 Katy Fwy. Houston, Texas 77024 RE: Notice of Non -Award CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO. 2000-4501 Dear Mr. Brinkley: The City of La Porte has awarded the above referenced project to Brooks Concrete of Pasadena, Texas. Thank you for your time and efforts in preparing your proposal for this project. I would like to encourage your participation in future projects. Sincerely, Carlos E. Martinez, Engineer I Planning Department cc: Doug K. Kneupper, P.E. — Director of Planning Reagan McPhail, Public Improvements Coordinator Correspondence file 604 W. Fairmont Pkwy. • La Porte, Texas 77571 • ' (281) 471-5020 a City of La Porte Established 1892 TEXAS June 4, 2001 Mr. Tommy Pitts Ideal Construction Services, Inc. P.O. Box 2915 Sugar Land, Texas 77487 RE: Notice of Non -Award CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO. 2000-4501 Dear Mr. Pitts: The City of La Porte has awarded the above referenced project to Brooks Concrete of Pasadena, Texas. Thank you for your time and efforts in preparing your proposal for this project. I would like to encourage your participation in future projects. Sincerely, Carlos E. Martinez, Engineer I Planning Department cc: Doug K. Kneupper, P.E. — Director of Planning Reagan McPhail, Public Improvements Coordinator Correspondence file 604'W. Fairmont Pkwy. 9 La Porte, Texas 77571 • (281) 471-5020 City of La Porte Established 1892 rE X A`3 June 1, 2001 Mr. Terry Sandlin Brooks Concrete 4018 Allen Genoa Pasadena, TX 77504 (281) 72MO89 RE: Notice to Proceed CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP #2000-4501 Dear Mr. Sandlin: You are hereby notified to proceed with the above referenced contract on or before June 4, 2001, and shall fully complete all of. the work of said contract within 90 consecutive calendar days thereafter. The contract provides for an assessment of the sum of $100.00 as liquidated damages for each consecutive calendar day after the above established contract completion time that the work remains incomplete Sincerely, Carlos E Martinez, Engineer I Planning Department cc: Doug Kneupper, Director of Planning Reagan McPhail, Public Improvements Coordinator 604 W. Fairmont Pkwy. • La Porte, Texas 77571 • (281) 471-5020 I CITY OF LA PORTE CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2600-2001 CLP Project No. 2000-4501 TABLE OF CONTENTS SECTION NO. OF PAGES NOTICETO BIDDERS ............................................................................................................. 1 SCOPEOF WORK ................................................................................................................... 1 INSTRUCTIONS TO BIDDERS ............................................ ................................................... 4 SIDEWALKLOCATIONS ....................................................................................................... 10 BIDPROPOSAL .................................... .................................................................................. 4 AGREEMENT...... ..................................................................................................................... 2 PAYMENTBOND ........................................................................ I .......................................... 2 PERFORMANCEBOND ........................................................................................................... 2 GENERAL CONDITIONS ........................................................................................................ 42 SUPPLEMENTARY CONDITIONS .. ...................................................... I ............................... 10 TECHNICAL SPECIFICATIONS ....................... a .................................................................... 19 NOTICE TO BIDDERS CLP Project No. 2000-4501 Sealed bids, in duplicate, on the original forms, signed by an officer of the Company, and addressed to Martha Gillett, City Secretary, City of La Porte, 604 W. Fairmont Parkway, P.O. Box 1115, La Porte, Texas 77572-1115 will be received until 2:00 PM, April 30, 2001, for the construction of. CITY OF LA PORTE CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 CLP PROJECT NO.2000-4501 2. Bidders are requested to attend a pre -bid conference to be held in the Council Chambers at City Hall, 604 W. Fairmont Parkway, La Porte, Texas, April 23, 2001, at 10:00 AM. 3. Interested contractors may obtain plans, specifications and necessary bidding information at no cost from: CITY OF LA PORTS PLANNING DEPARTMENT 604 W. FAIRMONT PARKWAY LA PORTE, TEXAS 77571 (281) 471-6020 4. Each PROPOSAL shall be accompanied by a cashier's check, certified check, or bid bond from a surety company licensed in the State of Texas in an amount not less than five percent (5%) of. -the total amount bid, asa guarantee that the successful bidder will enter into a Contract and execute the Bond(s) if required, within ten (10) days after the receipt of the Contract Documents. 5. The City of Porte.hereby notifies all bidders that in regard to any Agreement entered into pursuant to..this advertisement, minority business enterprises will be afforded equal opportunities to submit bids in response to. this invitation and will not be discriminated against on the grounds of race, color, sex, age, religion or national origin in consideration for an award. 6. The Owners reserve the right to reject any and all bids and to waive informalities in bidding. In case of ambiguity or lack of clearness in stating the prices in the bid, the Owner reserves the right to consider the most advantageous construction thereof or to reject the bid. CITY OF LA PORTE Martha Gillett Notice to Bidders Page 1 of 1 SCOPE OF WORK. CLP Project No. 2000-4501 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Project consists of the removal of existing sidewalks and replacement being with either sidewalk or wheelchair ramps. Wheelchair ramps shall meet the minimum criteria as established by the American Disabilities Act. Removed concrete shall become the property of the contractor and removed from the site. Performance and Payment Bonds shall be required for this project. Scope of Work Page 1 of 1 INSTRUCTIONS TO BIDDERS CLP Project No. 2000-4501 RECEIPT AND OPENING OF BIDS The City of La Porte (herein called "Owner"), invites bids on the form attached hereto, all blanks of which must be appropriately filled in. Bids will be received by the Owner at the office of the City Secretary, until the time and date indicated within the NOTICE TO BIDDERS, and then at said office publicly opened and read aloud. The envelopes containing the bids must be sealed and addressed to Martha Gillett, City Secretary at P.O. Box 1115, 604 W. Fairmont Parkway, La Porte, Texas 77571. The Owner may consider informal any bid not prepared and. submitted in accordance with the provisions hereof and may waive any informalities or reject any and all bids. Any bid may be withdrawn prior to the above scheduled time for the opening of bids or authorized postponement thereof. Any bid received after the time and .date specified shall not be considered. No bidder may withdraw a bid within thirty (30) days after the actual date of the opening thereof. PREPARATION OF BID Each bid must be submitted on the prescribed form. All blank spaces for bid prices must be filled in, in ink or typewritten, in both words and figures, and must be fully completed and executed when submitted. Each bid must be submitted in duplicate in a sealed envelope bearing on the outside the name of the bidder, his address, and the name ofthe project for which the bid is submitted. If forwarded by mail, the sealed envelope containing the bid must be enclosed in another envelope, address as specified in the bid form. The bidder is specifically advised that any person, firm, or other party to whom it is proposed to award a subcontract under this contract must be acceptable to the Owner. Bidders may not subcontract more than fifty percent (50%) of the work. TELEGRAPHIC MODIFICATION Any bidder may modify his bid by telegraphic communication at any time prior to the scheduled closing time for receipt of bids, provided such telegraphic communication is received by the Owner prior, to the Dosing time and, provided further, the Owner is satisfied that a written confirmation of the telegraphic modification of the bidder was mailed prior to the closing time. The telegraphic communication should not reveal the bid price but should provide the addition or subtraction or other modification so that the final prices or terms will not be known by the Owner until the sealed bid is opened. If written confirmation is not received within two (2) days from the closing time, no consideration will be given to the telegraphic modification. . Instructions to 6ldders, Page 1 of 4 INSTRUCTIONS TO BIDDERS QUALIFICATIONS OF BIDDER The Owner may make such investigations as he deems necessary to determine the ability of the bidder to perform. the work, and the bidder shall fumish to the Owner all such information and data for this purpose as the Owner may request. The Owner reserves the right to reject any bid if the evidence submitted by, or investigation of, such bidder fails to satisfy the Owner that such bidder is properly qualified to carry out the obligations of the contract and to complete the work contemplated therein.. Conditional bids will not be accepted. BID SECURITY Each bid must be accompanied by a cashier's check, a certified check of the bidder, or a bid bond prepared, duly executed by the bidder as principal and having as surety thereon a surety company approved by the Owner, in the amount of five percent (5%) of the bid. Such checks or bid bonds will be returned to all except the three (3) lowest bidders within three (3) days after the opening of bids, and the remaining checks or bid bonds will be returned promptly after the Owner and the accepted bidder have executed the contract, or, if no award has been made within thirty. (30) days after the date of the opening of bids, upon demand of the bidder at any time thereafter, so long as he has not been noted of the acceptance of his bid. LIQUIDATED DAMAGES FOR FAILURE TO ENTER INTO CONTRACT The successful bidder, upon his failure or refusal to execute and deliver the contract and bonds required within ten (10) days after he has received notice of the acceptance of his bid, shall forfeit to the Owner, as liquidated damages for such failure or refusal, the security deposited with his bid. TIME OF COMPLETION AND LIQUIDATED DAMAGES Time is of the essence in' this project and the contractor must diligently pursue the construction of the work so as to offer it for final acceptance by the Owner within the time limit specified in the proposal. Liquidated damages of $100.00 per day shall be chargeable for each day the work remains incomplete past the stated time limit. CONDITIONS OF WORK Each bidder must inform himself fully of the conditions relating to the construction of the project and the employment of labor thereon. Failure to do so will not relieve a successful bidder of his obligation to furnish all material and labor necessary to carry out the provisions of his contract. Insofar as possible the contractor, in carrying out his work, must employ such methods or means as will not cause any interruption of or interference with the work of any other contractor. ADDENDA AND INTERPRETATIONS Instructions to Bidders, Page 2 of 4 INSTRUCTIONS TO BIDDERS No interpretation of the ,meaning of the plans, specifications or other pre -bid documents.will be made to any bidder orally. Every request for such interpretation should be in writing addressed to "City of La Porte, Attn: Planning Department, P.O. Box 1115, La Porte, Texas 77572-1115" and to be given consideration must be received at least five (5) days prior to the date fixed from the opening of bids. Any and all such interpretations or any supplemental instructions will be in the form of written addenda to the specifications which, if issued, will be mailed by certified mail with return receipt requested to all prospective bidders (at the respective addresses furnished for such purposes), not later than three (3) days prior to the date fixed for the opening of bids. Failure of any bidder to receive any such addendum or interpretation shall not relieve such bidder from any obligation under his , bid as submitted. All addenda so issued shall become part of the contractdocuments. CONTRACT SECURITY The Contractor shall be required to furnish performance and payment bonds, executed on the forms enclosed herein, each bond in an amount at least equal to one hundred percent (100%) of the total contract price, as security for the faithful performance of the contract and for the payment of all persons performing labor or furnishing materials and equipment on the project. NOTICE OF SUPPLEMENTAL GENERAL CONDITIONS AND SPECIAL CONDITIONS Attention is particularly called to those parts of the contract documents and specifications which deal with the following: a.. Survey, Permits and Regulations b. Protection of Work and Property C. Time of Completion and Liquidated Damages d. ' Subsurface Conditions Found Different e. Insurance f. Separate Contract . g. Subcontracting h. Photographs of the Project LAWS AND REGULATIONS The bidder's attentionis directed to the fact that all applicable State laws, municipal ordinances, and the rules and regulations of all authorities having jurisdiction over construction of the project shall apply to the contract throughout, and they will be deemed to be included in the contract the same as though herein written out in full. METHOD OF AWARD - LOWEST QUALIFIED BIDDERS If at the time this contract is to be awarded, the lowest base bid submitted by a responsible bidder does not exceed the amount of funds then estimated by the Owner as available to'fnance the contract, the contract will be awarded on the base bid only. If such bid exceeds such amount, the Owner may reject all bids. Instructions to Bidders, Page 3 of 4 INSTRUCTIONS TO BIDDERS The Owner further reserves the right to award the contract based on an adjusted base bid, which shall consist of any combination of alternate bid items and bid items included in the base bid. CERTIFICATION BY BIDDER The successful bidder will be furnished with a copy of .City of La Porte Ordinance #98-2217, prohibiting any expenditure for goods or services by the City of La Porte from any person, firm,_ or corporation owing any delinquent indebtedness to the City. The successful bidder will be required to certify that it Js in compliance with the requirements. of said ordinance. If the bidder is not in compliance with Ordinance #98- 2217, it will assign to the City of La Porte, the amount of its delinquent indebtedness to the City of La Porte, to be deducted by the City of La Porte from the amounts due. Failure to remit this certification or non-compliance with said ordinance shall be just cause for rejection or disqualification of bid. OBLIGATION OF BIDDER At the time of the opening of bids, each bidder will be presumed to have inspected the site and to have read and to be thoroughly familiar with .the plans and contract documents (including all addenda). The failure or omission of any bidder to examine any form, instrument or document shall in no way relieve any bidder from any obligation in respect to his bid. SAFETY STANDARDS AND ACCIDENT PREVENTION With respect to all work performed under this contract, the Contractor shall: (1) Comply with the safety standards provisions of applicable laws, building and construction codes and the "Manual of Accident Prevention in Construction" published by the Associated General Contractors of America, and the requirements of the Occupational Safety and Health Act of 1970 (Public Law 91-596). (2) Exercise every precaution at all times for the prevention of accidents and the protection of persons (including employees) and property. (3) Maintain at his office -or other well known place at the job site, all articles necessary for giving first aid to the injured, and shall make standing arrangements for the immediate removal to a hospital or a doctor's care of persons (including employees), who may be injured on the job site. In no case shall employees be permitted to work at a job site before the employer has made a standing arrangement for removal of injured persons to a hospital or a doctor's care. Instructions to Bidders, Page 4 of 4 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Fairmont Park Central E. Side of Farrington between Catlett & Belfast Sidewalk 23.2 In front of Riauto Elementary ,. Sidewalk 30.0 TOTAL 53.2 L.F. Catlett Drive 10330 10306 Belfast Drive 10318 10238 10238 10302 Winding Trail Drive 10350 16330 10403 10407 10411 Collingswood 10410 10419 10434 Sidewalk Sidewalk TOTAL Sidewalk Sidewalk (placement only) TOTAL WCR "D" (removal) . WCR °D° (removal) Sidewalk Sidewalk Sidewalk Sidewalk Sidewalk Sidewalk Sidewalk Sidewalk TOTAL TOTAL 17.0 19.7 36.7 L.F. 5.6 16.4 22.0 L.F. 39.0 22.0 61.0 L.F. 8.0 8.0 15.6 36.5 10.6 78.7 L.F. 16.0 13.5 8.0 37.5 L.F. Sidewalk locations, Page 1 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Fairmont Park West Wilmont Drive REMOVAL 9803 -:Sidewalk & WCR "A" 26.7 10115 WCR "B" 17.9 3810 WCR "A" 13.4 381.1 WCR "A" 14.6 TOTAL 72.6 L.F. Rustic Gate Drive 9934 WCR "B" 24.0 TOTAL 24.0 L.F. Shell Rock Drive 9946 WCR "B" 17.2 TOTAL 17.2 L.F. Clairmont Drive 9751 WCR "A" 23.5 10003 WCR "A" 17.7 TOTAL 41.2 L.F. Dover Hill Drive 9927 WCR "A" 24.2 .10002 WCR "A" 23.3 TOTAL 47.5 L.F. Stonemont Drive 10003 WCR "A" 22.8 10002 WCR "A" _ 23.6 TOTAL 46.4 L.F. Parkmont Drive 3411 WCR "B" 23.8 TOTAL 23.8 L.F. Hillridge Drive 10119 WCR `A" 13.5 TOTAL 13.5 L.F. Sidewalk locations, Page 2.of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Fairmont Park East REMOVAL NW Comer Fleetwood & Malberry WCR 7.1 NE,Comer Fleetwood & Idlewood WCR 7.9 NE Comer Fleetwood & Dogwood WCR 7.3 NW Comer Fleetwood & Dogwood WCR 7.3 SE Comer Fleetwood & Dogwood WCR 7.4 SW Comer Fleetwood & Dogwood WCR. 7.5 NE Comer Fleetwood & Linwood WCR 9.1 NW Comer Fleetwood & Linwood WCR 16.5 SW Comer Fleetwood & Linwood WCR 7.6 TOTAL 77.7 L.F. Sidewalk locations, Page 3 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Brookalen/Col leaewiew 8294 Oak Haven Sidewalk & WCR "A" 8835 Oak Haven ' WCR "A" 8523 Ashwyne Sidewalk & WCR "A" 8519 Bandridge Sidewalk & WCR'A" 3219 Fernrock Sidewalk & WCR "A" 3215 Gladwyne Sidewalk 8502 Lazy Brook WCR "B" ' 8415 Lazy. Brook Sidewalk 8518 Lazy Brook Sidewalk (relocate w/meter) 8511 Lazy Brook-3842 Fair Brook Sidewalk 20.9 Removal 12.0 Removal 26.8 Removal 24.4 Removal 20.8 Removal 35.4 9.0 Removal 38.0 26A 15.9 Y Sidewalk locations, Page 4 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Glen Meadows Crestway Street 4910 Sidewalk 4.0 4913-4917 Sidewalk 41.7 4925 Sidewalk 12.3 4926 Sidewalk 4.0 5009 Sidewalk 4.0 5218 Sidewalk 7.8 TOTAL 73.8 Valley View 5222 Sidewalk 7.4 5210 Sidewalk .4.0 5114 Sidewalk 7.4 5101 Sidewalk 4.0 4921 Sidewalk 4.0 4913 Sidewalk 13.9 TOTAL 40.7 Meadow Place 5013 Sidewalk 17.2 5206 Sidewalk 7.7 5217 Sidewalk 17.1 TOTAL 42.0 L.F Glen Valley 5201 Sidewalk 4.0 5117 Sidewalk. 19.1 5110 Sidewalk 4.0 4929 Sidewalk 3.3 4926 Sidewalk 5.3 TOTAL 35.7 L.F. Meadow Crest. 4901 Sidewalk 6.5 5209 Sidewalk 4.0 Sidewalk locations, Page 5 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Glen Meadows (Continued) 5218-5214 Sidewalk 8.0 5226-5222 Sidewalk 29.8 TOTAL 48.3 L.F. Creek View 5226 Sidewalk 10.8 5221 Sidewalk 9.1 5202 Sidewalk 4.0 4933 Sidewalk 15.6 4929 Sidewalk 14.7 4925 Sidewalk 4.0 TOTAL 58.2 L.F. Sidewalk locations, Page 6 of 10 CITY-WIDE.SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Monument Estates Mission Street 1415 1211 1223 Bexar Street .11703 11711 Crockett Street 11720 11723 11738 Alamo Street 11735 11731 =Sidewalk (saw -cut) 4.0 Sidewalk 3.9 Sidewalk (saw -cut) 4.0 TOTAL 11.9 L.F. Sidewalk 17.5 Sidewalk 10.6 TOTAL 28.1 L.F. Sidewalk 6.3 Sidewalk 6.6 Sidewalk (saw -cut) 4.0 TOTAL 16.9 L.F. Sidewalk 17.0 Sidewalk 16.3 TOTAL 33.3 L.F. Sidewalk locations, Page 7 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Town of La Porte NW comer "E' & S. Lobit NE comer "E" & S. Carrol NE comer "E" & S. Iowa 521 S. Virginia (on "E') NE comer "E" & S. Virginia NW comer "E" & S. Virginia 515 San Jacinto 222 Broadway 725 Broadway (tennis courts) Oak Leaf 927 922 907 . Silver Springs WCR (removal ) WCR (removal ) WCR (removal) sidewalk WCR (removal) WCR (removal) Sidewalk Sidewalk Sidewalk Shady River Sidewalk Sidewalk Sidewalk 3106 Sidewalk 3103 Sidewalk 3102 Sidewalk Woodland Court 3115 Sidewalk 3102 (on Hollow Tree) Sidewalk Silver Springs 3103 (on Hollow Tree) Sidewalk' 10.9 8.1 . 9.0 8.3 9.9 8.3 4.2. 4.4 79.0 TOTAL 142.1 L. F 4.0 38.2 46.6 78.0 4.0 8.2 Hollow Tree 1002 Sidewalk NW comer Lary Pine & Oak Leaf WCR "B' (removal) TOTAL 21.2 4.0 11.2 53.4 24.1 292.9 L.F. Sidewalk locations, Page 8 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Bayou Glen Briar Glen 206 Sidewalk 4.4 210-208 Sidewalk 12.0 TOTAL 16.4 L.F. Brook Meadow 1605 Brook Meadow Sidewalk . 42.5 9903 Brook View Sidewalk 9.5 9904 Brook Side Sidewalk 4.0 TOTAL 56.0 L.F. CreekMont Stone Creek . 5410 Sidewalk 24.2 5422 Sidewalk 4.7 5510 Sidewalk 5.7 5622 Sidewalk 5.7 Canyon Springs 606 Sidewalk 706 Sidewalk 901 Sidewalk 905(across street). Sidewalk 1102 Sidewalk 1301 Sidewalk 1317 Sidewalk 1401 Sidewalk 742 Sugar Hill Sidewalk 714 Briar Creek Sidewalk 601 Briar Creek (on Sugar Creek) Sidewalk. 5502 Sugar Creek Sidewalk 5413 Sugar Creek Sidewalk 602 Heather Springs Sidewalk 606 Heather Springs (across street)Sidewalk 4.0 4.0 3.7 5.0 5.0 4.6 5.0 6.8 6.6 4.3 12.9 4.2 4.0 4.0 6.8 Sidewalk locations, Page 9 of 10 CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 Rock Springs 5413 Sidewalk 4.7 5421 Sidewalk 5.5 5425 -Sidewalk 30.5 5426 Sidewalk 5.3 5425 Pine Creek Sidewalk 5426 Pine Creek Sidewalk 10006 River Creek Sidewalk 1105 Oak Tree (_across street) Sidewalk 1101 Oak Tree Sidewalk Willow Creek 713 Sidewalk 725 Sidewalk 731 Sidewalk 953 Sidewalk 1009 Willow Creek (across street) 714 Myrtle Creek Sidewalk Sidewalk 5.0 5.0 11.7 8.8 5.4 4.9 5.3 4.7 4.0 4.2 5.8 TOTAL 8$T� 0 Sidewalk locations, Page 10 of 10 IT! . Proposal of J �f 6.1d '140 !(hereinafter called "Bidder')* a corporation •;:;<:i' organized and existing under, the laws of the State of • a partnership; or an individual doing business as %�livTA.�[-Tn.�/ to the City of LaPorte Texas (hereinafter. called "Owner"). Ladies and Gentlemen: The Bidder,. in compliance with your invitation for bids for the.. construction CITY-WIDE ....... SIDEWALK REPLACEMENT PROJECT ' FY 99-0o per plans and specifications. prepared by the City.of La Porte, and having examined the plans and specifications with ' related documents. and the _site of the proposed work, and being familiar with'all of the conditions surrounding. the construction of the proposed project including the availability of :materials and labor, hereby proposes to furnish all labor, materials and supplies and, ;to .construct the project in accordance with the contract documents within the time set •:forth therein, and at. the prices stated in the attached Bid Schedule. These prices are to cover,.; .all expenses incurred'. in performing the work required under the, contract ,documents; of which this, proposal is a part. Bidder herebyagrees to commence work under this contract, on a date to be specified i�ntten "Notice to Proceed" of the Owner and to fully complete the project ithin consecutive calendar days thereafter as stipulated in the specifications. Bidder further agrees to pay as liquidated damages, the sum of $100.00 for each '.consecutive . calendar day thereafter as provided in Paragraph SC-6 of the t . ;. Supplementary Conditions of the Agreement. g r , ... Bidder acknowledges receipt of the following addendum: DATE: Bid Proposal Page 1 of 4 BASE BID PROPOSAL ` BASE PROPOSAL: Bidder agrees to perform all of the Work shown on the plans and further s i the p Gficatio s for a sum o /W& dollars ($ _ ). Amount shall b shown in both words and figures. In case of discrepancy, the amount shown in words will govern.) Bidder understands that the Owner reserves the right to reject any or all bids and to:waive any informalities in the bidding. The bidder agrees that this bid shall be good and may not be withdrawn for a penod of thirty (30) calendar days after the scheduled Dosing time for receiving bids. Upon receipt of written notice of the acceptance of this bid, bidders will execute ..the,formal.contract attached within ten (10) days and deliver a Surety Bond or Bonds as required by the General Conditions. .security attached, in sum of 1 C� lip31% ) is to become the property of the Owner in the event the y'�, " contract and bond are not executed within the time above set forth, as liquidated damages for the delay and additional expense to the Owner caused thereby. Respectfully sub 'tted BY: ass o fl (� (Signaty a of Authorized Person) (City) (State) (Zip Code) (Telephone Number) Bid Proposal Page 2 of 4 STATEMENT OF MATERIALS AND OTHER CHARGES �-''- MATERIALS INCORPORATED INTO THE PROJECT: $ `.::_ ALL.OTHER CHARGES: $ 2Z Y-W , TOTAL: $ 0 i. This total must agree with the total 'Total Amount Bid" figure shown on the bid sheet. For purposes.,of• complying with ,the Texas .Tax Code, the Contractor agrees that the charges :for any material incorporated into the project in excess of the estimated quantity provided for herein will be no less than the invoice price for such material to the Contractor. Bld Proposal Page 3 of 4 CITY-WIDE SIDE BID SCHEDULE CLP Project No. 2000-4501 JALK REPLACEMENT PROJECT FY Item ; • r_' . °,, ', Description, .'. Unit. Estimated Unit .Total,. , No. Quantities Price r ;!A 0.Concrete Sidewalk Removal LF 1979.8 _ complete in place s per, 2.0 4' wide concrete sidewalk LF 1387.1Q7/ i complete in place 19 per �- 3 0 Wheelchair,ramps EA 39 _ complete in place 77J J. per- Me "4:0 :: Extra Bank Sand (ordered by city) TN o; compl.ete.in place /0 per, T,l% 5.0.Extra Sod (ordered by city) SY complete in place E r,; per'.. 11 n .1' :. } ;,;: . • ``{ '.Total ($ o z ,rr;, ,. Bid Proposal Page 4 of 4 AGREEMENT CLP Project No. 2000-4501 THIS AGREEMENT, made this 8"h day of May 2001, by and between the CITY OF LA PORTE, hereinafter called "Owner", acting herein through its CITY MANAGER and Brooks Concrete. Inc. (a corporation)+ of Pasadena , County of Hams , and State of Texas, hereinafter called "Contractor". WITNESSETH: That for and in consideration of the payments and agreements hereinafter mentioned, to be made and performed by the OWNER, the CONTRACTOR hereby agrees with the OWNER to commence and complete the construction described as follows: CITY-WIDE SIDEWALK REPLACEMENT PROJECT CLIP PROJECT NO.2000-45,01 hereinafter called the project, for the Total Price of Twenty six thousand six hundred five and 60/100 dollars ( $ 26,605.60 ) and all extra work in connection therewith, under the terms as stated in the General and Supplementary Conditions of the Contract; and Further, that the CONTRACTOR agrees, at his (its or their) own proper cost and expense, to furnish all the materials, supplies, machinery, equipment, tools, superintendence, labor, insurance, and other accessories and services necessary to complete the said project in accordance with: A The terms and conditions stated in the Proposal and in the General Conditions, and Supplementary Conditions of this Contract; Scope of Work B. The plans, which include all maps, plats, blue prints, and other drawings and printed or written explanatory matter thereof; and C. The Specifications and other contract documents therefore, as prepared by the City of La Porte, all of which are made a part hereof and collectively evidence and constitute the contract. Agreement, Page 1 of 2 AGREEMENT The CONTRACTOR hereby agrees to commence work under this contract on or before a date to be specified in a written "Notice to Proceed" of the Owner and to fully complete the project within 90 calendar days thereafter. The CONTRACTOR further agrees -to pay, as liquidated damages, the sum of 100 for each consecutive calendar day thereafter as hereinafter provided in Paragraph SC-6 of the Supplementary Conditions. IN WITNESS WHEREOF, the parties to these present have executed this contract, each of which shall be deemed an original, in the year and day first above mentioned. A Robert T. Herrera City Manager Title of Signare of Authorized Person Title of Authorized Person Address and Zip Code City of La Porte Name of Owner SEAL Attest: By: U0A tL A, Martha Gillett City Secretary' Title SEAL V V I11 1000 Agreement, Page 2 of 2 - OD1 Western Surety Company PAYMENT BOND Bond Number: 058599351 KNOW ALL PERSONS BY THESE PRESENTS, That we Brooks Concrete. Tnr- _._. of __- 4018 Allen Genoa Rd., Pasadena, TX 77504 hereinafter referred to as the Principal, and _ .. - western Surety Company,.,., , as Surety, are held and firmly bound unto ___ . City of LaPorte Of Box P.O. __ .. 1 ..- }}3, LaPprte, TX 77572-1115 .„ ,hereinafter referred to as the Obligee, in the sum of Twenty-SI x Thpusand,,Si dundred Five and eD/i no _ Dollars ($ 26, 605.60 ), for the payment of which we bind ourselves, our legal representatives, successors and assigns, jointly and severally, firmly by these presents. 14 Ab v 74 WHEREAS, Principal has entered Into a contract with Obligee, dated _.._.. day of Cancrete Sid@Malk Replacement copy of which contract Is by reference made a pert hereof. NOW, THEREFORE, If Principal shall, in accordance with applicable Statutes, promptly make payment to all Persons supplying labor and material In the prosecution of the work provided for in said contract, and any and all duly authorized modifications of said contract that may hereafter be made, notice of which modifications to Surety being waived, then this obligation to be void; otherwise to remain in full force and effect No suit or action shall be commenced hereunder (a) After the expiration of one (1) year following the date on which Principal ceased work on said contract It being understood, however, that If any limitation embodied in this bond Is prohibited by any law controlling the construction hereof such limitation shall be deemed to be amended tm as to be equal to the minimum period of limitation permitted by such law. (b) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project, or any part thereof, is situated, or In the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. The amount of this bond shall be reduced by end to the extent of any payment or payments made in good faith hereunder. SIGNED, SEALED AND DATED this 23rd day of By G•105578-8 May 2001 (Sean izje ' (Seal) Duane Barnes Attomey-in-Fad OD°l Western Surety Company PERFORMANCE BOND Bond Numberr 056599351 KNOW ALL PERSONS BY THESE PRESENTS, That we .__BxogXq goncpr te, Inc. _._ ... _ of 4018 Allen Genoa Rd., Pasadena, X 77 04 , _ , hereinafter referred to as the Principal, and Western Surety Company M� as Surety, are held and finely bound unto City of .LaPorte of P,Q; B,px 1115, LaPorte, Tx 77572-1115 hereinafter referred to as the Obligee, In the sum of Twenty -Six Thousand Six HLndrGd_, Five and 60/300 Dollars (S 26, 60 5. 60 ), for the payment of which we bind ourselves, our legal representatives, successors and assigns, jointly and severally, firmly by these presents. .S. WHEREAS, Principal has entered Into a contract with Obligee, dated the day of A0 , NOW, THEREFORE, if the Principal shall faithfully perform such contract or shall indemnify and save harmless the Obligee from all cost and damage by reason of Principal's failure so to do, then this obligation shall be null and void; otherwise it shall remain In full force and effect. ANY PROCEEDING, legal or equitable, under this Bond may be Instituted In any court of competent jurisdiction in the location In which the work or part of the work Is located and shall be Instituted within two years after Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform Its obligations under this Bond, whichever o=rs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense In the Jurisdiction of the suit shall be applicable. NO RIGHT OF'ACTION shall accrue on this Bond to or for the use of any person or corporation other than the Obligee named herein or the heirs, executors, administrators or successors of the Obligee. SIGNED, SEALED AND DATED this 23rd day of May _-...... _ 2001 Inc. By 1 ke Duane Barnes Attomey4r Feeclt) G-105578-C Western Surety Company POWER OF ATTORNEY - CERTIFIED COPY Bond No. 058599351 Know All Men By These Presents, that WESTERN SDRtitiW COMPANY, a corporation duly organized and existing muter the Iowa of the State of South Dakota, and baring its principal office in Sioux Palls, South Dakota (the 'Compnny % don by these presents make, constitute and appoint R.14ka,D.uane—Rarnne fb tens. sad IawAil atfnrney(o)-in-fhct, with full power and authority hereby cooformd, to execute, acknowledge sad deliver and on its behalf m Surety, bonds for PrindpaL• Brooks, Concrete, Inc. Obligee: City of LaPorte Amount: $26, 605.60 and to bind the Company thereby as fully and to the same extent as if aacb boude were atgnod by the Executin Vice President, sealed with the corporate Beal of the Company and duly attested by its Secretary, hereby ratifying and confirming all that the said _ attorney(e)-in•fhct may do within the above stated limitations. Said appointment is mado ender and by authority of the following bylaw of Western Surety Company which remains in full for= and effect 'Section 7. All bonds, policies, undertakings, Powers of Attorney or other obligations of the corparstio o shah be executed in the oorpmYta name of the Company by the President, Searebry, any Assistant Secretary, Treasurer, or any Pas President or by such other officere as the Board of Ditactere may suthnrtza. The Prmidant, any Pane President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shag have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seat is not necessary for the validity of any bonds, polices, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such dfiwr, and the corporate seal may be printed by facefmt7e,' All authority hereby conferred shall expo+ and terminate, without notice, unless used before midnight of _... A%%gty9Lt__2—, 2001. „ _ but until such time shall be irrevocable and in full force and effect. In Witness Whereof. Wmtarn Surety Company has mused these presents to be signed by its Executive Vice President Stephen T. be affixed this —Z3Lfl_ day of May 2001 , WESTER COM NY 27 pben T. Pate, Executive Vim President ST1 A 1 w rouri'kY•,• Jj m On this 23rd day of ..J _.._,M9Y-.__, in the you 2001 , before me, a notary public, personally appeared Stephen T. Para, who being to me duly Sworn, acknowledged that he signed the above Power of Attorney as the aforesaid oTmor of WEMM M SURL'IT COMPANY and acknowledged said instrument to be the voluntary art and deed of opid corporation. •,,,w.w,.,,.,r,w.,w,,, t f D. n KRELL xau m puauc . t 8o0rH Notary Public - South Dakota My Commission Fxpi m November 30, 2006 I the unt"rotgned officer of Wasbta Surety Company, a stack corporation of the State of South Dakota, do hereby certify that the attached Power of Attorney is in full force and effect and is irrevocable, and furthermore, that Section 7 of the bylaws of the Company as sot forth in the Power of Attorney is new in force. In tesMtimony whereof; I have hereunto ant my hand and seal of Western Surety Company this ....... day of 2441. WESTER S RETX C- _ T Fora, phen T. Pato, Executive Vice Fteadent 'tLiJNSENT TO RATE APPLICATION for FIDELITY, SURETY AND GUARANTY BONDS AND POLICIES GOVERNED UNDER ARTICLE 5.15 IMPORTANT: A SEPARATE APPLICATION MUST BE FILED ON EACH POLICY OR BOND NAME OF SUBMITTING COMPANY: Western Surety Company ADDRESS: 950 Echo Lane #250. Houston. Texas 77024 TO: TEXAS DEPARTMENT OF INSURANCE . --' Bond Department M C/1 04-1 B P.O. Box 149104 Austin, Texas 78714-9104 Date: May 23, 2001 In accordance with the provisions of Article 5.15 (c), Texas Insurance Code, as amended, application is hereby made for approval of rates or premiums. greater than Department standard or our company filed rates or premiums, as follows: 1. Name and Address of Principal or Risk: hooks Concrete. Inc.. 4018 Allen Genoa Rd., Pasadena, TX 77504 2. Policy or Bond: (a) -Effective Date: May 23, 2001 (b) Policy or Bond No.: 058599351 (c) Bond (Contract, Fin. Inst., Lic., & Permit, etc.): Contract (d) Bond Type (Pert., Pymt., Form 24, Mixed Bev., etc.): Performance & Payment (a) Obligee: City of LaPorte (f) Job Name or Number: Concrete Sidewalk Replacement (g) Penalty of Bond: $26.605.60 (h) Type of Contract (Class A, Class A-1, Class B): A-1 (1) Other (Explain): 3. Coverage to be written at rates or Dremiums nraater than standard nr rmmnanv filed ratan nr nmmii tme- Complete (a). (b), c or d STANDARD or COMPANY FILED RATES or PREMIUMS XCESS RATES or PREMIUMS a Entire Risk; or $9.40 per M 2.5%Flat (b) Portion of Risk (name portion) ;or c Covers a ;or d Other TOTAL PREMIUM $ 66 4. Keasons for requiring rates or premiums greater than standard or company filed rates: O'Aaft of Financial Statement Dngog Net Warrant gtandert CorinmdAratInn 5. 1 (We) hereby consent to approval by the Department of rates or premiums for insurance greater than the standard rates or premiums that have been approved by the Departmenj. Signature of nsure on o zed Act for Insured) Notes: (1) THIS APPLICATION MUST BE COMPLETED 11 FUL AND THE ORIGINAL WITH ONE COPY FILED WITH THE TEXAS DEPARTMENT OF INSURANCE. (2) Consent rates or, premiums greater than standard or company filed rates or premiums should be expressed either In dollars or in percent above Department standard rates or premiums. (3) If additional space is required to clearly show the proposed rating procedures, use reverse side of this form for explanation. FORM NO. BCC002 (10-96) GENERAL CONDITIONS CLP Project No. 2000-4501. respect to its completion or modiArntion. GENERAL CONDITIONS CONSTRUCTION CONTRACT Prepared by Engarleers Joint Contract Documents Committee and Issued and Published Jointly By t \M W lr V eOtltl C\� PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A practice division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS AMERICANN CONSULTING ENGINEERS COUNCIL AMERICAN SOCIETY OF CIVIL ENGINEERS CONSTRUCTION SPECIFICATIONS INSTITUTE This document has been approved"and endorsed by The Associated General .a Contractors of America These General Conditions have been prepared far use with the Owner�ontraeior Agrr_ments (No. 1910-8-A-1 or 191048 A-2) (1990 Editions). Their provisions are interrelated and a change in one may necessitate a change in the others. Comments concerning their usage are contained in the. Commentary on Agreements for Engineering Savica and Contract Documents (No. 1910.9) (1986 Edition). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (No. 1910-M (1990 Edition). When bidding is involved, the Standard Form of Instructions to Bidders (No. 1910-12) (1990 Edition) may be used. n 9 ICDC No. 19104 (1990 Edition) wed S91 C 1990 National Society of Professional Engineers 1420!I{ing Street, Alexandria, VA =314 American Consulting Engineers Council 1015 15th Sweet, N.W., Washington, DC 20005 American Society of Civil Engineers -345 East 47th Street, New York NY 10017 Construction Specifications Institute 601 Madison St., Alexandria, VA 22314 TABLE 0, NTE2N7S OF GENERAL CONDITIONS brick or Paragraph Dumber & 7-ak N DEFINITIONS .............................:..... LI Addenda .:........................... 1.2 Agreement ........................... 13 Application for Payment ..............' 1.4 Asbestos ............................. ISBid ..................................'. 1.6 Bidding Documents ................... 1.7. Bidding Requirements ................ 1.8 Bonds ................................ 1.9 Change Order .............. :......... 1.10 Contract Documents :................. I.11" Contract Price................tract 1.12 Cones ....................... Tun I. CONTRACTOR ...................... 1.14 defective ......... :.................... 1.13 Drawings ......:'............ 1.16 Effective Date of the Agreement ...... 1.17 ENGINEER ...'....................... 1.18 ENGINEER's Consultant ............. 1.19 Feld Order .................... ........ 1 20' Genetal'Requirements ................ IMHazardous Waste ........... ;......... Ir Laws and Regulations; Laws or Regulations .................... 1.�9' Liens ................................. 1.24 Milestone ............................. I?S Notice of Award .........:............ 1.26 Notice to Proceed .............:...... 137 OWNER ............................. 128 Partial Utilization ..................... 1.29 PCBs ................................. 130 Petroleum .................. :......... 131 Project ............................... 132 Radioactive Material ...... :........... 133 en Resident Project Representative ....... 134 Samples ..................: I........... 135 Shop Drawings....................... . 136 Spec�tions ............. `:... . 137 Subcontractor ......................... 138 Substantial Completion ............... 139 Supplementary Conditions............ 1.40 Supplier .............................. 1.41 Underground Fae'Gdes .........:....:. 1.42 Unit Price Work .... :................. 1.43 Work ................................. 1.44 Work Change Directive ............... 1.45 Written Amendment .................. 2. PRELIMINARY MATTERS ....................... 2.1 Delivery of Bonds ..... :.............. 2 2 Copies of Documents .:............... 2.3 Commencement of Contract 7m=: Notice to Proved .......... .... 2.4 Starting the Work ..................... Pare ruaber 13 13 13 13 13 13 ....13 13 113 13 13 13 13 13 13 13 13 . 13 13 13 14 14 14 14 14 14 14 14 14 14 14 14 14 14 14 14 14 14, 14 14 14 14 14 Is 15 15 15 I5 Is U is Article or Paragraph Number & rule 2.5-2.7 Before Starting Construction: CONTRACiDR's Responsibility to Report Preliminary Schedules: Delivery of Certificates of Insurance........................ Page Number 2.8 Bteconsnvcuon Conference ........... L9 Initially Ac=epmWc Schedules ......... 3. CONTRACT DOCUMENTS: INTENT. AMENDING. REUSE ............... .......:...... 3.1-3.2 ..'latent .... :............ ............... 33 Reference to Standards and ' Specifications of Tedudc:d Societies; Reporting and Resolving . Discrepanciesi 3.4 ................... Intent of Certain Terms or Adjectives .. 33 Amending Contract Documents ...:... 3.6 Supplementing Contract Documents ... 3.7 Reuse of Documents .................. 4. AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICALCONDITIONS;REFERENCEPOINTS . 4.1 Availability of Lands ...............:.. 43 Subsurface and Physical Conditions ... 4 2.1 Reports and Drawings ................ 4? 7 Limited Retiaoce by CONTRACTOR . Authorized; Technical Data ...::.... 4.23 Notice of Differing Subsurface or Physical Conditions ........:........ 4-3:4 ENGINEER's Review ................ 41S Possible Contract Documents Change . 43.6 Possible Price and Times'Adjustments . 43 PhysicatCondntions-Underground. Facilities ........................... 43.1 Shown or Indicated ................... 4.33 Not Shown or lndioted .............. 4.4 Referee¢ Points ...................... 4.5 Asbestos. PCBs; Petroleum: Hazardous Waste or Radioactive Material .....'. 5. BONDS AND INSURANCE .........`............ 5.1-5 2 Performance. Payment and Other Beads . 5.3 I nccesed Sureties and Insurers; Certificates of Insurance .:..::...... 5.4 CONTRACTOR's Liability Insurance . 5.5 OWNER's Liability Insurance ........ 5.6 Propetry,Insuranee ................... 5.7 Boner and Machinery or Additional Property Insurance ................. 3.8 Notice of Canmccfl, on Provisions ..... 5.9 CONTRACIDR's Responsibility for Deductible Aiiaoumits ................ 5.10 Other Special Insurance ............... 5.11 Waiver of Rights ...................... 15 15 16 16 16 16 17 17 17 17 17 17 17 17 18 18 18 IS 13 18 18 19 19 19 M 20 20 ' 71). 21 21 21 21 22 22 Article or Paragraph Page Article. or Paragraph Page Number & Title Number 'Number & T-uie Number 5.12-5.13. Receipt and Application of Insurance &6 Change Orden ....:.................. Z Proceeds ................ ;.......... ?: 8.7 inspections. Tests and Approvals ...... 29 5.14 Acr_ptance.of Bonds and Insurance; 8.8 Stop or Suspend Work; Terminate Option to Replace ................. ,s CONTRACTOR's Scrvices ......... 29 5.15 Partial Uttiization-Ptoperry 8.9 Limitations on OWNER's Insurance .....................:.... 23 Responsibilities ..................... 30 8.10 Asbestos PCBs, Pt uolatm. hazardous 6. CONTRACTOR'S RESPONSIBILITIES ......... +.3 Wane or Radioactive Material ...... 30 6.1.6 2 Supervision and Superintendence ...... M 9.11 Evidence of Finannial Arrangemeam 30 6.3-6.5 6.6 LaboA Materials and Equipment ...... Progress Schedule '23 23 9..ST ST ENGINEER'S STATUS DURING 6.7 .................... Subsrinues and "Or -Equal" Items: CONSTRUG' ON .............................. • 3o CONTRACTOR's Ex Expense;. 9.1 OWNER's Representative ............ 30 Subsduae.Constntction 93 visits to Site ...............:.......... 30 Methods or Procedures; 9.2 Project Representative ................ 30 ENGINEER'S Evaluation 23bari6atioas 9.4 C and Interpretations ....... 30 6.&A.11 """"" Concerning Subcontrctors, aSuppliers 9.5 Authorized Variations in Work """" 30 and Others; Waiverof Rights ... .... +4 9.6 - Rejecting Defective Work .......:..... 30 � 6.1_ Patent Fees and Royalties ............. ; 3 9.7.9.9 Shop Drawings, Change Orders and 6.13 .................. Permits """"""' '3 Payments '...... .......... ....... :.... 31 L 14 Laws and R Regulations ''""""""" + 3 9.10 Des mninations for Unit Prices 31 6.16 Taxes ...................... 25 9.I!-9.I2 Decisions on Disputes; ENGLNEER ns ER a 6.16 Premises Use of Preanses ....:................. 26 Initial Interpreter ................... � . 31 6.17 Site Cleanliness ....................... 26 9.13 Limitations on ENGINEER's 6.18 Safe Structural Loading ............... 26 Authority and Responsibilities ...... 31 6.19 Record Documents ................... 26 6.20 Safety and Protection ................. 26 10. CHANGES IN THE WORK ..................... 32 6.21 Serfcry Representative ............ 26 10.1 OWNER Ordered Change ............ 32 6?? ..... Hazardmu Comaicatian Pro �� ""' Z7 0 10_ Llaun for Adjustment ................. 32 6.23 Emergencies ........ :..... ......... 10.3 Wort Not Required by Contract 6_+4 Shop Drawings and Samples 27 Documents ......:............ ...... 32 6.25 Submittal Procedures; 10.4Change Orders CONTRACIOR's Review Prior to 10.5 - Notination of Sure Surety .....,........... 32 Shop Drawing or Sample Submittal .. 27 11. CHANGE OF CONTRACT PRICE .............. 32 6.26 Shop Drawing & Sample Submittals 11.1-I1 Contract Price; Claim for Adjustment;: Review by ENGINEER ............ 27 Value of the Work ................... 32 6_+7 Responsibility for Variation From 11.4 Cost of the Work ..................... 33 Contract Documents ................ 27 11.5 Exclusions to Cost of the Work ....... 34 618 Related Work Performed Prior to 11.6 CONTRACTOR's Ice ................ 34 ENGINEER'S Review and Approval . 11.7 Cost Records :....... ................. 34 of Required Submittals ............... 27 11.8 Cash Allowances ... :................. 35 6.29 Continuing the Work .................. 28 11.9 Unit Price Work ...................... .35 630 ... ''CONTRACTOR's General Warranty and Guarantee ............ 28 12..CHANGE OF CONTRACT TIMES .............. 35 631-633 Indemnification ....................... 28 12.1 Claim for AQpsstiaent :.....;:.......... 35 634 Survival of Obligations ................ 28 12 1 Tune of the Essence .................. 35 123 Delays Beyond CONTRACIOR's 7. OTHER WORK .................................. 29 Control .....................:...... 35 7.1-7.3 Related Work at Site .................. 29 12.4 Delays Beyond OWNER'a and 7.4 Coordination CONTRACTOR's Control .......... 35 & OWNER'S RESPONSIBILITIES ................. 29 8.1 Communications to Conuacmr ........ 29 13. TESTS AND INSPECTIONS; CORRECTION, 8_2 Replacement of ENGINEER .......... 29 REMOVAL OR ACCEPTANCE OF DEFECTIVE 83 Furnish Data and Pay Promptly When WORK .......................................... 36 Due ......... ....................... 29 13.1 Notice of Defects ..................... 36 8.4 Lands and Easements Report: and 13.2 Access to the Work Tests ............................... 29 133 Tests and Inspections; Contrrctor's 8.5 Insurances ............................. 29 Cooperation ........................ 36 rticle or Paragraph Page .:amber & Tale Number 13.4 OWNER's Responsib0'ides: Independent Testing Laboratory .... 13.5 CONTRAC,TOR's Responsibilities ..... 13.6-13.7 CoveringWork Prior to Inspection. Testing or Approval ................ 13.8-13.9 • Uncovering Work at ENGINEER's Request -....... .................... ' 13.10 OWNER May Stop the Work ......... 13.11 Correction or Removal of Defective Worst.... .................... 13.12 Correction Period ..................... ' 13.13 Aceepmncc of Defective Wort ........ 13.14 • OWNER -May Correa Defective Wort ............................... 1. PAYMENTS TO CONTRACTOR AND COMPLETION ..........:.........:............ I4.1 Schedule of Values ...::............... 14.2 -Application for Progress Payment ..... 143 CONTRAC TOR's Warranty of Tide ... 14:4714.7 Review of Applications for Progress Payments ................. 14.9-14.9 Substantial Completion ......... 14.10 Partial Utill"tton :............. ....... 14.11 Finallnspec'on ........... 36 36 36 36 36 37 37 37 37 37, 38 38 38 39 39 39 .3 Article or Paragraph Page Number & 77t1e Number 14.12 Final Application for Payment ......... 40 14.13-14.14 Fuel Payment and Acceptance ........ 40 14.15 Waiver of Claims ..................... 40 IS. SUSPENSION OF WORK AND TERMINAMON................................ 40 15.1 OWNER May Suspend Work "......... 4o 15345.4 OWNER May Terminate .............. 40 15-S CONTRACTOR May Stop Work or Terminate .......................... 41 16. DISPUTE RESOLUTION ....................... 41 17. MISCELLANEOUS ............................. 17.1 Giving Notice ........................ 17.2 Computadon of Times .....:.......... 17.3 Notice of Claim ...............:. 17.4 Cumulative Remedies ................. 17-5 Professional Fees and Court'Costs Included..........:..........:...... EXHIBTT,GC-A (Optionan: Dispute Resolution Agreement (Optimmo ..... GC -Al 16.1-16.6 Arbitration ...............:.... GC -AI . 16.7 Mediation ..................... GC-A2 0 42 42 42 . �n 42 12 INDEX TO GENERAL CONDITIONS Article or Paragraph Number Acceptance of - Bonds and Insurance ................................. 5.14 defective Work ....................... 10.4.1, 13.13. 13.15 final payment .................. :.............. 9.12. 14.15 insurance........................................5.14 other Work by CONTRACTOR ...................... 73 Substitutes and -Or-Equal- Items .................. 6.7.1 Work by OWNER ........................ 2J, 630. 634 Access to the - Lands, OWNER and CONTRACTOR tbtlitiu respons....................:................ 4.1 site, related work .................................... 71 Work .................................... t3 I3.14. I4.9 Acts or Omissions Acts and Omissions - CONTRACTOR ............................. 6.9.1.9.133 ENGINEER................................6.20.9.133 OWNER ....................................... 6.20. 9.9 Addenda -definition of (also see definition of Specifications) ........... Additional Property Insurances ......................... 5.7 Adjustments Contract Price or Contract Tune ......... 1.5. 3.5. 4.1, 43143?. 4.5.3. 9.4, 9.5, 10.2-10.4. 11. 12. 14.8, 15.1 progressschedule .................................... 6.6 Agreemeni- definition of .......................................... 1 2 All risk Insurance, policy form ......................... 5.6 2 Allowances. Cash............; ......................... 11.8 Amending Contract Documents ......................... 3.5 Amendment. Written - in general .... 1.10. 1.45, 3J, 5.10. S.12. 6.6.2. 6.83. 6.19. 10.1. 10.4. 11? 12.1, 13.11 14.7.2 Appeal. OWNER or CONTRACTOR intent to .............. :....... 9.10, 9.11. 10.4. 16.2. I6J Application for Payment- ' definition of ........' .................................. 13 ENGINEER's Responsibility ......................... 9.9 final payment .................. 9.13.4. 9.13.5. 14.12-14.15 in general ....................... 2.8. 7-9. 5.6.4. 9.10. I53 Progress Payment .............................. 14.1, 14.7 reviewof ...................................... 14.4.14.7 Arbitration (Optional) ...............'............... 16.1-16.6 Asbestos - claims pursuant thereto ..........4.5.2.4.5 ............. 3 CONTRACTOR authorized to stop Work ........... 4.5.2 definition or .......................................... 1.4 OWNER responsibility, for .................... 4.5.1. 8.10 passable price and times change ..................... 4-5.2 Authorized Variations in Work ........-.. 3.6.6.25.6.27.9.5 valabt'liry of Lands ............................... 4.118.4 Award. Notice -of -defined ............................. 1.25 Before, Starting Construction ........................ 2 5-2.8 Hid -definition of ..................................:... 1J. (1.1. 1.10. 2J, 3.3. 4.2.6.4. 6.13. 11.43, 11.9.1), Article or Paragraph Bidding Downtyfinit me-deion of .... Number ............ 1.6 (6.8.2) Bidding Requirements -definitions of ...... 1.7 (1.1, 4?.6.2) Bonds - acceptanceof ....................................... 5.14 additional bands ..... ......................•103, 11.43.9 Cost of. the Work ... ..................:............ 113:4 definitionof .......................................... 1.8 . delivery of ...................................... final application for payment .................. 14.12-14.14 general ...............1.10, 5.1-53. 5.13, 9.13.10.5, 14.7.6 performance, payment and Other ................. 5.1-5 2 Bonds and Insurance -in general ......................... 5 Builders risk "al risk" policy form ..... :.............. 5.6 2 Cancellation Provisions, Insurance ........ 5.4.1 l., 5.8, 5.15 . CashAllowances ...................................... 11.8 Certificate of Substantial Completion ....... 138, 6.30.2J, 14.8. 14.10 Certificate of Inspection ................ 9.13.4. 13.5, 14.12 Certificates of Insurance .. 2.7. 53, 5.4.11, 5.4.13, 5.65, 5.8. ...... :............... 5.14, 9.13.4, 14.12 Change in Contract Price. - Cash Allowances ................................... 11.8 claim for price adjustment ..... 4.1. 4? 6, 43, 5.15, 6.8=, 9.4. 9.5, 9.11, 10.2. 10.5. 11.7, 13.9. 13.13, 13.14, 15.1, 15.5 CONTRACTOR's fee ............................... 11.6 Cost of the Work general...................................... 11.4-11.7 Exclusionsto .......................... _............ 11.5 CostRecords .....................:................. 11.7 in general .............. 1.19, 1.44, 9.11. 10.4.2. 10.4.3. 11 Lump Sum Pricing ................................ 11:3.2 Notification of Surety ..:................. :.......... 10.5 Scope of ....................................... 103-10.4 Testing and Inspection. Uncovering the Work ........ 13.9 UnitPrice Work .........................:.......... 11.9 Valueof Work ....................................... 11.3 Change in Contra= Time- Claim for time adjustment .... 4.1, 41.6, 4.5. 5.15. 6.83, 9.4. 9.5. 9.11. to 10J. 12.1. 13.9. 13.13. 13.14, 14.7. 15.I. 15.5 Contractual time limits .................:............ 12.2 Delays beyond CONTRACTOR': control ............ 123 Delays beyond OWNER': and CONTRACiOR's con- trol..............................................: 12.4 Notification of surety ................................10.5 Scrape of than Change Orders -- Acceptance or Defective Work ..... :...:.. ..... :... 13.13 Amending Contract Documents ..................... 3.5 Cash Allowances ................................... 1I.8 Change of Contract Price ............................. I Change of Contact Tunes ...........:................ 12 Changes in the Work .................................... 10 CONTRACTOR': fee ............................... 11.6 Cost of the Work ............................... 11.4-11.7 ,...icle or Paragraph Number Article or Paragraph Number Cost Records ....................................... 11.7 definition of .......................................... 1.9 emergencies ............. :................. ......... 6 ?3 ENGINEER's responsibility .......... 9.8. 10.4. 11.2.12.1 execution of.......:.................................10.4 Indemnification ..................... 6.12 6.16. 631. 633 Insurance. Bonds and ....................5.10.5.13, I03 OWNER may terminate ........................ 151-15.4 OWNER's Responsibility .......................8.6. 10.4 Physical Conditions- ' Subsurface and . ............................ :......... 4 Underground' Facilities 1::.....................:.. 43 2 Record Documents........... ...:................... 6.19 Scope of Change ............................... 103 10.4 Substitutes ..........................:........ 6.73.6.8 Unit Price Work .............. :..................... 11.9 value of Work. covered by ... :....................... 11.3 Changes in the Work ...................................... 10 Notification of surety ................................. 10.5 OWNER's and CONTRACTOR'S responsibillties .... 10.4 Right- to an adjustment .............................. 10.2 Scope of change ............................... 103-10.4 Claims- . against CONTRACTOR .............. ......6.16 against ENGINEER ..... :.......................... 632 against OWNER ..................................... 632 Change of Contract Price :...................... 9.4. 11.2 Change of Contract Times ...................... 9.4.. T_'.l CONTRACTOR's 4.7.1. 9.4. 9.5. 9.11. 101 ILL 11.9. 121. 14.8. 15.1. 15.5. 17-3, CONTRACTOR's Fr...............................'11.6 CONTRACTOR's liability ............ 5.4. 6.12. 6.16. 631 Cost of the Work ......... :..................... I IA. 11.5 Decisions on Disputes ...:..................... 9.11. 9.12 Dispute Resolution .................:................ 16.1 Dispute Resolution Agreement .................. 16.1.16.6 ENGINEER as initial interpretor................:.... 9.11 Lump Sum Pricing ...........: .................... 11.3.2 Notice of ............................................ 173 OWNER's ........... 9.4. 9.5. 9.11. 10? II_'. 11.9, 12-1. 13.9. 13.13. 13.14, 173 OWNER's liability ................................... 5-5 OWNER may refuse to make payment .............. 14.7 Professional Fees and Court Costs Included........... 17.5 request for formal decision on ........................ 9.11 Substitute items ............. :....................... 6.7.1.2 Time Extension .............:....................... 12.1 Time requirements ............................ 9.11. 12.1. Unit Price Work .................................. 11.93 Valueof .............................................. 113 Waiver of -on Final Payment ................ 14.16. 14.15 Work Change Directive ............................. 10 written notice required ................... 9.11. ILL 12.1 Clarifications and Interpretations ..... '...... 3.63. 9.4, 9.I I Clean Site ............................................ 6.17 Codes o(Technical Society, Organization or Association ...................................... 333 Commencement of Contract Tithes ..................... 23 Communications - general.................................... 6.16.91, 8.1 Hazed Communication Programs ................... 6.n Completion - Final Application for Piyttwu.................'...... 14.12 Final Inspection ................................... 14.11 Final Payment and Accwmtrce ...........:... 14.13-14.14 Partial UuTrretion.................................. 14.10 Substantial Completion ................... 138. 14.8-14.9 Waiver of Claims ................................... 14.15 Computation of Times ........................1721-173_1 Concerning Subcontractors, Suppliers and Others ............... I ,........ _6A-6 11 Conferences -- initially actable schedules .........................2.9 pteconsuuaion...................................... 2.8 Conflict. Error, Ambiguity. Discrepancy - CONTRACTOR to Report ..::......:. 2-5. 33 2 Construction, before starting by CONTRACTOR .... 2.5-27 Construction Machinery. Equipment. etc ................ 6.4 Continuing the Work ....... .:.... Contract Documents Amending...........................•................ 3.5 Bonds............................................... 5.1 Cash Allowances ................................... 11.8 Change of Contract Price ............................. 11 Change of Contract Times ........................ "' 12 Changes in the Work .........:.................. I0.4-10.5 check and verify..............................:1...... 25 Clarifications and Intapmntions ....... 33. 3.6. 9.4. 9.11 definition of ......................................... 1.10 ENGINEER as initial interpreter of ................. 9.11 ENGINEER as OWNER's representative ............ 9.1 general .................:.........................::... 3 Insurance............................................ 53 Intent............................................ 3.1-3.4 minor variations in the Work ......................... 3.6 OWNER's responsbStty to furnish data .............. 9-3 OWNER's responsibility to.make prompt payinent ....................... 8.3. 14.4, 14.13 precedence ....................................3.1.333 Record Documents ................................. 6.19 Reference to Standards and Specifications or Techhnical Societies .............................. 33 Related Work ........................................ 7-2 Reporting and Resolving Discrepancies ........... 2.5. 33 Reuse of ..........:................................... 3.7 Supplementing ........................... :..:......... 3.6 Termination of ENGINEER's Employment ........... 82 Unit Price Work ..................................... 11.9 variations ................................. 3.6, 6 23, 6_'77 Visits to Site. ENGINEER's .........I.............:...9.2 Contract Price- 4(ijiutmeat of ................ 3.5, 4.1, 9.4, 103, 11.2-113 Change of ............................................. I Decision on Disputes ............................... 9.11 definition of ........................................ 1.11 Contract Times- adjustmeni of .................... 3.5. 4.1, 9.4. 103. 12 Change of.... .....................:............. 11.1-124 J Article or Paragraph Number Commencement of ......: ............................ 23 definitionof ........................................ 1.12 CONTRACTOR - Acceptance of Insurance ..........................:. 5.14 Limited Reliance on Technical Dan Authorized ..... 4-2 Communications ............................... 6.16.9 2 Continue Work ................................. 6.29.10.4 coordination and scheduling .......................c.6.92 definition of ........................................ 1.13 May Stop Work or Terminate ....................... 15-5 provide site acmes to others ......................7 2 131 Safety and Protection ....... 4.3.1.2. 6.16, 6.18. 621:6 3, 72,.13.2 Shop Drawing and Sample Review Prior to Submittal . 6Z5 Stop Work requiremenrs ............................ 4-52 CONTRACTOR's- Compensation.................................. 11.1-11 2 Continuing Obligation .............................. 14.15 Defective Work .......................... 9.6. 13.10-13.14 Duty to correct defective Work ..................... 13.11 Duty to Report - Changes in the Work caused by Emergency....................................... 6.3 Defects in Work of Others ......................... 7.3 Differing conditions...................:...........4.23 Distmepanry:in Documents :.......... 2 5. 3.3.16.14.2 Underground Facilities not indicted ............:. 43 2 Emergencies........................................ 6.3 Equipment and Machinery Rental, Cost of the Work ........... :....................... 11.4-5.3 Fr--Cost-Plus ..................... 11.45.6. 11.5.1. 11.6 General Warranty and Guarantee .................... 630 Hazard Communication Programs .................. .6.= Indemnification ...............:...... 6.12:6.16. 631-6.33 Inspection of the Work ......................... 7.3, 13.4. Labor, Materials and Equipment :................. 6343 Laws and Regulations, Compliance by ............. 6.14.1 Liability Insurance .................................... 5.4 Notice of Intent to Appeal .:.:................. 9.10. 10.4 obligation to perform and complete the Work ........ 630 Parent Fees and Royalties, paid for by ............... 6.12 PerformanG and Other Bonds ........................5.1 Permits. obtained and paid for by .................... 6.13 Progress Schedule ..... 2.6, 2.8, 19, 6.6, 6.29.10.4. 1521 Request for formal decision on disputes ..............9.11 Responsibilities - Changes in the Work .............................. 10.1 Concerning Subcontractors, Suppliers and - Others . 6.8- 6.11 Continuing the Work ........................ 6.29. 10.4 CONTR4CIOR's expense ....................... 6.7.1. CONTRACIUR's General Warranty and Gumn- tee............................................. 630 CONTRACTOR's review priorto Shop Drawing or Sato-. pie submitd .. 6?5 Coordination of Work .............................. 6.9 2 Emergencies ...................................... 623 ENGINEER's evaluation. Substitutes or "Or -Equal' Items .......................... 6.73 Article or Paragraph Number For Acs and Omissions of Others...... 6.9.1.6.92.9.13 for deductible amounts, insurance .................. 59 general .......................:......... 6.7.17.3. 89 Hazardous Communication Programs ............. 62_'' Indemnification..............................631.6.33 Labor. Materials and Equipment ................. 6 34.5 Laws and Regulations ............................ 6.14 Liability Insurance .................................. 5.4 Notice of variation from Contract Documents ..... 6_n Patent Fen and Royalties ......................... 6.12 Permits .....................::.............:...... 6.13 ProgressSchedule ................................. 6.6 Record Documents .......:....................... 6.19 related Work performed prior to ENGINEER's approval of required submittals .................. 628 safe structural loading ............................ 6.18 Safety and Protection :.................. 6.20, 7.113.2 Safety Representative ............................. 6.21 Scheduling the Work •............................. 6.92 Shop Drawings and Samples ...................... 6.24 Shop Drawings and Samples Review . by ENGINEER ................................ 616 Site Cleanliness ........................... :....... L17 Submittal Procedures ............................. 6.25 Substitute Construction Methods and Procedures .................................... 6.i2 Substitutes.and "Or -Equal" items ................ 6.7.1 Superintendence.................................... 6.2 Supervision ......................................... 6.1 Survival of Obligations .........:.................. 6.34 Tries............................................ 6.15 Tess and lnsp=dors ............................: 13.5 ToReport ....................:.................... 2-5 Use of Premises .................... 6.16-6.18. 6.30.2.4 Review Prior to Shop Drawing or Sample Submittal .. 625 Right to adjustment for changes in the Work ......... 102 right to claim .. 4. 7.1. 9.4. 9.5. 9.11, 10.2. 11 1, 119. 12.1. 13.9. 14.8. 15.1. 15.5. 173 Safety and Protection ................. 6.20-6= 7.2. 13.2 Safety Representative ............................... 6_1 Shop Drawings and Samples Submittals ......... 624428 Special Consultants ............................... 11.4.4 Substitute Construction Methods and Procedures ..... 6.7 Substitutes and "Or -Equal- Items. Expense .. 6.7.1, 6.7 2 Subcontractors. Suppliers and Others ............ 6.&6.11 Supervision and Superintendence ........... 6.1. 6) 621 Taxes, Payment by .......................... :....... 6.15 Use of Premises ................................ 6.16d18 Warranties and guarantees ...................... 630. 6.5 Warranty of Title ................................... 143 Written Notice Required - CONTRACTOR stop Work or terminate ........... 15.5 Reports of Differing Subsurface and Physical Condi- tions ............................................. 4=1 Substantial Completion ........................... 14.8 CONTRACTORS -other ................................. 7 Contractual Liability Insurance ..................:... 5.4.10 Contractual Time limits ....:'L ..................... I Coordination A-.___- or Paragraph Number Article or Paragraph Number . CONTRACMIX's responsibility .................... 6.9 2 Copies of Documents ...:........................ Correction Period .................................... 13.12 Conrction. Removal or Acceptance of Defective Work in general ............................. 10.4.1. 13.10.13.14 Aceepr nce of Defective Work ..................... 13.13 Correction or Removal of Defective Work ..... 630. 13.11 Correction Period .................................. 13.12 OWNER May Correct Defective Work ............. 13.14 OWNER May Stop Work .......................... 13.10 Cast - of Tests and Inspections.............................13.4 Records............................................ 11.7 Cast of the Work-, Bonds and insurance, additional ................. 11.43.9 ..................... Cash Discounts ................................. .......... .I ... 11.4.2 CONTRACIUR's Fc .............................. 11.6 Employee Expenses...........................:..11.4.5.1 Exclusions to ....................................... 113 General ........................................ 11.4.1i_5 Home office and overhead expenses ................. 11.5 Lasses and damages ............................. 11.43.6 Materials and equipment ......:................... 11.3 2 Minor expenses ................................. 11.45.8 Payroll costs on changes .......................... IIAA performed by Subcontractori ...................... 11.4.3 Recasts ............................................ 10 Rentals of construction equipment and machinery . 11.4.53 Royalty payments, permits and license fees ...... 11.4-5.5 Site'ofiice and temporary facilities ............... 11.4-5.2 'Special Consultants, CONTRACMR's ............ 11A.4 Supplemental ..................................... 11.4.5 Taxes related to the Work ....................... 1-1.43.4 Tests and Ins pecuon................................ 13.4 TradeDiscounts .....................:............ 11.4r Utilities, fuel and sanitary facilities ............... 11.4.5.7 Work after regular hours .....................:.... 11.4.1 Covering Work .................................... 13.6.13.7 Cumulative Remedies .... ............... :........ 17.4-17.5 Cutting, lining and patching ............................ 73 Darn, to be furnished by OWNER ...................... 9.3 Day -definition of .................................... 17''_' Decisions on Disputes ........................... 9.11, 9.12 defective-definiuon of.................................1.14 defective Work - Acceptance of .............................. 10.4.1. 13.13 Correction or Removal of ................... 10.4.1. 13.11 Correction Period .................................. 13.12' in general ................................. 13, 14.7. 14.11 Observation by ENGINEER ......................... 9.2 OWNER May Stop Work ...............:.......... 13.10 Prompt Notice of Defects .................:......... 13.1 Rejecting ............................................ 9.6 Uncovering the Work ............................... 139 Definitions ............................................... I Delays .................................. 4.1. 6.29. 123-12.4 Delivery of Bonds ...................................... 2.1 Delivery of certificates of insurance ..................... 1.7 Determinations for Unit Prices ........................ 9.10 Differing Subsurface or Physical Conditions Notice of .........:........... ENGINEER's Review ........ :.................... 4.14 Possible Contra Doaune= Change ............... 4.2.5 Possible Price and Tunes Adjustments .............. 4.2.6 D'isercpaneim-Reporting and Resolving .... 2.5. 3.3 2 6.14 2 Dispute Resolution - Agreement ..................................... 16.1-16.6 Arbitraion..................................... 16.1-165 general :... 16 Mediation .......................................... 16.6 Dispute Resolution Agreement .................... 16.1-16.6 Disputes, Decisions by ENGINEER .............. 9.11-9.12 Documents - Copies of ... :...........:............................ 2 Record............................................. 6.19 Reuseof .............:............................... 3.7 Drawings -definition of ............................... 1.15 Easements ................:.- "...................... 4A Effective date of Agr=ment-definition of ............. 1.16 Emergencies .......................................... 6.23 ENGINEER- ' as initial interpreter on disputes ................. 9.11-9.12 definition of ........ :................................ 1.17 Limitations on authority and responsi'blities..................................9.13 Replacementof ...................................... 8.2 Resident Project Representative ...................... 93 ENGINEER's Consultant -definition of ............... 1.18 ENGINEER'S - authority and responsibTry, limitations on ........... 9.13 Authorized Variations in the Work .................... 9.5 Change Orders, responsibility for .......... 9.71 10, 11, 12 Clarifications and Interpretations ............... 3.63. 9.4 Decisions on Disputes .......................... 9.11-9.12 defective Work noticeof ........................... 13.1 Evaluation of Substitute Items ...................... 6.73 Liability ....................................... 6.32, 9,12 Notice Work is Acceptable ......................... 14.13 Observations ................................. 6M.7 9.2 OWNER's Representative ...........................9.1 Payments to the CONTRACTOR. Respoanbiliiry, for ..................... :........ 9.9.14 Recommendation of Payment ................. 14.4, 14.13 RcsNnsibliues= limitations oo ........................:...... 9.11-9.13 Review of Report/ on Differing Subsurface and Physical Conditions .....................:.... 424 Shop Drawings and Samples. review responsibility .....................................6-16 Status During Construction - authorized variations in the Work .................. 9J CWifiations and Interpretations ................... 9.4 Deeisions'on Disputes .......................... 9.11-9.12 Detetmmadons on Unit Price .. 9.10 ENGINEER as Initial Interpreter ............ 9.11-9.12 ENGINEER'S Responsibilities ................ 9.1-9.12 F Article or Paragraph Number "tazions on ENGINEER's Authority and Responsibilities ................................... 9.I3 OWNER's Representative ......................... 9.1 Project Representative ....... Rejecting Defective Work ................... 93 .. Shop Drawings, Change Orders andcad ............... 9.6. Payments .......I ................. ....... 9.7-9.9 Visits to Site 9.2 Unit Price Determinations ................... Visits to Site 9 9.2 Written consent required Equipment, Labor, Materials ......................... nd 7.2 9.1 EgtnPmeat n=W' Cost of the Work ....... .....' 1.4.5.3 Equivalent Materials and Equipment ...................... 6.7 Errors or omissions 6 7 missions .......... � ' Evidence of Financial Arran ... 633 Explorations of h eeoneas ................... 8.11 �' CO Physical conditions ......'............. 4.2.1 Fad Order - definition TRACTOR s--CostrPlus .................... 11.6 definition of ...... issued by ENGINEER .......... ...... ..... 1.19 Final A 3.6 1.95 PPiiation for Payment ...........:..::.....:., 14.12 Final Inspection ....:.......:..:. Finial Payment- 14.11 and Acceptance .....................:..:..... 14.13-14.14 Pricer to, for cash allowances •.........:.:. 11.8 General Provisions ... ::.:...........:...: 173 17.4 General Requirements- defintion of ....... Principal references to . 1.20 Giving Notice .................... ..................... 1134 Guraruee of Work-by.1 a, ..... 2.6. C4, 6.6 6.7, 6 CONTRACTOR .............................. 630. 14.12 Hazard Communication Programs ILaaMous Waste- 6 » definition of ..............................: 13I ...... general ............................................. 4.5 OWNER's responsibility for ... :............... ..... 9.10 Indemnification............. .. 6.12.6.16, 631-633 tni[tapy Aecptable Schedules .............::...........I.9 Inspection- . Ccrt • of ......................... 9.13.4, 135. 14.12 Final ............................................... 14.11 SP=Tests i, required al ENGINEER ..................... 9.6 Tess and Approval .... ....................8.7, 13.313.4 Instrtanee- Acceptance oG by OWNER ..........................5.14 Additional, required by changes in the Work .....:............... Before I I A.59 .s._taJrlin.g the waif' :............................ 2.7 Bonds and -in general ................................. 5 CanC.-potion Provisions .. 5.8 ........ Cerufiatei of .. 2.7. S. 53, 5.4.1I,'5.4.13, 5.6.S. 9.13.4, 14.12 CompletedRA TOR's operations .. it'y .*...................... 5.4.13 CON2 R AC7UR's L iabilty ...........:............... 5.4 CONTRACIOR's objection to Coverage ............. 5.14 Con°acwW Liability ................... :............. 5.4.10 Article or Paragraph deductible amounts, amounts. CONTRACIOR's - responsibility ..................................... 5.9 Final Application for Payment .....................: 14.12 Licensed [niter; ........:. ...............:...... 5.3 :vatic requirements, material changes ......................:.....: . 5.8. 10.50 Option to Replace other special insurances .... S.14' OWNER as fiats 5.10 Y far insureds .............. 5.12-5.13 OWNER's Liability .......... . 5.5 OWNER's Responsibility ........................... BS Partial Utilization, Property Insurance .. .. Property .................. 5.15 ...... 5.6-5.10 Receipt and Application of Insurance pr Special lnsormce ...::................ems .. 5.12-5.13 Waiver of Rights5.10 Intent of Contact Documents ...............: 5.11. Interpretations and 3.1-3.4 Clarifications .................3.6.3.9.4 lnvestigadons of physical Conditions ........... Labor, Materials g1°Pmen[ : and E 4'- ................... Lands - and Easements .......... :.................... 8.4 Availability of .................- Reports & Tests ......... 4.I, 8.4 Laws and R """"" 8.4 Bonds egula[ions-laws or Regulations- ............ Changes in the Work ................'................ 10.4 Contract Documents ........ CONTRACIOR's Responsibilities s..................... 3.1 espoosnbpities defecdv................... 6.14 Correction Period. e Work ....:........... Cost of the Work, taxes • • 13.12 definitionof ........................................ 1= Seiietal...................................... :.. 6.14 IndCmnificadon 631.6Z-3 Insurance ............ ................... 5.3 .. ............. Ptr..edence'..........:.......................: 3.1.3:33 Referenceto ...................:............... . 33.1 Safety and Protection ............ 6:M, 13.2 Subcontractors. Suppliers and Others ......... Tests and I ..8-6.11 Inspections ..............:................. 133 Use of Premises ......................... Visits to Site 6.16 I.iabLry. Itsivanee_ ...... 92 CONTRACPOR's.................................... S.4 . OWNER's ................... ................. 5S Licensed Sureties and Insurers ............ 3 Liens.- 5 Application for"Progress,Payment .......... 14?Contactor'sWarraary ofTide ....................... 143 Final Application for Payment ...................... 14.12 IJ definition of ........................................ LM Waiver of Claims ...:.. Limitations an ENGINEER'S authority and 14.15 responsibilities ..... :................. .... 9.13 Li ' mited Refiace uby CO Authorized . CONTRACTOR Authorized ...... 42.21 Maintenance and Operating MmtuaLf.., Fuel Application for Payment ...................... 14.12 Manuals (of others}-- Precedeare....................................... 333.1 I Article or Paragraph Number Reference to in Conttact'Documents ................ 33.1 Materials and equipment - furnished by CONTRACMR ................. :...... 63 not incorporated in Work ............................ 14.2 Materials or equipment -equivalent ..................... 6.7 Mediation .(Option!) ................................... 16.7 Milestones --definition of .............................. : 114 Mucenaneous- Computation of Times .............................. 17.2 Cumulative Remedies ..... :.......................... 17.4 Giving Notice ...............:....................... 17.1 Notice of Claim ..................................... 173 Professional Fees and Court Costs Included .......... 173 Muhi-prime contracts ................................. :..7 Not Shown or Indicated .............................. 431 Notice of Acceptability of Project ............................ 14.13 Award. definition of ................................. 1.25 Claim.............................................. 173 Defects, ...................... o ..................... 13.1 Differing Subsurface or Physical Conditions ..........4 23 Giving.............................................. 17.1 Tests and Inspections ............................... 13.3 Variation. Shop Drawing and Sample ................ 6.27 Notice to Proceed - definition of ........................................ 1.26 giving of ............................................. 23 Notification to Surety ................................. 10.5 Observations, by ENGINEER ....... :............ 630, 9.2 Occupancy of the Work ................ 5.15, 630? 4, 14.10 Omissions or acts by CONTRACTOR ............. 69. 9.13 Open petal" policy form: Insurance ...................5.61 Option to Replace....................................5.14 "Or Equal" Items .....................:................ 6.7 Otherwork .................................... :.........7 Overtime Work-prohbiuon of ......................... 63 OWNER - Acceptance of defective' Work .......:..........:... 13.13 appoint an ENGINEER .............................. 81 as fiduciary :............a.....................: 5.12-5.13 Availability of Lands. responsibility ................... 4.1 definition of ...................................... 1_7 data, furnish...............................I.......... 83 May Correct Defective Work ....................... 13.14 May refuse to snake payment ........................ 14.7 May Stop the Work ........................:....... 13.10 may suspend work. ' terminate ........:.............. 8.8. 13:10. 15.1-15.4 Payment, make prompt .................... 83. 14.4 14.13 performance of other Work ....:........... .i'.: I ..... permits and licenses, requirements ...6.13 purchased insurance requirements ....... ... 3.6 5.10 OWNER's- Acceptance of the Work ......................... 630� Change Orden, obligation to execute ....... :............................. L6. 10.4. Communications ..................................... 8.1 Coordination of the Work ............................ 7.4 Disputes. request for decision ....................... 9.11 Article or Paragraph Number Inspections, tests and approvals ................. 9.7. 13.4 Liability Inuurance...................................53 Notice of Defects ....' ............................... 13.1 Repttzettative-During Construction. ENGINEER's Status ............................ 9.1 ResponsiWities-- Asbrstos. PCBs. Petroleum. Hazardous Waste on Radioactive Material ..........:....... 8.10 Change Orden .......................... :....... ... 8.6 Changes in the Work .............................. 10.1 communications ................................... L I CONTRACT OR's'reipoiWbiIirics .................. 89 evidence of financial arrangements ................ 8-I1 inspectiom tests and approvals' .................... 9.7 Insurance ......................................... 8.5 lands and casements ................ ..:............ 8.4 prompt payment by .7................................ 8.3 replacement of ENGINEER ....................... 8.2 reports and tests ................................... 8.4 stop or suspend, Work .................. B.S. 13.10, 15.1 terminate CONTRACTOR'S services .......... U, 151 separate representative at site ........................ 93 independent testing ..........................:...... 13.4 use or occupancy of the Work .............................:...... 5.15, 14.10 written consent or approval . required ............:::................. 9.1. 63. 11.4 written notice required .......... 7.1, 9.4, 9.11, 11.2, 11.9, 14.7. 15.4 PCBs - definition of ........................................ 1.29 general . ............................... ................. 43 OWNER's responsibility for ........................ 8.10' Partial Utilization - definition of ........................................ 128 general ................................... 630 ? 4, 14.10 Property Insurance ............:.................... 5.15 Patent Fees and Royalties .............................. 6.12 Payment Bonds ..................................... 5.I-51 Payments. Recommendation of ............. 14.4 14.7, 14.13 Payments to CONTRACTOR acid Completion - Application for Progress Payments ................... 14.2 CONIRACTOR's Warranty of Tide ................. 143 Final Application for Payment ...................... 14.12 Final`Inspection.:................................. 14.11 'Fnmal Paymenrand Acceptance ............... 14.13-14.14 general ........................................... 83, 14 Partial Utilization ............. ....... 14.10 ............... Retainage........................................... 141 Review of Applications for Progress Payments .................................. 14.4-14.7 prompt payment .................................... 83 Schedule of Values .:................................ 14.1 Substantial Completion ......................... 14.8-149 Waiver of Claims .................................. 14.13 when payments due .......................... 14.4. 14.13 withholding payment ................................ 14.7 Performance Bonds ................................. 5.1-5.2 Permits ............................................... 6.13 Article or Paragraph Number Petroleum - definition of ........................................ 130 general' .............................................. 4.5 OWNER'S responsibility for ......................... 8.10 Physical Conditions - Drawings of, in or relating to ...................... 42.1 2 ENGINEER's review .............................. 4.14 ousting structures .................................. 422. general........................................... 4 ? 12 Subsurface and . .................................... :. 4 2 Underground Facilities ......................... :..... 4.3 Possible Contract Document. Change ... ......... ... : 4? S Possible Price and Times Adjustment .............. 42.6 Reports and Drawings .............................. 4.11 Notice of Differing Subsurface or . .................. 42.3 Subsurfaceand ....................................... 4.2 Subsurface Conditions ............................ 4 I.1 ta, Technical DaLimited Reliance by CONTRACTOR Authorized ......:............. 422) Underground Facilities - general.........:................................ 43 Not Shown or Indicated ....................... 43_2 Protection of ............................... 4.3.6.20 Shown or Indicated ............................ 43.1 Trhnical Data ........:.::......................... 4.12 Preeoastrumion Conference ............................. 2 8 Pr.Gminary Matters ...................................... 2 Preliminary Schedules ..:............................... 2.6 Premises. Use of ................................. 6.16-6.18 Prier, Change of Contract ................................ 11 Price, Contract -definition of .......................... 1.11 Progress Payment, Applications for ....................142 Progress payment-retainag........................... 142 Progress schedule, CONTFLA=R's .....16. 2.8. 2.9. 6.6. 6.29, 10.4..15.2.1 Proje_t-definition of .................................. 131 Project Representative- "ENGINEER's Status. During Construction ............ 93 Project Representative; Resident ---definition of ..............................:....... 133 Prompt Payment by OWNER ........................... 83 Property Insurance Additional.........'............: ...................... 5.7 general.......... :............................... 5.6.5.10 .............................. Pamal:UaTizauan5.15.14.102 receipt and application of proceeds .................................. 5.12-5.13 ' Protection, Safety and ....................... 620.631, 132 Arndt list ............................................ 14.11 Radioactive Material- definition........................................... 132 general 43 OWNER'S responstbiTiry for .:...................... 8.10 Recommendation of Payment .............. 14.4. 14.5. 14.13 Record Document ............. :............. ... 6.19. 14.12 Records. procedures for maintaining .................... 2.3 Reference Points ....................................... 4.4 Reference to Standards and Specifications of Technical Societies................................3J Article or Paragraph Number Regulations. Laws and (or) ............................ 6.14 Rejecting Defective Work ............................... 9.6 Related Work - atSite .......................................... 7.1-73 Performed. prior to Shop Drawings and Samples submittals review .................. 628 Remedies. cumulative ............................ 17.4, 17.5 Removal or Correction of DefectiveWork .................................... 13.11 rental agreements. OWNER approval required ...................................... I1.4.53 replacement of ENGINEER, by OWNER .............. a Reporting and Resolving Discrepancies .... 2.5. 3.3.2. 6.14.2 Report.-. andDrawings ....................................... 4 LI and Tests. OWNER'S responmbu7iry .................. 8.4 Resident Project Representative- definition 'of ........................................ 133 provision for ......................................... 93 Resident Superintendent CONTRACTOR's ............. 62 Responsibilities— CONTRACTO R's-in. general ............... I. ........... 6 ENGINEER's-in. general ............................... 9 Limitationson .................................... 9.13 OWNER'S -in general.........................:........a Rctainag.............................................. 142 Reuseof Documents ................................... 3.7 Review by CONTRACTOR. Shop Drawings and Samples Prior to Submittal ................ :...... 6M Review of Applications for Prowess Payment ...................................... 14.4-14.7 Right to an adjustment ................................ 102 Rightsof Way..........................................4.1 Royalties. Patent Res and ............................. 6.12 Safe Structural Loading ............................... 6J8 Safety - and Protection ........4.32, 6.16. 6.18, 6.20-621, 7.2, 13.2 general ........................................ 6.I0,6.23 'Representative. CONTRACIUR's ................... :..6M Samples - definition of ........................................ 134 general ........................... :............ 624.6.29 Review by CONTRAC. MR ......................... 6ZS Review by ENGINEER ........................ 626. 6_77 - related Work .............. .................... ...... 628 submittalor; ...................................... 6.24.2 submittal procedures ................................ 62S Schedule of progress ..... 2.6. 2..8-2.9, 6.6. 6-)9, 10.4, 132.1 Schedule of Shop Drawing and Sample Submirtals ....................... 2.6. ? 8-29. 6 24-628 Schedule of Values ......... :.............. 2.6.2.8-2.9. 14.1 Schedules - Adhere = to ................................:.... 152.1 Adjusting ...... .....6.6 Change of Contact Times .......................... 10.4 Initially Acceptable ............................... 2.8-29 Preliminary.......................................... 2.6 Scope of Changes .............................. 103-10.4 Subsurface Conditions .............................. 4-71.1 10 Arrk 'Paragraph Number Article or Paragraph Number Shop Drawings- 'aad Samples. general ........................... 624-6.28 Change Orders & Applications for Payments, and ............................... 9.7-9.9 definition of ............. :.......................... 135 ENGINEER's approval of ......................... 3.6- ENGINEER's responsibility for review ............................... 9.7, 624-628 related Work ....................................... 628 review procedures ......................... 2.8. 6 244M submittal required ................................. 624.1 Submittal Procedures ............................... 6.= use, to approve substitutions ........................ 6.7.3 Shown or Indicated ................. .......... :....... 43.1 Site Access .....:................................. 72, 13.2 Site Cleanliness ....................................... 6.17 Site. Visits to - by ENGINEER ................................ 9,) 13 2 byothers ........................................... 132,. "Special causes of loss" policy form, insurance ....... 5.6 2 Specifications - definition of ...........................::........... 136 of Technical Societies, reference to ................. 33.1 precedence........................................ 333 Standards and Specifications of Technical Societies....................... ......:............. 33 Starting Construction, Before .:..................... 25-2.8 Starting the Work ....................................:. 2.4 Stop or Suspend Work - by CONTRACTOR ................................. 15.5 . by OWNER ......................... 8.8. 13.10, 15.1 Storage of materials and equipment ................. 4.1.7.2 Structural Loading, Safety ............................... 6.18 Subcontractor= Concerning . :.................................... 6.8-6.11 definition of ........................................ 137 delays ........................................... 123 waiver of rights .... ............................... 6.11 Subcontraetors-in general ........................ 6.8-6.11 Subcontracts --required provisions ......... 5.11. 6.11. 11.43 Submittals. - Applications for Payment ............................ 142 Maintenance and Operation Manuals ............... 14.12 Procedures ......................................... 6.-S Progress Schedules ..........:................••. 2.6, 2.9 Samples .......................................624-6.28 Schedule of Values ............................. 2.6. 14.1 Schedule of Shop Drawings and Samples Submissions .................... 2.6. 2.&1.9 Shop Drawings .................................. 624-628 Substantial Completion- . certification of ........................ 6.30.2.3. I4.8.14.9 definition of ....................................... 138 Substitute Construction Methods or Procedure ....... 6.72 Substitutes and "Or Equal' Items .....:................ 6.7 CONTRACTOR's Expense ....................... 6.7.13 ENGINEER's Evaluation .......................... 6.73 "Or -Equal" .......................................... 6.7.1 Substitute Construction Methods of Procedures...... 6.7.2 11 Substitute Items .................................. 6.7.12 Subsurface and Physical Conditions— Drawings of. in or relating to ..................... 42_12 ENGINEER's Review ............................. 414 general.............................................. 42 Limited Reliance by CONTRACTOR Authorized....................................4 , Notice of Differing Subsurface or Physical Conditions ................................ 423 Physical Conditions ................................. 42.12 Possible, Contract Documents Change, .::...........:.. 43'S 'Possible Price and Times A0vaments ................. 42.6 Reports and Drawings ................................ 42.1 Subsurface and ...................................... 42 Subsurface Conditions at the Site ................. 4ZI.1 TechnicalData ..................................... 4 ? Supervision- CONTRACTOR's responsibility ...................... 6.1 OWNER shall not supervise .........................89 ENGINEER shall not supervise ................ 92 2 9.13 Superintendence ....................................... 62 Superintendent. CONTRACTOR's resident ........... 6.2 Supplemental costs ... :.... :......................... 11.45 Supplementary Conditions- definition of ......................................... 139 principal reference to .... 1.10. 1.18, 'r? 2.7, 42. 4-3. 5.1, 53. 5.4. 5.6-5.9. 5.11, 6.8. 6.13. 7.4. 8.11. 93. 9.10 Supplementing Contract Documents ......... :.......... 3.6 Supplier - definition of ............................ :........... 1.40 principal references to .................. 3.7. 6.5. 6.8-6.11. 620. 624, 9.13. 14.12 Waiver of Rights .................................... 6.11 Surety - consent to final payment ...............'...... 14.12. 14.14 ENGINEER has no duty to ......................... 9.13 Notification of ........................... 10.1, 10.5. 152 qualification of .................................... 5.1-53 Survival or Obligations .................. ......... ...634' Suspend Work. OWNER May .................. 13.10. 15.1' Suspension of Work and Termination ................... 15 CONTRACTOR May Stop Work or Terminate ..................'......................15.5 OWNER May Suspend Work ....................... 15.1 OWNER May Terminate ..................... :. 15.2-15.4 Taxes -Payment by CONTRACTOR .................... US Technical Data - Limited Reliance by CONTRACTOR ............... 4 2 2 Possible Price and Tunes Adjustments .............. 42.6 Reports of Differing Subsurface and Physical Conditions .............................. 423 Temporary construction facilities ........................ 4.1 Termination - by CONTRACTOR ................................. 15.5 by OWNER ............................... 8.8. 15.1-15.4 of ENGINEER's employment ...'..................... 82 Suspension of Work-in general ........................ 15 Terms and Adjectives .................................. 3.4 Tests and Inspections- Arrlcle or Paragraph Number .Access to the Work, by others 2 CONTRACIOR's responsibilities ....................13.5 costof ..:........................................... 13.4 covering Work prior to ...... ................... 13.6 13.7 Laws and Regulations (or) ........:.....0.............. 13.. 13.7 Notice of Ddcas 13.1 ........... OWNER May Stop Work ..... ............... 0..... 13.10 OWNER's independent testing ........0............. 13.4 ea spal, required by ENGINEER ............... 9.6 timely notice required ..... Uncovering the Work. at ENGINEER's request.......0...:... .............. ....... 13 8 13.9 Tares - Adjusting............................................ 6.6 Change of Contract ................................... 12 Adjusting..............0..................0.........0 6.6 Computationof ..............0.. 0.................. 17.2 Contract Times --definition of .......................1.12 y ..............................: ........17.72 Milestones 12 Requirements- appeals....... ....... 0.......... .......... ......: 16 daritications, claims and disputes .............:............... 9.11, 11.2, 12 cdmmencetnem of contract times ................... 23 Pm'construction conferetc ......................... 2 B schedules....0............................ 26, 2.6.6 starting the Work ................. .4 Tide. Warranty of ......... Uncovering Work'.... . .. 143 Underground F.ictlities. Physical Conditions - definition of................0.0......................1. 1 Not Shown'or Indi®ated 41 Protection of ................................... 43. 6.20 Shown or Indicated ..........0............ .... 43.1 . Unit Price Work - claims .......... .................................. 11.9.3 definition of ........... ........... ..................'1.42 Scotto! .................................. ITS. 14.I. 14.5 Unit Prices general...........0..................... ...... 11.3.1 Determination for ................ . 9.10 Use of prcmues UtMtY owners . ......... .... ................ 6.16. 6.18, 630.2.4 . .... •••••.....6.13.6.20,7.1-73.13.2 Article or Paragraph Number Uo'lization. Partial ............... 118: S.I S, 630, 24, 111.3 Value of the Work ............ ... II3 ............. Values, Schedule of .....:................. 7-6. 2.8.2.9. 14.1 Variation in Work -Minor Authorized ................................ 6.25. 6_77. 95 Visits of Site -by ENGINEER .... Waiver of Claims.......:.Claims-onFinal .... Payment...:.......r.d.................. ••" 14.15Waiver of RightsbY insured ............... 1.11.6.11 Warranty and Guarantee, General -.by CONTRACTOR .................................... 1630 Warranty of Tide, CONTRACIOR's ............. 43 Worst Accessto ............................................ 13.2 yothers . .........................................:... 7 Changes in the ............................... Continuing the, 10 May Stop 6� CONTRACTOR May Stop Work or Terminate ................................... I5.5 Coordination of ...................................... 7.4 Cost of the ..................................... 1I.4-11.5 definition of ........ :.. ............................. 1.43 n4c=.cd by CONTRACTOR .... ..............:... 13.14 otherWork ............. OWNER May Stop Work ....... :.................. 13.10 OWNER May Suspend Work ................. 13.10. 15.1 Related, Work at Site ............................. 7.1-73 Startingthe' .......................................... 2.4 Stopping by CONTRACTOR ........................ 15:5 Stopping by OWNER .......................... 15.1-I5.4 Variation and. deviation authorized, minor........................................... 3.6 Work Change Direcdve- claims pursitantto ...... :10.2 .. definitionof ....................................... 1.44 Principal references to ..................... 3.5.3, 10.1-10.2 Written Amendment de5ni.don of ........................................ �1.45 PPa1 references to ... 1.10. 3.5, 5.10, 5.12, 6.63 6,81 6.19. 10.1. 10.4. 112 12.1, 13.12.7. 14.7.2 Written Clarifications and laterPreations........................... 3.63. 9.4, 9.11 Written Notice Required- by CONTRACTOR •••••...7.1.9.10-9.11, 10.4. 11.212.1 by OWNER ...................9.10-9.11, 10.4. 111, 13.14 . 12 GENERAL CONDMOna ARTICLE I—DEFINMONS Wherever used in these General Conditions or in the other Contract Doetrments.the following terms have.the meanings radiated which are applicable to both the singular acid plural thereof:. I.I. Addenda —Written or graphic instruments Issued prior to the opening of Bids which clarify, correct or change the Bidding Requirement or the Contract Daeumens. 1Z Agreement —The written contract between OWNER and CONTRACTOR covering the Wort to be performed; other Contract Documents are attached to the Agreemeat and made a part thereof as provided therein. 13. Application for Payment —The form accepted by EN- GINEER which is to be used by CONTRACTOR iri requesting Progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents 1.4. Asbestos-Any'material that contains more than one pcmeat'asbestos and is friabir or is releasing asbestos fibers into the air above current action levels established by the United Stases Occupational Safety and Health Administration. 1.5. Bit -The offer or proposal of the bidder submitted on the prescribed form setting forth the price for the Work to be performed. . ment. together with all Writ -_ mendments. Change Orders, wort Change Directives. Fuld Orders and ENGINEER's written interpretations and clarifications issued pursuant to paragraphs 3-5. 3.6.1, and 3.6.3 on or after the Effective Daze of the Agreement. Shop Drawing submittals approved puns - ant to paragraphs 6 76 and 6.27 and the reports and drawings referred to in paragraphs 4 Z 1.1 and 4 Z 2 2 are not Contract Documents. 1.11. Contract Price The moneys payable by OWNER to CONTRACMR for completion of the Worst in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of paragraph 11.9.1 in the case of Unit Price Work). 1.12. Contract Times —The numbers of days or the dates stated in the Agreement: n to achieve Substantial Completion, and (7 to complete' the Wort so that it is ready for final . . payment as evidenced by ENGINEER's written mcommenda- don of final payment in accordance with paragraph 14.13. 1.13. CONTRAC R The person, firm or corporation with whom OWNER has ene.-ed into the Agreement. 1.14. defective —An adjr_tive which when modifying the word Wort refers to'Work that is unsatisfactory, faulty or deficient, in that it does not conform'to the Contract Docu- ments, or does not meet the requirements of any inspection, reference standard. test or approval referred to in the Contract Documents. or has been damaged prior to ENG1- NEER's recommendation of final payment (unless responsi- bility for the protection themofhas been assumed by OWNER at Substantial Completion in accordance with paragraph 14.8 or 14.10). 1.6. Bid&ng Documents --The advertisement or invitation 1.15..Drawings—lbe drawingi which show the scope.' to Bid, instructions to bidden, the Bid form, and the proposed extent and character of the Work to be furnished and per - Contract Documents (Including all Addenda issued prior to formed by CONTRACTOR and which have been prepared or receipt of Bids). approved by ENGINEER and are referred to in the Contract Documents. Shop drawing are not Drawings as so defined. 1.7. Biddung Requirements —The advertisement or invita- tion to Bid, instructions to bidden, and the Bid form. I.R. Bonds —Performance and Payment bonds and other hrstruments of security. 19. Change Orden —A doumtent r=orr==ded by ENGI- NEER, which is signed by CONTRACMR and OWNER and authorizes an addition, deletion or revision In the Work, or an adjustment in the Contract Price or the Contract Ties. Issued on or after the Effective Dare of the Agreement ' . 1.10. Contract Doeumenu—The, Agreement. Addenda. (which pertain to the Contract Daantiens). CONTRAC'IDR's Bid (Including documentation accompanying the Bid and any post Bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Agteetnumt. the Notice to Proceed, the Bonds, these General Conditions, the Supplementary Conditions, the Specifications and the Draw- ings as the sane acre more specifically identified in the Agra 1:16. Effective Date of the Agreement —The date indicated in the Agreement on which it becomes effective, but if no such dam is indicated it meatus the daze an which the Agreement is signed and delivered by the last of the two parties to sign and ddivm 1.17. ENGINEER- The person. firm oreorporation named as such in the Agreement 1.18. ENGINEER's Con tthant—A person. firm or corpo— ration laving a =in= with ENGINEER to famish service as ENGINEER's independent professional associate or coo- sultaat with respect to the Project and who is identified as such in the Supplementary Conditions. 1.19. Feld Ordet�A written order issued by ENGINEER which orders minor changes in the Work in accordance with paragraph 9.5 but which does not involve a claa1R in the Contact Price or the Contract Times. ; 13 110: General Regtrireme=r Secdons of Division 1 of the Specdatioas. 111. Hazardous Wosre—The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 1-'r'r- laws and RegalatfoIts: Laws or Regulasiont—Any and an applicable laws, rules, regulations. ordinances, coda and orders of any and an governmental bodies, .agenda. authorities and courts having jurisdiction IJ. Liens —liens, charges, security (htetests or encu m- brances upon real Property'or personal property, 1 14. Agesrone—A prinapal ever specified in,the Con- tract Documents relating'to an intermediate completion date or time prior to Substandal Completion of all the Work, .115. Notice oJ',twordt 'The written notice by OWNER to. the apparent successful bidder staring that upon compliance by the apparent successful bidder with the conditions precedent enumerated therein, within the time specified. OWNER will IF and deliver the Agreemem, 116 NorlceroProceed—AwtinarnotieegivenbyOWNER to CONTRACTOR (with a copy to ENGINEER) fixing the date on which the Contract Times wM commence to run and on which CONT -ILLMR shah start to perform CONTRAC- MR's obligations under the Contract Documents. . 1 17. OWNER —The public body or authority, corpora - don, association, firm or person with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be provided. I.28• P=W Unilisarloh—Use by OWNER of a substan- tially completed part of the Work for the purpose for which it is intended (or a related purpose) prior to Substantial Completion of an the Work. 119. PCBs --_polychlorinated biphenyLs. 1.30• Petroleum —petroleum, including crude of or any fraction thereof which is Squid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 Pounds per square inch absolute). such as OR, petroleum• fuel m7, of sludge: OR refuse. gasofiiu; kerosene, and on mixed with other non -Hazardous Wastes and mode ols. . 131' ProJect--The total construction of which the Work to be Provided under the Contract Documents may be the whole. or a part as indicated elsewhere in the Contract Documerits• 131 Radioactive Material-Zouree. special nuclear, or byproduct material as defined by the Atomic Energy Aix of 1954 (42 USC Section 2011 a seq.) as amended from time m time. 133. Re:ident Project Representalive— The authorized representative of ENGINEER who may be assigned to the site or any part thereof. 134. Sump/er-Physimlexamples of materials,equipmen4 or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work wl1 be judged, 1.35. Shop. Drawing: —All drawings, diagrams, llustra- dons, schedules and other dam or infornmtion'which arc' SP=Uicany Prepared or assembled by or for CONTRAC MIX and submitted by CONTRACTOR to illustrate some portion of the Work. 1.36. Specfications-Those portions of the Contract Doc- ument consisting of.written technical descriptions of materi- als, equipment. construction systems, standards and workman- ship as applied to the Work and, certain administrrdve decals applicable thereto, lx. subcontractor —An individual, firm or corporation having a direct contract with CONTRACTOR or with any other Subcantractor for the performance of a part of the Work at the site. 138. Substantial Completion The Work (or a specified Pan theml) has DMV=cd to the point where, in the opinion Of ENGINEER as evidenced by ENGINEER'S definitive certificate of Substantial Completion, it is suffciendy com- plete. in accordance with the Contract Documents, so that the Work (or specified part) can be utilized for the purposes for which it is intended; of if no such certificate is issued, when the Work is complete and ready for final payment at evidenced by ENGINEER s written recommendation of final payment in accordance with Paragaph 14.13. The terms -substantially complete" and .'stibstantiany completed" as applied to an or Part of the Work infer to Substantial Completion thereof. 1.3% Supplementary Cond don r—The part of the Conu= Document which araends'or supplements these General Can- didons. 1.40. Supplier —A manufacturerfabricator, suppilm dls- inbutor, anrerialu= or vendor having a direct conaact with CONTRACTOR or with any Subcontractor to furnish raters als or equipmeat to be incorporated in the Work by CON- TRACTOR or any Subcontractor. 1.41. UndergroundFacirries—Mpipeluma condu(ts,duas cables whes,rmanhola, vaults, tanks, tuanels.or other such ta or attachments, and any =czsemrnts containing such ides which have been installed underground to furnish any of the following services or materials: elrait * Bases, steam, Squid Petroleum products, telephone or other communica- tions, table television, sewage'and dtainag ' rernoval, =ffme or other control systems, or water. 1.42- Unit Price WofE—Work to be paid for on the basis of unit price. 14 1.43. Work --The entire completed con: ion or the var- ious separately identifiable parts thereof required to be fur- nished under the Contract Documents. Work includes and is the result of performing or famishing labor and furnishing and incorporating materials and equipment into the construction. and performing or furnishing services and furnishing docu- ments. all as required by the Contract Documents. 1.a4. work Change Directive —A written directive to CON- TRACTOR. issu on or after the Effective Due ,of the Agreement and signed by OWNER and recommended by . ENGINEER ordering an addition, deletion or revision in the Work, or mspond'mg to differing or unforeseen physical condi- dons under which the Work is to be performed as provided in paragraph 4.2 or 43 or to emergencies under paragraph 6.23. A Work Charge Directive will not Mange the Contract Price or the Contract Tunes, but is evidence thattthe parties expect that the change.d4rded or docrmriented by a Work Change Direc- tive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect. if any, on the Cona='Prieccr Contract Times as provided in paragraph 101 1.45. written Amendment —A written amendment of the Contract Documents, signed by OWNER and CONTRACTOR on or after the Effective Date of the Agreement and normally dealing with the nonengineering or nontechnical rather than strictly eonstnrcdon-rclarcd aspects of the Contract Doar- menu. ARTICLE 2—PRELIMINARY MATTERS . Deirxry of Bonds: 2.1. When CONTRACTOR delivers the executed Agree- ments to OWNER CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish in accordance with paragraph 5.1. Copies of Doamreats: OWNER shall furnish to CONTRACTOR up to ten eopies.(unless otherwise specified in the Supplememary Con- ditions) of the Contract Documents as are reasonably neees- sary'for the exeattion of the Work. Additional copies will be flunished, upon request, at the cost of,reproduuion. Qium reaarent of Conma runes: Nader to Proceed 23. The Contract Times will commence to run an the thin i- eth day after the Effective Date of the Agreement. or, if a Notice to Proceed is given, on the day ittdicatcd in the Node to Proceed A Notice to Proceed may be give at any time within duty days after the Effective Date of the Avcc mama in oo event will the Contract Tunes cowmen un later than the sixtieth day after the day of Bid opening on -'_ _rirdeth day after the Effective Date of the Agreement. whichever date is earlier. Stmsgrg the work: 2.4. CONTRACTOR shall start to perform the Work on the date when the Contract Times commence to rain, but no Work shall be done at the site prior to the date on which the Contract Times comment to run. Before Stardng Consa ucdan: 2-5.' Before underutking,each par of the Work CON- TRACTOR shall =mfAy study and compare the Contract Documents and check and verify pertinent figures shown thereon and all applicable field measurements. CONTRAC- TOR shall promptly report in writing to ENGINEER any conflict, error, ambiguity or discrepancy which CONTRAC-.• TOR may discover and shall obtain a written interpretation or clarification from ENGINEER before proceeding with any, Work affected thereby: however, CONTRACTOR shall not be Gable to.OWNER or ENGINEER for failure to report any conflict, error..ambiguity or discrepancy in the Contract Doc- uments: unless CONTRACTOR knew or rctsonably should have known thereof. 15 2.6. Within.ten days after the Effective Date of the Agree- ment (unless otherwise specified in the General Requirements). CONTRACTOR shall submit to ENGINEER for review: 6.1. a preliminary progress schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Wont, including any Milestones specified in the Contract Documents; . 2.6.2. a preliminary schedule of Shop Drawing and Sam- ple submittals which will list each required submittal and the times for submitting, reviewing and processing such submit- tal: 2.63. a preliminary schedule of values for all of the Work which will include quantities and prices of items aggregating the Contract Price and will subdivide the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include an appropriate amount of overhead and profit appG- cable to each item of Work. ' 2.7. Before any Work at the site is started. CONTRACTOR and OWNER'shall each deliver to the other, with copies to - each additional insured identified in the Supplementary Conde dons. certificates of insurance (and other evidcmr_ of insurance which either of them or any additional insured may reasonably . request) which CONTRACTOR and OWNER respectively are required to purchase and. maintain in accordance with para- graphs 5.4. 5.6 and;5.7. Premnsvuedon Conference: 2.8. Within twenty days after the Contract Timesstartto run, but before any Work at the site is started. a conference attended by CONTRACTOR. ENGINEER and others as ap- ProPriate will be held to establish a working understanding Smong the parties as to the Work and to discuss the schedules referred to in paragraph ? 6, procedures for handling Shop Drawings and other submimals. Processing Applications for Payment and maimaining,required records. lnrdaayAceapiabte Sehedalesr ... 19. Unless otherwise provided in the Contract Docu- mens. at least ten days before submission of the first Applica don. for Payment a conference attended by CONTRACTOR, ENGINEER and others as appropriate will be held to review for acceptability to ENGINEER as provided below'the ached- ales submitted in accordance with paragraph 2.6. CONTRAC- TOR shall have an additional ten days to make corrections and adjustments and to complete and resubmit the schedules. No Progress Payment shall be made to CONTRACTOR until the schedules are submitted to and acceptable to ENGINEER as provided below. The progressschedule will be acceptable to - ENGINEER as providing an orderly progression of the Work to completion within any specified Milestones and the Contract Times, but such acceptance will neither impose on ENGI- NEER responsibility for the sequencing, scheduling or progress of the Work nor interfere with or rerieve CONTRACTOR from CONTRACMR'sfullrtisponm'Mlirytherefor.CONIRAC MR's schedule of Shop Drawing and Sample submissions will be acceptable to ENGINEER as providing a'workable amnge- mem for reviewing add processing the required iubminals. . CONTRACTOR's schedule of values will be acceptable to ENGINEER as to form and substance. ARTICLE 3—CONTRACT DOCUMENTS: INTENT AMENDING. REUSE late= 3.1. The Contract.Doatmens comprise the entire agree. went between OWNER and CONTRACiDR concerning the Work The Contras Documents are complementary; what is Called for by one is as binding as if called for by all. The Conn= Documents will beconstrued in accordance with the law of the place of the, Project, 3.2. It is the intent of the Contract Documents to describe a flnxconally complete Project (or part thereof) to be con- im"'d in accordance with'the Contract Doemmints. Any Work, materials or equipment that may reasonably be inferred tram the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result w01 be furnished and performed whether or not specifically Called for When words or phrases which have a well- known technical or construction industry or trade meaning are used to describe Work, materials or equipment, such words or phrases shall be interpreted in accordance with that Meaning. Clad& cations and interpremdom of the Contract Documents shall be I ssued by ENGINEER as provided in paragraph 9.4. 33. Rejoena to Slaadands and Specifrccaoru ojTeehnie Soaerier• Repast": and Resolving Diserepandfr; 33.1. Reference to standards, specifications, manuals or codes bf any technical society, organization or associai o or to the Laws or Regulations of any governmental authority, whether such reference be specific or by implication, shall mean the lateen standard" specificado.n, manual, code or LAWS or Regulations in effect at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids). except as may be otherwise speeitically stated in the Contract Documents 333. If, during the Performance of the Work. CON- TRACTOR discovers any conflict, error, ambiguity or cgs. aePancy within the Contract Documents or between the Contract Documents and any provision of any such Law or Regulation'applicable to the performance of the Work or of any such standard, ipccification, manual or code or of any instruction`Of any Supplier referred to in paragraph 63. CONTRACTOR shall report it to ENGINEER in writing at once, and, CONTRACTOR shall not proceed with the Work affected thereby (except in an emergency as authorized by Paragraph 6.23) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in paragraph 3s or 3.6; provided, however, that CONTRACTOR shall not be liable to OWNER or ENGI. NEER for failure to report any such conflict, error, ambigu- ity or d'ncePancy unless CONTRACTOR knew or reason- ably should have known thereof. 3.33. Except as otherwise specifically stated in the Contract Documents or as may be provided by amendment or supplement thereto issued by one of the methods indi- cated in paragraph 3.5 or 3.6, the provisions of the Contract Documents shall take precedence in, resolving.any conflict, error, ambiguity or discrepancy bciwe-_n the provisions of the Contract Documents and: 3-33.1. the provisions of any such standard, ipeei- fication. manual, code or instruction (whether or net sPli ically incorporated by reference in the Contract Documents); or 333 2 the provisions of any such I-aws or Regu- ladom applicable to the performance of the Work (unless such an interpn ration of the provisions of the Contract Documents would ruult in violation of such Law or Regulation). No provision of any such standard, specification, manual. code orintauction steal be effective to change the duties and responsibilities ofOWNER CONTRACTOR or ENGIN EER. or any of their subcontractors. consultants, agents. or em- ployees from those set forth in the Contract Documents, nor shall it be effective to assign to OWNER ENGINEER or any of ENGINEER's Consultants, agents or employees any duty or authority to supervise or direct the furnishing or 16 performance of.the Work or any duty or authority to ander- take responsibility inconsistent with the provisions of para- graph 9.13 or any other providom of the Contract Doan menu. 3.4. Whenever in the Contracr Documents the terms "as ordered;' "as directed:' "as requited;' "as allowed;' "as approved" or terms of like effect or import are used, or the adjectives "reasonable; "'suitable," "acceptable," "proper" or 'satisfactory" or adjectives of Hite effect or import are used to describe a requirement, direction, review or judg- ment of ENGINEER as to the Work, It is intended that such requirement, direction, review or judgment will be solely to evaluate, in general, the completed Work for compliance with the requirements of and information to the Contract Documents and conformance with the design concept of the completed Project as a functioning whole as shown or indicated .in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective shag not be effecdve to assign to ENGI- NEER any duty or authority to supervise or direct the furnishing or performance of the Work. or any duty or. authority to undertake responsibility contrary to the provi- sions of paragraph 9.13or any other provision of the Contract Documents. Amendurg and Supplementing Contact Document: 3.3. The Contract Documents may be amended to provide for additions, deletions and revisions in the Work or to modify the terms and conditions thereof in one or mom: of the following ways: 35.1. a formal Written Amendment, 3.5? a Change Order (pursuant to paragraph 10.4), or 3.5.3. a Work Change Diiecdve (pursuant to paragraph 10.1). . , 3.6. In addition; the requirements of the Contract Docu- meats may be supplemented, and minor variations and devia. does in the Work may be authorized, in one or more of the. following ways. 3.6.1. a Feld Order (purniant to paragraph 9.5), 3.6.7- ENGINEER's approval of a Shop Drawing or Sample (pursuant to paragraphs 6.26 and 6=.' or 3.63. ENGINI:-r'F. is written interpretation or ciarifica- e..tion (pursuant to paragraph 9A). Rense ojDo=merur 3.7. CONTRACTOR. and any Subcontractor or Supplier or other person or organization performing or furnishing any of the Work under a direct or indices contract with OWNER 01 shall not have or acquire any title to or ownership rights in any of the Drawings, Spcmfi is or other documents (or copies of any thereof) -prepared by or bearing the seal of ENGINEER or ENGINEER's Cimsulnnt. and a shall not reuse any of such Drawings, Specifications, other documents or copies on extensions of the Project or any other project without written consent of OWNER and ENGINEER and specific written veriB=ion or adaption by ENGINEER ARTICLE 4—AVAILABILITY OF LANDS; SUBSUR-FACE AND PHYSICAL CONDITIONS; REFERENCE POINTS Avmlobiliry of Lands: 4.1. OWNER shall furnish,. as indicated in the Contract Documents, the lands upon which the Work is to be performed, rights-af--way and crements for access thereto, and such other lands which ate designated for the use of CONTRACMPL Upon reasonable written request; OWNER shall furnish CON- TRACTOR with a correct statement of record legal title and legal description of the lands upon which the Work is to be performed and OWNER's interest therein as necessary for giving notice of or filing a mechanic's Gen against such lands in accordance with apprtable Taws and Regulations. OWNER stall identify any encumbrances or restrictions riot of genial application but specifically related to use of lands so furnished with which CONTRACTOR will have to comply in performing the Work. Easements for ponrament structures or permanent changes in existing fadrities will be obtained and paid for by OWNER unless otherwise provided in the Contract Docu- ments. If CONTRACTOR and OWNER are unable to agree on entitlement to or the amount or extent of any adjustments in the Contract Price or the Contras Times as a result of any delay in OWNER's furnishing these lands. rights -of -way or casements. CONTRACTOR may make a claim therefor as provided in Articles II and 12. CONTRACTOR shall provide for all additional lands and ar.=s thereto that may be required for temporary construction facilities or storage of materials and equipment. 4.L Subsarf= and Physical CondItim : 4? I. Reports and Drawings: Reference is made to the Supplementary Conditions for identification of: 4.M.1. Subsurjnce Candufont: Those reports of explo- rations and tests of subsurface conditions at or contiguous to the site that have been utilized by. ENGINEER in preparing the Contract Documents; and 4.L I? Physical ConcUtions: Those drawings of physical conditions in or rdadtrg to existing surface or subsurface smu a, at or camiguau to the site,(exeept Underground FazTties) that have been utilized by ENGINEER in ptspar- ing the Contract Documents. 17 4" Limited Reliance by t.UNTRACTOR Atrtho'ced. Technical Data: CONTRACTOR may rely upon the general acuraey of the "technical data" contained in such report/ and drawings, but such reports and drowmi p are not Contract Documents. Such "technical data•• is identified in the Supple- mentary Conditions Except for such reliance on such "tech- nical data," CONTRACTOR may not rely upon or mike any, claim against OWNER. ENGINEER or any of ENGINEER'S Consultants with respect to: 4 �? 1. the completeness of such reports and drawings for CONTRACTOR': purposes, including, but not limited to, any aspeeu of the means, methods, techniques, se. quences and procedures of construction to be employed by CONTRACTOR and safety precautions and program inci- dent thereto, or 4'—Z3 other data, interpretations, opinions and irdor- mation contained in such reports or shown or indicated in such drawings, or 4? 23• any CONTRACTOR interpretadon of or conclu- sion'drawn from any "technical data" or any such data, interpretations, Opinions or inforrnadarL - ' 4•23. Notice of D(fering Subsurface or Physical Coady dons: If CONTRACTOR believes that any subsurface or Physical condition at or contiguous to the site that is uncovered or revealed either. 4.L3.1. is of such a nature as to establish that any •'technical data" an which CONTRACTOR is entitled to. rely as provided in paragraphs 4? I and 41 is materially leaxurate, or 4.13.2 is of such a nature as to require a change in the Contract Documents, or. - 4.233. differs materialiv from that shown or indicated in the Contract Documents. or 41.3.4. ' is of an unusual suture. and differs materially. from conditions ordmenly encountered and generally recog- nized as inherent in work of the character provided for in the Contract Daeumentr'then CONTRACTOR shall, promptly after becoming aware thereof and before (lather disturbing conditions affected thereby or performing any Work in connection therewith (except in an cmeBencY as Permitted by paragraph 6.23), notify OWNER and ENGINEER in writing about such condition. CONTRAC- TOR shaf not further disturb such conditions or perform any Work in connection therewith (except as aforesaid) nml re. celpt of written order to do so. 4? 4. ENGINFMR's Review: ENGINEER will promptly review the Perthneot conditions, determine the necessity of OWNER's obtaining additional exploration or tests with re. :Peet thereto and advise OWNER in writing (with a copy to CONTRACTOR) of ENGINEER's findings and conclusions. 4.2-3. Possible Contract Doeamenu Change: If ENGI- NEER concludes that a change in the Contract Documents is required as a result of a condition that meets one or more of the cuegories in paragraph 42l., a Work Change Directive or a Change Omer will be issued as provided in Article 10 to reflect and document the consequences of such change. 4? 6 Passaic Price and Times Adjustments: An equitable adjusmnent in the' Contract Price or in the Contiact Tunes, or both. wall be allowed to the extent that the existence of such uncovered or revealed condition cause an increase or de-' cease in CONTR kCIOR's cost or, or time required for perfottnance of, the Wark; subject. however, to the followhilp, 4? 6.1: such condition must meet any one or more of the categories described in paragraphs 4.2.3.1 through 423.4, inclusive; 4.2.6.L a change in the Contract Documents pursuant to paragraph 4.23 will not be an automatic authoiffitioo of nor a condition precedent to entitlement to any such adjustment:. 4Z6.3. with respect to Work that is paid for on.a Unit Price Basis, any adjustment in Contract Price will be subject_ to the provisions of paragraphs 9.10 and 11.9; and 4 2.6.4. CONTRACTOR shall not be entitled to any adjustment in the Contract Price or Irma if-, 4.2.6.4.1. CONTRACTOR knew of the existence of such conditions at the time CONTRACTOR Trade a firhal commitmem to OWNER in respect of Contract Price and Contract Tuna by the submission of a bid or becoming bound under a negotiated contract; or . 43 6.4.2. the existence of such condition could rea- sonably have been discovered or revealed at a result of any examination; investigation, exploration, tat or study of the site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for CONTRACTOR prior to CONTRACiOR's [Waking such final commitment; or .4Z6.43. CONTRACTOR fatted to give the written notice within the time and as required by paragraph 4? 3. If OWNER and CON*—. ACTOR arc unable to agree on entitlement to or as to the amount or length of any such equitable adjustment in the Contract price or Contract Tunes, a claim may be made thereforas provided in Articles 1 I and 12. However, OWNER ENGINEER and ENGINEER's Consult- ants shall not be ruble to CONTRACTOR for any claims, costs, losses or damages sustained by CONTRACTOR on or in connection with any other project or anticipated projL-- 43. Ph;aad Conddont--Undogmund Facader. 4.3.1. Shown or indlcared: TNe infometion and dam shown Or indicated in the Contract Documents with respcx in existing Underground Facilities at or contiguous to the site is based on is F information and data furnished to OWNER or ENGINEER by the owners of such Underground Facilities or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: 4.3.1.1. OWNER and ENGINEER shall not be respon, srble for.the accuracy or completeness of any such inform - donor data, and 4.3.1-7 The cost of all of the following win be included in the Contract Price and CONTRACTOR shall have full respon- sfoEiry for. 0 reviewing and cherldng all such infort®tion and data, i7 locating aD Underground &&ides shown or indicated in the Comrru Documents. (m cooroaradon of the Work with the owners of such Underground Facilities during construction. , and (v) the safety and protection of all such Underground 'Facilitics as provided in paragraph 6.m and repairing any damage thereto resulting from the Work. 43? Not Shown or Indicated: If an Underground Facility is uncovered or revealed at or contiguous to the site which was not shown or indicated in the Contract Docu scrim CON- TRACTOR shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or per- forming any Work in connection therewith (except in an cmersency as Wired by paragraph 6M), identify the owner of such Underground Facility and give written notice to that owner and to OWNER and ENGINEER ENGINEER will prompdy.review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to re&ct and document the consequences of the existence of the Underground Facirity. If ENGINEER con- cludes that a change in the Contract Documents is requited, a Work Change Directive or a Change Order will be issued as provided in Article 10 to reflect and document such conse- quences. During such time. CONTRACTOR shall be respon- aible for the safety and protection of such Underground Factliry as provided in paragraph-620. CONTRACTOR shall be al- lowed an incase in the Contract Prix or an extension of the Contract Times, or both, to the extent that they are attributable to the existence of any Underground Fatality that was not shown or indicated in the Contract Documents and that CON- TRACTOR did not know of and could not reasonably have been expected to be aware of or to have anticipated. If OWNER and CONTRACTOR are unable to agree on eatitie- mett to or the amount or length of any such adUustment in Contract Price or Contract Tunes, CONTRACTOR may make a claim therefor as provided in Ardcla .l l and 12. However; OWNER, ENGINEER and ENGINEER's Consultants shall not be Gable to CONTRACTOR for any claims, costs: losses or damages incurred or sustained by CONTRACTOR on or in connection with any other project or anticipated project. Re erxn" Poinit: 4.4. OWNER shall provide engineering surveys to estab- fsh reference points for concoction which in ENGINEER's judgment are necessary to enable CONTRACTOR to proceed with the Work. CONTRACTOR shall be responsible for laying out the . Work, shall' protect and preserve _the established reference points and shall make no changes or relocations without the prior written approval of OWNER CONTRAC- TOR shall report to ENGINEER whenever any reference point is lost or destroyed or requires relocation because of necessary changes in grodei or locations, and shall be respon- stble,for the accurnte replacement or relocation of such refer- ence points by:professionally qualified personnel. 4.5. Asbestos, PCBs, Petrolenm, Hazardous Waste or Radio- actfve Material: 4.5.1. OWNER shall be responsible for any Asbestos, PCBs. Petroleum. Hazardous Waste or Radioactive Material uncovered or revealed at the site which was not shown or 'mdrated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work and which may present a substantial danger to persons or property exposed thereto in connection with the Work at the site. OWNER shall not be responsible for any such materials brought to the site by CONTRACTOR. Subcontractor, Suppli- en or anyone else for whom CONTRACTOR is responsible. 4S1. CONTRACTOR shall immediately n stop all Work in connection with.such hazardous condition and in any'area affected thereby (except in -an emergency as re- quired by paragraph 6.3). and Q notify OWNER and ENGINEER (and thereafter confirm such notice in writing). OWNER shall promptly consult with ENGINEER concern- ing the necessity for OWNER to rcmin a qualified expert to evaluate such haardous condition or take corrective action, if any. CONTRACTOR shall not be required to resume Work in connection with such hazardous condition or in any such affected area unnl after OWNER has obtained any required permits related. thereto and delivered to CONTRACTOR special written notice: () specifying that such condition and any affected area is or has been tendered safe for the resumption of Worki or n specifying any special conditions under which such Work may be resumed safely. If OWNER and CONTRACTOR cannot agree as to entidemem to or the amount or extent of an 4ustment, if any, in Contract Price or Contract Times as a result or such Work stoppage or such special conditions under which Work is agreed by CON- TRACTOR to be resumed, either party may make a claim. therefor as provided in Articles 11 and 12. 433. If after receipt of such special written notice CONTRACTOR does not agree to resume such Work based on a reasonable belief it is unsafe, or oes not agree to resume such Woik under such special conditions, then OWNER may order such portion of the Work that is in connection with such hazardous condition or in such af- fected area to be deleted from the Work. if OWNER and CONTRACTOR cannot agree as to entitlement to or the amount or extent of an aajusunent, if any, in Contract Prix or Contract Tunes as a result of deleting such portion of the Work. then either parry may make a claim therefor as provided in Articles 11. and 11 OWNER may have such defend portion of the Work performed by OWNER's own forces or others in axordance with Article 7. 45.4. To the Itillest extent permitted by Laws and Reg- ulations. OWNER shall indemnify. and hold harmless CON- TRACTOR Subcontractors. ENGINEER. ENGINEER's 19 1 Consultants and the officers, directors. employees, agents. Other consultants and subcontractors of each and any of them from and against an claims. costs. lasses and damages wising out of or resulting from such hazardous.condition, Provided that: n-any such -claim. cost. loss or damage is atitioutable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itsa, including the loss of use resulting therefrom. and no nothing in this subparagraph 45.4 shall obligate OWNER to indemnify any person or entity from and against the consequences of that petson's or entity's own neghi- gene. 4.5.5. The provisions of paragraphs 4_ and 43 are not inteaded to apply to Asbestos, PCBrole s. Petum, Hazardous Waste or Radioactive Material uncovered or revealed at the Sim ARTICLE5—BONDS AND INSURANCE PVfoM-=Ce, PaYment and OdwBondr:" 5.1. CONTRACTOR shall furnish PCdonaance and Pay - meat Bonds. each in an amount ht least equal to the Contract Price as security for the faithful performance and payment of an CONTRACTOR's obligations under the Contract Docu. menu Tbese Bonds shall remain in' effect at least until one Year after the date when final payment becomes due, except as Provided otherwise by Laws or Regulations or by the Contract Documents. CONTRACTOR shall also furnish such other Bonds as are required by the Supplementary Conditions. An Bonds -shall be in the form prescribed by the Contract Docr- menWCXc-cat as provided otherwise by Laws or Regulations. and shall be executed by such sureties as "ate named in the current list or "Companies Holding Certificnes of Authority as Actxptabic Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Cucularro (amended) by the Audi Staff, Bureau of Government Financial Opera - dons, U.S. Treasury Department. All Bonds signed by an agora must be accompanied by a certified copy of such agent's authority to act. 5.1 If the surety on any Bond furnished by CONTRAC. TOR is declared a bankrupt or becomes insolvent or its right to do busiuess is terminated in any state where any part of the Project is located or it ceases to meet the requirements of paragraph 5.1. CONTRACMR shall within ten days thereafter substitute another Bond and surety, both of which must be acceptable to OWNER SA lloatred Sureties and Insurers; C"ci 1parer of lanx o c 1 53.1. An Bonds and insurance required by the Contract J DOMmrnts to be purchased and maintained by OWNER or CONTRACTOR shall be obtained from surety or insurance companies that art duly licensed or authorized in the juris- diction in. which the prefect is located to issue Bonds or insurance policies for the Twits and coverages so required. Such surety and irunrance companies shall also meet such additional requirateeits and qualifications as may be pro- vided in the Supplementary Conditions. 53? CONTRACTOR shall deliver to OWNicR, with copies to each additional insured identified in the Supple. mentary Conditions, cerdficlues of insurance (and other evidence of insimin a requested by OWNER or any other Additional insured) which CONTRACTOR is requited to purchase and maintain in accordance with paragraph 5.4. OWNER shall deliver to CONTRACTOR, with copies to each additional" insured identified in the Supplementary Conditions, certificates of insurance (arid other evidence of insurance requested by CONTRACTOR or any other ad& tionial insured) which OWNER is required to purchase and maintain in accordance with'paragraphs 5.6 and 5.7 hereof. CONMACTOR's IlabsTuy Irtrmvnee. 5.4. CONTRAC-MR shallpurchase and maintain such liability and other insurance as is appropriate for the Work being performed and famished and as will provide protection from claims set forth below which may arise out of or result from CONTRACIUR's performance and furnishing of the Work and CONTRACTOR's other obligations under the Con- tract Docaweats, whether it is to be performed or furnished by CONTRACTOR, any Subcontractor or Supplier, or by anyone directly or indiiectly employed by any of them to perform or furnish any of the Work, or by anyone for whose aces any of them may be liable: 5.4.1. Claims under workers' compensation, disability benefits and other similar employee benefit acts; 5.4.1 claims for damages because' of bodily -injury. oc- eupational Sickness or disease, or death of CON'rRAC. TOR's employees; 5.43. claims for damages because of bodily injury, sick- ness or disase, or death of any person other than CON- TRAC MR% employees; 5.4.4. claims for damages insured by customary personal INury liability coverage which are sustained: ni by any Person as a result of an offense directly or indirectly related to the employment of such person by CONTRACTOR, or (uj by any other person for any other reason; 5.4.5. claims; for damages, other than to the Work itself. bemuse of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 5.4.6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership. maintenance or use of any motor vehicle. u The policies of insurance so_requimd by this paragraph 5.4 to be purchased and maintained shall: 5.4.7. with respect to insurance required by paragraphs 5.43 through 5.4.6 inclusive, include as additional insureds (sugieet to any customary exclusion in respect of piofm- sional liability) OWNER ENGINEER ENGINEER's Coo- sultana and any other persons or entities identified in the Supplementary Conditions, all of whom shag be listed as additional insureds, and include coverage for the respective a>5tzis and employees of all such additional iawredi; 5.4.8. include the specific coverages and be written for not less than the limit of liability provided in the Supple- mentary Conditions or `required by Laws or Regulations, whichever is greater, 5.4.9. include completed operations insurance; 5.4.10. include contractual liability insurance covering CONTRAC717OR's indemnity obtiptions.under paragraphs 6.12, 6.16 and 631 through 633; 5.4.11. contain a provision or endorsement that the .coverage afforded will not be cancelled, materially changed or renewal refined until at least thirty days prior written notice has been given to -OWNER and CONTRACTOR and to each other additional insured identified in the Supplcmen- tary Conditions to whom a.cettifttate of insurance has been issued, (and the certifies of insurance furnished by the CONTRACTOR pursuant to paragraph 53.2 will so pro- vide); 5.4.12. r'cTMa in effect at leasi umil final payment and at 'an times thereafter when CONTRACTOR may be correct- ing, removing or replacing defective Fork in accordance - with paragraph 13.12; and 5.4.13. with respect tocompleted operations, insurance, and any insurance coverage wiirten on a clans-made.basis, remain in effect for at least two yeah after final piy:neni (and CONTRACIOR'shall furnish OWNER and riaeh other additional insured identified in the Supplementary Condi- tions to whom a eertificau of insurance has been issued evidence sadsfactory to OWNER and any such additional' insured of continuation of such insuanc at final payment . and,one year thereafter). OWNER's Lkbr7u7 frtrrrmrer 5.5. In addition to the insurance required to be provided by CONTRACTOR uiider paragraph 5.4..OWNER at OWNER's option, may purchase and maintain at OWNER's expense OWNER's own liability insurance as will protect OWNER against claim which may arise from operations under the Contract Document. Pmperry frurrm cc: 5.6. Unless otherwise provided in the Supplementary Con- ditions. OWNER shall purchase and maintain property init r- ante upon the Work at the site in the amount of the fug replacement cost thereof (subject to such deducible amount as may be provided in' the Supplementary. Conditions or required by Laws and Regulations). This insurance shag 5.6.1. include the interests of OWNER CONTRAC- TOR Subcontractors, ,ENGINEER ENGINEER's Con- sultants and any other persons or entities identified in the Supplementary Conditions, each of whom is deemed to have an insurable interest and shag be listed as an insured or additional insured: 5.6.L be writtenon a Builder's Risk "all-risk" cr open peel or,sp=W asses of loss policy, form that shag at lc= include insurance for physical loss or damage to the Work, temporary buildings, falsework and Work in transit and shag insure against at least the following penis fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage, and such other perils as may be specifically required by the Supplementary Conditions; 5.63. include expenses incurred in the repair or replace- ment of any insured property (including but not limited to fees and,charges of engineers and architect 5.6.4, cover materials and equipment stated at the site or at another location that was agreed to in writing by OWNER prior to being incorporated in,the Work, provided that such materials and equipment have been included in an Appfica- tion for Payment recommended by ENGINEER: and 5.63. be maintained in effect until final payment is made unless otherwise agreed to in' writing by OWNER, CON- TRACTOR and ENGINEER with thirty days written. notice to each other additional insured to whom a certificate of Insurance has been issued. 5.7. OWNER shah purchase and maintain such boiler and machinery insurance or additional property insurance as may be required,by the Supplementary Conditions or Laws and Reguladotis which will include the interests of OWNER CONTRACTOR, Subcontractors. ENGINEER, ENGINEER': Consultants and any other persons or entities identified in the Suppieatentary Conditions, each of whom is deemed to have an insurable interest and shall be listed as an insured or additional insured 5.3. An the policies of insurance (and the cerdfiata or other evidence thereof) required to be purchased and main- tained by OWNER in accordance with paragraphs 5.6 and 5.7 will contain a provision or endorsement that the coverage afforded will not be cancelled or materially changed or renewal refused until at least thirty days' prior written notice has been given to OWNER and CONTRACTOR and to each other additional insured to whom a certificate of insurance has beea issued and will contain waiver provisions in accordance with paragraph 5.11: 21 5.9. OWNER shall not be responsible for purchasing and maintaining any property insurance to protect the interests of .CONTRACTOR, Subconuaetom or others in the Work to the extent of any deductible amounts that are identified in the Supplementary Conditions. The risk of loss within such iden- tified deductible amount, will be bottle by CONTRACTOR. Subcontractor or others suffering any such loss and if any of them wishes Property insurance coverage within the limits of such amounts, each may purchase and maintain'it at the purchaser's own expense. 5.10. If CONTRACTOR requests in writing that other special insurance be included in the property insurance policies Provided under paragraphs 5.6 or 5.7. OWNER Shan, if posse Me, include such insurance, and the cost thereof will be charged to CONTRACTOR by appropriate Change Order or Written Amendment: Prior to commencement of the Work at the site. OWNER shall in writing advise CONTRACTOR Whether or not such othr, insurance has been procured by OWNER. 5.11. Revsr of fti=.. 5.11.1. OWNER and COMRACMR intend that all Policies purchased in accordance with paragraphs 5.6 and 5.7 will protect OWNER, CONT RACIOR, Subcontractors, ENGINEER, ENGINEER's Consultants and all other per- sons or entities identified in the Supplementary Conditions to be listed as insureds or additional insureds in such policies and will provide primary coverage for an losses and damages caused by the penis covered thereby. All such policies shall contain Provisions to the effect that in the event of payment Of any loss or damage the insures will have no rights of recovery against any of the insureds or additional insureds thereunder. OWNER and CONTRACTOR waive an rights against each other and their respective officers, ditectors, employees and agents for an losses and damages caused by, arising out of or resulting from any of the perils covered by such policies and any other property insurance appU=bie to the Work; and, in addition, waive an such rights against. Subcontractors, ENGINEER; ENGINEER's Consultants and en other persons or entities identified in the Supplemen- tary Conditions to be listed as insureds or additional insureds under such policies for losses and damages so caused. None of the above waivers shin extend to the rights that any party ttuakiag such waiver may have to the proceeds of insurance held by OWNER as trustee or otherwise payable under any policy so issued. , 5.112 In addition, OWNER waives an 'rights against CON'TRAt, M& Subcontractors, ENGINEER, ENGI- NEER's Consultants and the officers, directors, employees. and agents of any of them, for. 5.1121. loss due to business interruption, loss of use or other consequential loss extending beyond direct phys- ical loss or damage to OWNER's property or the Work caused by, arising out of or resulting from fire or -other Peril. whether or not insured by OWNER; and S.I 1 17 loss or damage to the completed Project or Part thereof caused by, arising out of or resulting from fire !or other insured. peril covered, by any property insurance maintained on the completed Project or part thereof by OWNER. during partialuttilization Pursuant to paragraph 14.10, after substantial completion pursuant to paragraph 14.8 or after final payment put== to paragraph 14.13. Any insurance policy maintained by OWNER covering any loss, damage or consequential loss referred m in this paragraph S.1 12 shall contain provisions to the effect that in the event of Payment of any, such loss, damage or consequential loss the insurers will have no rights of recovery against any.of CON- TRAC'MR.Subcoattacton, ENGINEER, ENGINEER's Ccn- stdtans and the officers, directors, employees and agents of any of them. Receipt and Application of Insurance Proceeds 5.12. Any insured loss under the policies of insurance required by paragraphs 5.6 and 5.7 will be adjusted with OWNER and' made payable to OWNER as fiduciary for the insureds, as their interests may appear, subject to the require- ments of any applicable mortgage clause and of paragraph 5.13. OWNER shall deposii account a separate aount any money so received, and shall distribute it in accordance with such agree- ment ai the parties in interest may reach If no other special agreement is reached the'damaged Work shall be repaired or replaced, the moneys so received applied on account thereof and the Work and the cost thereof covered by an appropriate Change Order or Written Amendment 5.13. OWNER as fiduciary shall have -power to adjust and settle any loss with the insurers unless one of the, parties in interest shall object in writing within fifteen days after the occurrence of loss to OWNER's exercise of this power. irsuch objection be made, OWNER as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may teach. If no such agreement among the pardes in interest is reached. OWNER as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any pay in interest OWNER as fiduciary shall give bond for the proper performance of such duties. Aeerprance of Bander and Insunu=, option to Replace. 5.14. If either party (OWNER or CONTRACTOR) has any objection to the coverage afforded by or other provisions of the Bonds or insurance required to be purchased and maintained by the other party in accordance with Article S 6n the basis of non-conformance with the Contract Documents, the objecting Party shall so notify the other party in writing within ten days after receipt of the certificates (or other evidence requested) required by Paragraph 2:7. OWNER and CONTRACTOR shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request If either parry does not purchase or maintain an of the Bonds and Insurance required of such parry by the Contract Documents, such party shall notify the other party in writing of such fariure to purchase prior to the start of the Work or of such failure to maintain prior to any change in the required coverage- Without prejudice to any other right or remedy, the other party may deer to obtain equivalent Bonds or insurance to protect such other Parry's interests at the expense of the party who was 22 required to provide such coverage, and tinge Order shall be issued to adjust the Contract Price accordingly. Pardal UoTvadon—Property lnsum=: 5.15. if OWNER finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work such use or omtpancy may be accomplished in accordance with paragraph 14.10; provided that -no such use or occupancy shall commence before the insurers providing the property insurance have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property incur once shall not be cancelled or permitted to lapse on account of any sueh'parual use or occupancy. ARTICLE 6--CONTRACTOR'S RESPONSIBILITIES Saperviaon and Superinundene . 6.1. CONTRACTOR shall supervise, inspect and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Con- tract Documents. CONTRACTOR shall be. solely responsible for the means, methods, techniques, sequences and procedures of construction. but CONTRACTOR shall not be responsible for the negligence of others in the design or spcdit ..ion of a specific means, method, technique, sequence or procedure of construction which is shown or indicated in and, expressly required by the Contract Documents. CONTRACTOR shall be respotmble to see that the completed•,Work compiles accu- rarely with the Contract Documents. 6? CONTRACTOR,shall .keep on the Worts at all times during its progress a competent resident superintendent, who shall not be replaced without written notice to OWivER and ENGINEER except under extraordinary erzuumstances. The superintendent will be CONTRACTOR's representative at the site and shall have authority to act on behalf of COS -TRAC- TOR Ali communications to the superintendem'shall be as binding as if given to CONTRACTOR . . . Labor, Mmaials and Equipment: 63. CONTRACTOR shall provide competent- suitably yual- ified personnel to survcy, lay out and eonstruet'the Wdrk as required by the Contract Documents CONTRACTOR shall at all times maintain good discipline and order at the site. Except as otherwise required for the safety or protection of persons or the Work or property at the site or adjacent thei = and except as otherwise indicated in the Contract Document. all Work at the site shall be performed during regular working hours and CONTRACTOR will of mit overtime work or the perfor- mance of Work on Sruuruiiy. Sunday or any legal holiday without OWNER's written consent given after prior written notice to ENGINEER 6.4. Unless otherwise specified in the Gene. -al Require- ments. CONTRACTOR shall furnish and assume full respon- sibility fora0 materials, equipment. labor. transportation, con- suuetion equipment and machinery, tools, appliances, fuel. power.. fight. heat, telephone, water, sanitary facilities. tempo- rary facilities and all other facilities and incidentals necssary for the furnishing, performance, testing, start-up and comple- tion of the Work 6.5. All materials and equipment shall be of good quality and new, except as otherwise provided in the Contiaet Dour meats. Ali warranties and guarantees specifically called for by the Specifications shall expressly run to the benefit of G WNER. If required by ENGINEER CONTRAC.'TOR shall furnish satisfactory evidence Cmcluding reports of required tau) as to the kind and quality of materials and equipment. All materials and equipment shall be applied, installed,.eonnected, erected, used, cleaned and conditioned in accordance with instructions of the applicable Supplier, except as otherwise provided in the Contract Documents. Progress Scheduk: 6.6. CONTRACTOR shall adhere to the progress schedule established in accordance with paragraph 2.9 as it may be adjusted from time to time as provided below: 6.6.1. CONTRACTOR shall submit to ENGINEER for acceptance (to the extent indicated in paragraph 1.9) pro- posed adjustments in the progress schedule that will not change the Contract Times (or Milestones). Such adjust- mems will conform generally to the progress schedule then in effect and additionally will comply with any provisions of the General Requirements applicable thereto. 6-1 . Ptoposed.adjustatents in the progress schedule that will change the Contract Times (or Milestones) shall be submitted in accordance with the requirements of paragraph 12.1. Such may only be" made by a Change Order or Written Amendment in accordance with Article 12 V. Sabua4oaes mad "Orzq - ltems: 6.7.1. Whenever an item of material or. equipment Is specified or described in the Contract Documents by using the name of a proprietary item or the tame of a patticmlar SuppOer, the specification or description is intended to establish the type. function and quality required. Ufiless the specification or description contains or is followed by words realm` that no lice equivalent or "or-cgtal" items or no subsdatcion is permitted. other items of, material or equip - meet or material or equipment of other Suppliers may be accepted by ENGINEER under the following circumstances: 6.7.1.1. "Or•Equor': [fin ENGINEER's sole discre- tion an item of material or equipment proposed by CON- TRACTOR is functionally equal to that named and suffi. ciently similar so that no change in. related Work will be required, it may be considered by ENGINEER as an 'or-cqual" item, in which case review and approval of the Proposed item may, in ENGiNEER's sole discretion, be aromPl'uhed without compftance with some or all of the requirements for ac=prance of proposed substituteitems. 6.7.1.2. Substitute Items: If in ENGINEER's sole discretion an item of material or equipment proposed by CONTRACTOR does not qualify as an "or-equal".item under subparagraph 6.7.1.1, it will be considered a pro- posed substitute item. CONTRACTOR shall submit suffi- cient information as provided below to allow ENGINEER to determine Nat the item of material or equipment Proposed is essentially equivalent to that named and an acceptable substitute therefor. The procedure for review by the ENGINEER wn1 include the following as supple- mented in.the General Retjturnmenrs and as ENGINEER may decide is appropriate under the circumstances. R& quests for review of proposed substitute items of material or equipment will not be accepted by ENGINEER from anyone other than CONTRACTOR. If CONTRACTOR wishes to furnish or use a substitute item of material or equipment. CONTRACTOR shall first make written appli- .cadim to ENGINEER for acceptance thereof, certifying that the proposed substitute will perform adequately the functions and achieve the results caged for by the general design, be similar in substance to that specified and be suited to the same use as that specured. The application will state the extent, if any, to which the evaluation and acceptance of the proposed substitute will prejudice CON- TRACTOR's achievement of Substantial Completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) to adapt the design to the proposed substitute and whether or not incorporation or'use'of the substitute in connection with the Work is -subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service will be indi- cated. The application will also contain_ an itemized esti- mate of. an costs or credits that will result directly or indirectly from acceptance of such substitute, including costs of redesign and chitin of other contractors affected by the resulting change, an of which will be considered by ENGINEER in evaluating the proposed substitute. EN- GINEER may require CONTRACTOR to famish addi- -donal data about the Proposed substitute. 6.7.13. CONTP-4C70R's Espense: An data to be Provided by CONTRACTOR in support of any proposed "or -equal" or substitute item will be at CONTRACI'OR's expense. . 6.7-7Substirrue Cotstrucrion Merbnds or Procedures: if a Specific means, method, technique, sequence or procedure of construction is shown or indicated in and expressly requited by the Contract Documents, CONTRACTOR may furnish or utilize a substitute means, method, tcchnigtie, sequence or procedure of construction acceptable to ENGINEER CON. TRACTOR Shan submit sufficient information to allow ENGI- NEER, in ENGINEER': sole distinction, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The procedure for review by ENGI- NEER will be similar to that provided in subparagraph 6.7.1 ? 6.73. Engineer's Evaluation: ENGINEER will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to paragraphs,6.7.12 and 6.72. ENGINEER will be the sole judge of acceptability. No ,"on equal" or substitute will be ordered. installed or utilized Without ENGINEER's prior written acceptance which will be evidenced by either a Change Order or an approved Shop Drawing. OWNER may require CONTRACTOR to furnish at CONTRAC'IOR's expense a special performance guarantee or other surety with respect `to any "or -equal" or substitute. ENGINEER will record time required by ENGINEER. and ENGINEER's Consultants in evaluating substitutes proposed or submitted by CONTRACTOR pursuant to paragraphs 6.7.1.2 and 6.7 2 and in making changes in the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) occasioned thereby. Whether or not ENGINEER accepts a substitute item so proposed or submit- ted by CONTRACTOR; CONTRACTOR. shall reimburse OWNER for the charges. of ENGINEER and ENGINEER's Consultants for evaluating each such proposed substitute itern. Coneerninp Sabcalraaemrs, Suppliers and Odwm 6.8.1. CONTRACTOR shall not employ any Subeoo- tractor, Supplier or other person or organization {including those ac---ptable to OWNER and ENGINEER as indicated in paragraph 6.82),. whether initially or as a substitute, against whom'OWNER or ENGINEER may have reason- able objection. CONTRACTOR shall not be requited to employ any Subcontractor,.Suppner or other person or Organization to furnish or perform any of the Work against whom CONTRACTOR has reasonable objection. ' 6.8.2 If the Supplementary Conditions requite the iden- tity of certain Subcontractors, Suppliers or other persons or organizations (inclu(fing those who are to fui�nish the pdnci- pal items of materials or equiipment) to be submitted to OWNER in advance of the specified date prior to the Effective Data of the Agreement for acceptance by OWNER and ENGINEER, and if CONTRACTOR has submitted a list thereof in accordance with the Supplementary cots& [ions, OWNER's or ENGINEER': acceptance (either in writing or by failing to matte written objection thereto by the date indicated for acceptance or objection in the bi ldmg documents or the Contract Documents) of any such Subcon- tractor, Supplier or other person or organization so identified may be revoked* on the basis of reasonable objection after due investigation, in which case CONTRACTOR shall sub. mit an acceptable substitute, the Contract Price will be adjusted by the difference in the cost occasioned by such 24 e. substitution and an appropriate Change C will be issued or Written Amendment signed. No acceptance by OWNER _ or ENGINEER of any such Subcontractor. Supprict or other person or organization shall constitute a waiver of any right of OWNER or ENGINEER to reject defective Work. 6.9.1.- CONTR&ACTOR shall be Cully responsible to OWNER and ENGINEER for all acts and omissions of the Subcontractors. Suppliers and other persons and organia- dons performing or furnishing any of the Work under a direct or indirect contras with CONTRACTOR just as.CON- TRACMR is responsible for CONTRACMR's own aces and omissions. Nothing in the Contract Documents shall create for the benefit of any such Subcontractor, Supplier or other person or organization any contractual relationship between OWNER or ENGINEER and any such Subcon- tractor, Supplier or other person or orgatumtion, nor shah it create any obligation on the part of OWNER or ENGI- NEER to pay or to see to the payment of any moneys due any such Subcontractor; Supplier or, other person or organi- zation except as may otherwise be required by LAws and Regulations. 6.92. CONTRACTOR shall be solely responsiblefor scheduling and coordinating the Work of Subcontractors. Suppliers and other persons and organizations performing or famishing any of the Work under a direct or indirect contract with CONTRACTOR. CONTRACTOR shall require all Sub- contractors, Suppliers and such other persons and organia- dons performing or furnishing any of the Work to comi- cate with•the ENGINEER through CONTRACTORmun_ 6.10. The divisions and sections of the Specifications and' the identifications of any Drawings shall not control_CON- TRACTOR in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any . specific trade. 6.11. AD Work performed for CONTRACTOR by a Sub- contractor or Supplier will be pursuant to an appropriate agreement between CONTRAC.'I'OR and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Docu- ments for the benefit of OWNER and ENGINEER: Whenever any such agreement is with a Subcontractor or Supplier who is fisted as an additional insured an the property insurance provided in. paragraph 5.6 or 5.7, the agreement between the CONTRACTOR and the Subcontractor or Supplier will con - twin provisions whereby the Subcontractor or Supplier waive all rights against OWNER, CONTRACTOR, ENGINEER ENGWEER's Consultants and all other additional insureds for all losses and damages caused by, arising out of or resulting from any of the perils covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require'separate waiver forms to be signed by, any Subcontractor or Supplier. CONTRACTOR will obtain the same. Picric Fees and Rowlder. 6.I2. CONTRACTOR shall pay all license fees and royal- ties and assume all costs incident to the use in the performance 25 of the Work or the incorpc n in the Work of any invention, design, process, product or device which is the subject of patent rights or'copyrighu held by others. If a particular invention. design, process, productor device is specified in the Contract Documents for use in the performance of the Work and if to the actual knowledge of OWNER or ENGINEER its use is subject to patent rights.or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by OWNER in the Contract Documents. To the fufiest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harm- less OWNER, ENGINEER, ENGINEER's Consultants and the officers, directors, employees, agents and other consultants of each and any of them from and against all claims, costs, losses and damages -arising out of or resulting from any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the ineorpom- don in the Work of any invention, design, process, product or device not specified in the Contract Documents 633. Unless otherwise provided in the Supplementary Conditions, CONTRACTOR shag obtain and pay for all con- struction permits and ficeates. OWNER shall assist CON- TRAC MR, when necessary, in obtaining such permits and ficenses. CONTRACTOR shall pay all governmental charges and inspection fees necessary for the prosectnion of the Work, which are applicable at the time of opening of Bids, or, if there are no Bids, on the EBr-five Date of the Agreement. CON- TRACTOR shall pay all charges of utility owners for cormcc- tions to the Work, and OWNER shall pay all charges of such utility owners for capital costs related thereto such as plant investment fees. Laws and Regulaoons. 6.14.1. CONTIA=R shall give all notices and comply with all Laws andRegulations applicable to ftunishing sad' performance of the Work. Except where otherwise expressly requited by applicable Laws and Regulations, ncither0 WNER nor ENGINEER shall be responsible for monitoring CON- TRACTOR's cdmpliance with any Laws or Regulations. 6.141 . reaIf CONTRACTOR performs any Work knowing or having son to know that it is contrary' to Laws or Regulations. CONTRACTOR shaft bear all claims, costs. losses and damages caused_ by, arising outs of, or resulting therefrom: however, it shall not be CONTRACIOR's pri- mary responssbifiry maketmakecertain that the Specifications 'and Drawings are in accordance with Laws and Regulations. but this shall not relieve CONTRACTOR of CONTRAC- TOR's obligations under paragraph 33? Talc 6.15. CONTRACTOR shall pay all sales, consumer, use and other similar taxes required to be paid by CONTRACTOR in accordance with the Laws and Regulations of the plan of Documents unless CONTRACTOR has in writing called EN- TNEER's anention to each such variation at the time of submission as required by paragraph 6.25.3 and ENGINEER her given written approval of each such variation by speedic written natation thereof incorporated in or accompanying the Shop Drawing car Sample approval: nor will any approval by ENGINEER relieve CONTRACTOR from complying with the responsibility for tcquirements of paragraph 6.25.1. 6M- Where a Shop Drawing or Sample is required by the Contract Documents.or-the schedule of Shop Drawings and Sample submissions accepted by ENGINEER as required by Iaragraph 2.9, any related Wort performed prior to ENGI NEER's review and approval of the perti=t submittal win be at the sole "Paw and respongbifity of CONTRACTOR. Canda+dnr dw want 6z. CONTRACTOR Shan carry cam the Work and adhere to the ProB+ess'sche.dule during all disputes or disagreements with OWNER No Work shall be delayed or postponed pend- ing resolution of any disputes or disagreements, except as Permitted by Paragraph 15-5 or as OWNER and CONTRAC- TOR may otherwise agree in writing. 630. COMRACMR's Cea War7vr7 and G.,,••••_w- 630.1. CONTRACTOR warrants and guarantees . to OWNER, ENGINEER and ENGINEER's Consultants that an Work will be in accordance with the Contract Documents and will not be defective. CONTRAC OR's warranty and guammee hereunder excludes defects or damage caused by. 6.30.1.1. abuse, modification orimproper maintenance or operation by persons other than CONTRACTOR, Sub. -commacmrs or Suppliers; or 630.1 2 normal wear and tear under normal usage 630; CONTRAGTOR's obligatioh to perform and com- plete the Work in accordance with the Contract Documents shall be ibsolute. None of the following will constitute an a=ePmntx Of Work that is not in accordance with the Contract Documents or a release of CONfTRACTOR's obG- gstion to Perfbi m.the Work in accordance with the Contract Documents: 630.11. observations by ENGINEER; 630.2-.3. reeormnendation of any progress or final PsYmem by ENGINEER; 630,L3, the issuance of a certificate of Substantial Completion or any Payment by OWNER to CONTRAC. TOR under the Contract Documenri; 630? 4. use or occupancy of the Work or any pan thereof by OWNER; 630.2-5. any acceptance by OWNER or any failure to do so; 6.30.2 6. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of accept- ability by ENGINEER pursuant to paragraph 14.13; 6.30.2.7. any inspection. test or approval by others; or 630.2.8. any correction OfdefecriveWork byOWNM Cade°u rkadon: 6.31. To the fullest extent permitted by Laws and Regula- dons, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, ENGINEER's Consultants and the ofiicets. directors. employees, agents and other consults of each and any of them from and against an claims, costs, losses . and damages (including but not limited to an fees and charges of engineers, architects, attorneys and other professionals and all court or arbitration or other dispute resolution costs) caused by, arising out of or resulting from the performance of the Work, provided that any such claim, cost, loss or damage: (i) is attributable to bodfly injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, and n is eaused'in whole or in par by any negligent act or omission of CONTRACTOR, any Subcontractor, any Supplier, any person or Organization directly or indirectly employed by any of them to perform or furnish any of the Work or anyone for whose acts any of them may be Gable, regardless of whether or not caused in part by any negligence or omission of a person or entity indemnified hereunder or whether liability is imposed upon such indemnified party by Laws and Regulations regard- less of the negligence of any such person or entity. 6.32. In any and all claims against OWNER orENGI- NEER or any of their respective consultants, agents. officers, directors or employees,by any employee (or the survivor or Personal representative of such employee) of CONTRACTOR, any Subcontractor, any Supplier, any Person or organization directly or indirectly. employed by arty of them to Perform or f wnish any of the Work, or anyone for whose acts any of them . may be Gable, the indemnification obligation under Paragraph 631 shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits le by or for CONTRACTOR or any such Subcontractor Snippier or other person or organization under workers' compensation acts, disability benefit acts or other employee benefit acts, 6-33• The indemnification obligations of CONTRACTOR under paragraph 631 shall not extend to the liability of ENGI- NEER and ENGINEER's Consultants, officers, directors, employees or agents caused by the professional negligence, errors or omissions of any of them. Swvivd of Obfiradann 634, 'All representations. indemnifications, warranties and guarantees made in, required by or given in accordance with 0 the Contract Documents, as well as all co:.......ing obligations indicated in the Contract Documents, will survive final pay- .mcnt, completion and acceptance of the Work and termination or completion of the Agreement. ARTICLE 7--OTHER WORK Related Work of Sitc 7.1. OWNER may perform other work related to the Project at the site by OWNER s own forces. or let other direct contracts therefor which shall contain General Condi- tions similar to these, or have other work performed by utility owners. If, the fact that such. other work is to be performed was not noted in the Contract Documents, then: (t) written notice thereof will be given to CONTRACTOR prior. to starting any such other work, and fit) CONTRAC- TOR may make'a claim therefor as provided in Articles I and 12 if CONTRACTOR believes that such performance will involve additional expense to CONTRACTOR or re- quires additional time and the parties are unable to agree as to the amount or extent thereof. 7.2. CONTRACTOR shall afford each other contractor who is a party to such a direct contract and each utility owner (and OWNER, if OWNER is performing the addi- tional work with OWNER's employees) proper and safe sizes to the site and a reasonable 'opportunity. for the introduction and storage of materials and equipment and the. execution of such other work and shall properly connect and coordinate the Work with theirs. Unless otherwise'provided in the. Contract Documents. CONTRACTOR shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and inte- grate with such other work. CONTRACTOR shall not en- danger any work of others by cutting; excavating or other- wise altering their work and will only cut or alter their work with the written consent of ENGINEER and the others whose work will be affected. The duties and responsibilities of CONTRACTOR under this paragraph are'for the benefit of such utility owners and other contractors to the extent that them ate comparable provisions for the benefit of CON- TRACTOR. in said direct contracts between OWNER and such utility owners and other contractors. 73. If the proper execution or results of any partof CONTRAC OR's Work depends upon work performed by others under this Article 7, CONTRACTOR shall inspect such other work and promptly report to ENGINEER in writing any delays, defects or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of CONTRACTOR's Work. CONTRAC MR's failure so to report Will consriaue an. acceptance of such other work as fit and proper for integration with CONTRACTOR': Work except for latent or nonappartnt defects and deficiencies in such other work. Coonfrrmaom- 7.4. If OWNER contracts with others for the performance of other work on the Project at the site, the following will be set forth in Supplementary Conditions: ' 7.4.1. 'the person. firm or corporation who will have authority and responstt a try for coordination of the activities among the various prime contractors will be identified; 7.4.1 the specific mauers to be covered by such author- ity and responsibility will be itemized; and 7.43. the extent of such authority and responsibilities will be provided. , . Unless otherwise provided in, the Supplementary Condi- dons. OWNER shall have sole authority and responsibility in respect of such coordination. ARTICLE &_OWNER'S RESPONSIBILITIES 8 1. Except as otherwise provided in these General Condi. dons. OWNER shall issue all communications to CONTRAC. TOR through ENGINEER. 8.2 In case of termirmdon of the employment of ENGI- NEER. OWNER shall appoint an engineer against whom CONTRACTOR snakes no reasonable objection, whose status under the Contract Documents shall be that of the former ENGINEER .83. OWNER shall furnish the data required of OWNER under the Contract Documents promptly and shall make pay- ments to CONTRACTOR promptly when they are due as. provided in paragraphs 14.4 and 14.I3. 8.4. OWNER's duties in respect of providing lands and easements and providing engineering surveys to establish. ref- erence points are set forth in paragraphs 4.1 and 4.4. Paragraph 4.2 refers to OWNER's identifying and making available to CONTRACTOR copies of reports of explorations and tests of subsurface conditions at the site.and drawings of physical conditions in existing structures at or contiguous to the site that have bees utilized by ENGINEER in preparing the Contract Documents. F4 B.S. OWNER's responsibilities in respect of purchasing and maintaining liability and property insurance are set forth in paragraphs SS through S.10. L6. OWNER is obligated to execute Change Orders as indicated in paragraph 10.4. 8.7. OWNER's.responsibillty'in respect of certain inspc- dons, tests and approvals is set forth in paragraph 13.4. B.S. in connection with OWNER's right to stop Work or suspend Work. see paragraphs 13.10 and 15.1. paragraph 13.2 deals with OWNER's right to terminate services of CON- TRACTOR under certain circumstances. 8.9. The OWNER shall not supervise, direct or have control or authority over, nor be responsible for. CONTRAC. TOR's mcus, methods, techniques. sequences or procedures Of construction or the safety precaudons and programs incident thereto, or for any failure of CONTRACTOR to comply with haws and Regulations applable to the furnishing or perfor- mance of the Work OWNER will not be -responsible for CONTRACMR's failure to perform or furnish the Work in accordance with the Contract Documents. 8.10. OWNER'S rcponsibiliry in respect of undisclosed Asbestos, PCRs, Petroleum, Hazardous Waste or Radioactive Materials uncovered or revealed at the site is set. forth in Paragraph 4.9. 8.11. If and to the extent OWNER has agreed to furnish CONTRACTOR reasonable evidence that financial arrange- ments have been made to sadsfy OWNER's obligations under the Contract Documents. OWNER'S responsibility in respect thereof will be as set forth in the Supplementary. Conditions. ARTICLE 9—ENGINEER'S STATUS DURING CONSTRUCTION OWNER's Represeruadrr 9.1. ENGINEER will be OWNER's representative during the construction period. The dudes and resporastbib-ties and the limitations of authority. of ENGINEER as OWNER's repre- sentative during construction art: see forth in the Contract Documents and shall not be extended without Witten consent Of OWNER and ENGINEER. Vans to Sire. 9Z ENGINEER will make visits to the she at intervals appropriate to the various stages of construction as ENGI- NEER deems necessary in order to observe at an experienced and qualified design professional the progress that has been made and the quality of the various aspects of CONTRAC. TOR's executed Work. Rased oti information obtained dug * such visits and nbservadans, ENGINEER will endeavontil r for the benefit of OWNER to determine, in general. if cite Work is Proceeding in aeeordanm with the Contras Documents. EN- GINEER will not be requited to make exhaustive or continu- ous on -site inspections to check the quality or quandry of the Work. ENGiNHER's efforts will be directed towed providing for OWNER a greater degree of confidence that the completed Work will conform gtmeraly to the Contras Documents. On the basis of such visits and on -site observations, ENGINEER vvM keep OWNER informed of the progress of the Work and will endeavor to guard OWNER against defective Work. EN- GINEER's visits and on -site observations are subject.to an the limitations on ENGiNEER's authority and responsibility set' forth in Paragraph 9.13, and parderahatly, bud without l tdoidon. during or is a result of ENGINEER's on -site visits or observations of CONTRACfOR's Work ENGINEER will not supervise, direct control or have authority over or be'respon st'ble for CONTRAC OR's meats, methods, techniques, se. quence or procedures of construction, or the safety preau. tions and program incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations appl- able to the furnishing or performance of the, Work. Project Reprexr+rodrr: 9.3. If OWNER and ENGINEER afire-., ENGINEER win furnish a Resident Project Representative to assist. ENGT- NEER' in providing more continuous observation of the Work. The msponsibib'tiei and authority and limitations thereon of any such Resident Project Representative and assistants will be as provided in' -paragraph 9.13 and in the Supplementary Condidoas: If OWNER desigmtes another representative or agent.to represent OWNER at the site who is not ENGT- NEER's Consultant, agent or employee, the responsibilities and authority and limitations thereon of such other person will be as provided in the Supplementary Conditions. Ckrficadonr and 1XVPre=dQAr 9.4. ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the require. menus of the Contras Documents fin the form of Drawings or otherwise) as ENGINEER may determine necessary, which shall be consistent with the intent of and reasonably inferable from Contras Documents. Such written clarifications and interpretations will be binding on OWNER and CONTRAC. TOR. If OWNER or CONTRACTOR believes that a writtea clarification or interpretation jusdfies an acUustment in the Contract Price or the Conran Tunes and the parties are unable to agree to the amount or extent thereof, if any, OWNER or CONTRACTOR may make a written claim therefor as pro- vided in Article i 1 or Article.12. - .. Aurhar> sd,14mt®am in Wort: 9.5. ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment its the Contract price or the Contras hues and are comparable with the design concept of the completed project as a functioning whole as indicated by the Contras Documents. These may be accomplished by a Feld Order and will be binding on OWNER and also on CONTRACTOR who shall perform the Workinvolved promptly. If OWNER or CONTRACTOR believes that a Field Order jusdf= an adjustment in the Contract prim or the Cmus&ex Tuna and the parties are unable to agree as to the amount or extent thereof. OWNER or CONTRACTOR may make a written claim therefor as provided in Article I or 12. Rejermrg DeecdveWork 9.6. ENGINEER win have authority to disapprove or reject Work which ENGINEER believes to be defective, or 30 that ENGINEER believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents: ENGINEER will also have authority to require special inspec- tion or testing of the Work as provided in paragraph 13.9. whether or not the Work is fabricated, installed or completed. Shop Drt:wrrtgs, Chance Orders aced Paymentr. .. 9.7. In connection with ENGiNEER's authority as to Shop Drawings, and Samples. see paragraphs 6.24 through 6 28 inclusive. 9.8. In connection with ENGINEER': authority as to Change Orders, se-. Articles 10, I1, and 12. 9.9. In connection with ENGINEER's authority as to Applications for Payment, see Article 14. Daemrinadans for Unit Prices: 9.10. ENGINEER will determine the actual quantities and dusificac ons of Unit Price Work performed by CONTRAC- TOR ENGINEER will review.with CONTRACTOR the EN- GINEER's prcrtminary determinations on such matters Before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). ENGiNEER's written decision thereon will be final and binding upon OWNER and CONTRACTOR. unless, within ten days after the daze of any such decision. either OWNER or CON TRACTOR delivers to the other and to ENGINEER written notice of intention to appeal from ENGINEER's decision and: (J an appeal from ENGINEER's decision is taken within the time remits and in accordance with the procedures set forth in Exhibit GC -A: "Dispute Resolution Agreement.— entered into between OWNER and CONTRACTOR pursuant to Article 16. or (7 if no such Dispute Resolution Agreement has been entered into:• a formal proceeding is instituted by the appealing parry, in a forum of compacnt jurisdiction to exercise such rights or remedies as the appealing party may have with respect to ENGINEER's decision. unless otherwise agreed in writing by OWNER and CONTRACTOR. Such appeal will not be subjes[ to the procedures of paragraph 9.11. Decisions on Dirptacs: 9.11. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of, the acceptability of the Work thereunder. Claims. disputes and other matters relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the performance and furnishing of the Work and Claims under Articles 1 I and 12 in respect of changes in the Contra[ Price or Contract Times will be referred initially to ENGINEER in writing with a request for a formal decision in accordancewith this paragraph. Written notice -or each such claim, dispute or other matter will be delivered by the claimant to ENGINEER and the other party to the Agreement promptly (but in no event later than thirty days) after the start of the occurrence or event giving rise thereto, and written supporting data will be submitted to ENGINEER and the other party within sixty days after the start of such occurrence or event unless, ENGINEER allows an additional period of time for the submission of additional or more accurate data in support of such claim dispute or other matter. The opposing parry shall submit any response to ENGINEER and the claimant within thirty days after receipt of the claimant's last submittal (unless ENGINEER allows additional time). ENGINEER will render a formal decision in writing within thirty days after receipt of the opposing parry's submittal: if any, in accordance with this paragraph.. ENGINEER's written decision on such claim dispute or other matter will be firtal and binding upon OWNER and CONTRACTOR unless: 01 an appeal from ENGINEER': decision is taken within the time limits and in accordance with the procedures set forth in -EXHIBIT GC -A. "Dispute Reso- ludon Agreemen4' entered into between OWNER and CON- TRACTOR pursuant to Article 16. or CHI if no such Dispute Resolution Agreement has been entered. into, a written notice of intention to appeal from ENGiNEER's written decision is delivered by OWNER or CONTRACTOR to the other and to ENGINEER within thirty days after the date of such decision and a formal proceeding is instituted by the appealing party in a forum of competent jurisdiction to exercise such rights or remedies as the appealing party may have with respect to such claim, dispute or other matter in accordance with applicable Taws and Regulations within sixty days of the daze of such derision, unless otherwise agreed in writing by OWNER and CONTRACTOR. 9.12. When functioning as interpreter and judge under paragraphs 9.10 and 9.11. ENGINEER will not show partiality to OWNER or CONTRACTOR and will, not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to paragraphs 9.10 or 9.11 with respect to any such claim, dispute or other matter (except any which have been waived by the making or acceptance of final payment as provided in -paragraph 14.I5) will be a condition precedent to any. exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract Documents or by i.aws or Regulations in respect of any such claim, dispute or other matter pursuant to Article 16. 9.13. Lmamdons on ENGINEER's Audwruy and Reports Zades: 9.13.1. Neither ENGINEER-`s authority or responsibil- ity under this Article 9 or under any other provision of the Contract Documents nor any decision made by ENGINEER' in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise or performance of any authority or responsibility by ENGINEER shall create. impose or give rise to any duty owed by ENGINEER' to CONTRACTOR any Subcontractor, any Suppler, any other person or organization, or to any surety for or em- piovee or agent of any'of them. 9.13Z ENGINEER will not supe,-vise; duect, control or have authority over or, be responsible for CONTRAC• MR's meats, methods.,techniques, sequences or pro=. dures of construction. or the safety Precautions and. pro- grams incident thereto; or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the rnishing or per@mmance of the Work. ENGINEER will not bfue responsible forCO h the Work in n aNTRACIOR's Wure to perform or mmil ccordatse with the Cormaa Docu: rmenls. . 19.13.3. ENGINEER will not be responsible for the acts Or'ofnlss'oes of CONTRACTOR or of any Subcontractor, any Supplier, or of any other person or organization perform. ins or furnishing any of the Work. 9.13.4. ENGINEER's review Of[ he final Application for Payment and accompanying documentation and all maiate. Hance and operating instructions, schedules. guarantees, bonds and car ocates of inspection, tests and approvals and Other documentation required to be delivered.by Paragraph 14,12 will only be to determine generally that their content complies with the requirements of, and in the cats of certificates of inspections; tests and approvals that the results certified indicate compliance with. the Contract Doc- uments. 9.13.5. The limitations upon authority and responsibility set forth in this Paragraph 9.13 shall also apply to ENGI- NEER's Consultants. Resident Project Representative and assistants. ARTICLE 10•-.CHANGES IN THE WORK 10.1. Without invalidating the Agreement and without notice to any surety. OWNER may, at any time or from time to time, order additions, deletions or revisions in the Work. Such additions, deletions or revisions will be authorized by a Written Amendment, a Change Order, or a Work Change Directive. Upon receipt of any such document. CONTRAC- TOR shall promptly Proceed with the Work involved which will be Performed under the. applicable conditions of the Contract Documents (except as otherwise vided). specifically pro IOZ if OWNER and CONTRACTOR are unable to agree as to the extent. if any, of an adjustment in the Contract price or an adjustment of the Conttact Times that should be allowed. s a result of a Work Change Directive. a claim may be made therefor as provided in Article 1 I or Article 12. IOJ, CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any Work Performed that is not required by the Contract Documents as ascended, modified and supplemented as provided in Paragraphs 3.5 and 3.6 except in the case of an anue'Berhry as provided in Paragraph 6.11 or in the case of uncovering Work as provided in paragraph 13.9. 10.4. OWNER and CONTRACTOR shall execute appro- priate Change Orders recommended by ENGINEER (or Writ_ ten Amendments) covering: 10.4.1. changes in the Work which ate i7 ordered by OWNER pursuant to paragraph 10.1. n required because of acceptance of defective Work under paragraph 13.13 or correcting defective Work under paragraph 13.14, or (t agreed to by the parties; 10A.2, changes in the Contract Price or Contract Tama which are agreed to by the Parties; and 10.4,3, changes in the'Contract Price or Contract Tunes which embody the substance of any written decision ran. dered by ENGINEER pursuant to Paragraph,9.11; Provided that, in lieu of executing any such Change Order an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal. CON- TRACrOR'hail carry on the Work and adhere to the progress schedule as provided in paragraph 6.29. 10-5. If notice of change affecting the general scope of the Work or the provisions of the Contract Documents Gnciud- ins, but not limited to,. Contract Price or Contract Times) is required by the provisions of any Bond to be given to a surety, the giving of any such notice will be CONTRACMR's reiponf sblity, and the amount of each applicable Bond' will be adjusted accordingly. ARTICLE I [—CHANGE OF CONTRACT pRICt — ILL .The Conn= Price constitutes -the total compensa- tion•(subject to authorized adjustments) Payable to CON- TRACTOR for Perfomdng the Work. Ali duties, responvbiTr ties and obligations assigned to orundertaken by CONTRACTOR shall be at CONTRACTOR's expense without change in the Contra Price. 11 Z The Contract Prig, may only be changed by a Change Order or by a Written Amendment. Any claim for an adjust- ment in the Contract Price shall be based on written notice delivered by the party making the claim to the other parry and to ENGINEER promptly (but in no event later than thirty days) after the start of the occurrence or event giving rise to the claim and stating the general'=lure of the claim. Notice of the amount of the claim with supporting data shall be delivered within sixty days after the start of such occurrence or event (unless ENGINEER allows additional time for claimant to submit additional or more accurate data in support of the claim) and shall be accompanied by claimant's written statement that the adjustment claimed covers all known amounts to which the claimant is entitled as a result of said oceurrenee or event, All claims for adjustmeru in the Contract Price shall be determined by ENGINEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree on the amount involved. No claim for an adjustment in the Contract Price will 32 be valid if not submitted in accordance with this paragraph 11.3. The value of any Work covered by a Change Order or of any claim for an adjustment in the Contract Price will be determined as follows: 113.1. when: the Work involved is covered by unit pries contained in the Contract Documents, by application of such unit prices to the quantities of the items involved (subject to the provisions of paragraphs 11.9.1 through 11.93, inclusive); 11.3.1 where the Work involved is not covered by unit prices contained in the Contract Documents. by a muntally agreed lump sum (which may include an .aUowa= for overhead and profit not necessarily in accordance with paragraph 11.6.2); 1133. where the Work involved is not covered by, unit prices contained in the Contract Doarmemts and agreement to a lump sum is not reached under paragraph 113 1 on the basis of the Cost of the Work (determined as provided in paragraphs 11.4 and 11.5) plus a CONTRACIIOR's fee for overhead and profit (determined as provided in.paragraph 11.6). . ` cast of dw Wont^ 11.4. The term Cost of the Work means the sum of all costs necessarily incurred and paid by CONTRACMR in the proper performance of the Work. Except as otherwise may be agreed to in writing by OWNoun ER, such costs shall be in amts no higher than those prevailing in the locality of the Project, shall include only the following items and shall not include any of the costs itemized in paragraph 113: H A I. Payroll cost for employees in the direct employ of CONTRACMR in the performance of the Work under schedules of job classifications agreed upon by OWNER and CONTRACTOR. Such employees shall include without lim- itation superintendents, foremen and other personnel em- ployed fir!{- time at the site. Payroll costs for employees not employed full time on the Work shall be apportioned an the basis of their time spent on the Work. Payroll costs shall include, but not be' imited to, salaries and wages phis the cost of fringe benefits which shall include social iectuiry contributions, unemployment. excise and payroll taxer, work- ers' compensation: health and retirement benefits. bonuses. sick leave, vacation and holiday. pay applicable thereto. T'he expenses of performing Work after regular worfdng hours, on Saturday. Sunday or legal holidays. shall be inducted in the above to the extent authorized by OWNER. cash discounts shall accrue to OWNER. XII trade discounts, rebates and refunds and returns from sale of surplus materi- als and equipment shall accrue to OWNER, and CON- TRACTOR shall make provisions so that they may be obtained. 11.43. Payments made by CONTRACTOR to the Sub- contractors for Work performed or furnished by Subcontrac. tors. if required by OWNER, CON'T'R.ACMR shall obtain' compc#dve bids from subcontractors acceptable to OWNER and CONTRACTOR and shall deliver such bids to OWNER who will then determine, with the advice of ENGINEER, which bids. if any, ;will be accepted. If any subcontract provides that the Subcontractor into be paid on the basis of Costof the Work Plus a fee, the Subcontractors Cost of the Work and fee shall be determined in the same manner as C,ONTRACMR's Cost of the Work and fee as provided in paragraphs 11.4, 1IS, 11.6 and 11.7. All subcontracts shall be subject to the other provisions of the Contract Documents insofar as applicable. 11.4.4. 'Cotes of special consultants (including but not limited to engineers, architects, testing -laboratories, survey- ors, attorneys and accountants) employed for setvics spe- cifically related to the Work. 11.4.5. Supplemental costs including the following: 11.4.5.1. The proportion of necessary transportation, travel and subsistence expenses of CONTRACNR's em- ployees incurred in discharge of duties connected with -the Work. 11.4.5.2. Cost, including transportation and mainte- nance, of all materials, supplies, equipment, machinery, appliances, office and temporary facilities at the site and hand tools not, owned by the workers,which are con- sumed in the performance of the Work, and cost less market value of such items used but not consumed which remain the property of COhi'RACTOR. 11.4-5.3. Rentals of all construction equipment and .machinery and the part thereof whether rented from CONTRACTOR or others in accordance with rental agree- ments approved by. OWNER with the advice of ENGi- NEER, and the costs of transportation, loading, udoad- 'ing. installation. dismantling and removal thereof —all in accordance with the terms of said rental agreements. The rental of any such equipment, machinery or parts shall cease when the use thereof is no longer necessary for the Work 11.45.4. Sales, consumer. tue or similar taxes related to the Work, and for which CONT'RACIOR is liable, imposed by Laws and Regulations. 11.4.2. Cost of ap'materials and equipment furnished and btcorporated in the Work, including costs bf.transportation 11.4.5.5. Deposits lost for causes other than negli- and storage thereof, and Suppliers' field services required in Bence of CONTRACTOR any Subcontractor or anyone connection therewith. Allash discounts shall aeue to directly or indirectly employed by any of them or for CONTRACTOR unless OWNER deposits.timds with CON- whose acts any, of them may be liable, and royalty TRACLOR with which to make payments, in which case the payments and fees for permits and liccnses. 33 11.4.5.6. Losses and damages (and related expenses) °used by damage to the Work, not compensated by "'nce or otherwise, sustained by CONTRACTOR in connection with the Performance and furnishing of the Work (except losses and damages within the deductible amounts of Property insurance c=bfished by OWNER in accordance with paragraph 59). provided they have m. sulted Rom causes other than the nesugeice of CON- TRACTOR, any Subcontractor, or anyone directly or "direetly employed by any of them or for whose acts any of them may be liable, Such )oases shall include settle - meats. madewith the written consent and approval of OWNER. No such losses. damages and expenses shall be included in the Cost of the Work for the purpose of determining CONTRACTOR's fee.. If, however, any such loss or damage requires reconstruction and CONTRAC- TOR is plated in charge thereof, CONTRACTOR shall be paid for services a fee proportionate to that stated in paragraph 11.6 1 11.45:7. The cost of utilities, fuel and sanitary facili- tiesatthe site. _ 11.4.5.8. Minor expenses such as telegrams, long dis. tance telephone calls, telephone service at the site, ex- Prrssage and similar petty ash items in connecdon with the Work 11.45.9. Cost of premiums 'for additional Bonds and insurance required because of changes in the Work 11.5. The term Cost of the Work shall not include any of the following: 11.5.1, payroll costs and other compensation of CON- TRACTOR's.officers, executives, principals (of partnership and sole proprietorships), general managers: engineers, ar- ehitecs, estimators. attorneys. auditors, accountanis, pur- dmsing.and contracting agents, expediters. timekeepers. clerks and other personnel employed by CONTRACTOR whethcr-at the site or in CONTRACTOR's principal or a ,branch office for general administration of the Work and not specifically included in the agreed upon schedule of job d"`i c2dons referred to in paragraph 11.4.1 or specifically covered by paragraph 11.4.4—all or -which are to be consid- ered adnunstradve costs covered by the CONTRACTOR's tee. 11.31. " Expenses of CONTRACTOR's principal and branch 015ces other than CONT'RACTO R's office at the site. 11.5.3. Any part of CONTRACTOR': capital expenses, including interest on CONTRACTOR's apical employed for the Work and charges against CONTRACTOR for delin- quent payments. 11:5.4.- Cost Of premiums for a5 Bands and for 25 insurance whether or not CONTRACTOR is required by the Contract Doeunens to purchase and maintain the same (except for the cost of 11.4.5.9 above). premiums aovcrcd by subparagraph ' 11.5.5. Costs due to the negligence of CONTRAC_ TOR, any Subcontractor, or anyone directly or indi- rectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work,:disposal of materials or equipment wrongly supplied and malting good any damage to property. . Other overhead or general expense Cosa of any kind and the costs of any item not spccm-cally and expressly included in paragraph 11.4. 11.6. The CONTRACTOR's fee allowed to CONTRAC. TOR for overhead and profit shall be determined as fo8ows: 11.6.1. a mutually acceptable fixed fee; or 11.6-1 if a fixed fee is not agreed upon, then a fee based on the following percentages of the various Portions of the Cost of the Work: 11.6.2.1. for costs incurred under paragraphs 11.4.1 and .11.4.2. the CONTRACTOR's fee shall be fiftcn percent; for costs incurred under paragraph 11.43, the CONTRACTOR's fee shall be five pereent; 11.6.L3., where one or more des of subcontracts am on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of paragraphs 11.4.1. 11.41. 11.43 and 11.6.2 is that the Subcontractor who actually Performs or furnishes the Work. at whatever tier, wal be paid a fee of fifteen percent of the costs incurred by such Subcontractor under paragraphs 11.4.1 and 11.41 and that any higher tier Subcontractor and CONTRACTOR will. each be,paid a fe-_ of five"peree t of the amount paid to the next lower der Subcontractor, 1142.4. - no fee shall be payable on the basis of Coss itemized under paragraphs 11.4.4. 11.4.5 and 11.5; 11.6.M. the amount of credit to be allowed by CON- TRACTOR to OWNER for arty change whici results in a net decease in cost will be the amount of the actual oat decrease in cost plus a deduction in CONTRACTOR's fee by an amount equal to five Percent of such net decease; and 11.6 5 6. when both additions and credits are involved To any one change, the adjustment in CONTRACTOR': fee shall be computed on the basis of the set change in accordance with paragraphs 11.61-1 through Ili, inclusive. 11.7. Whenever the cost of any Work is to be determined pursuant to paragraphs 11.4 and 11.5, CONTRACTOR wTl =ablish and maintain records thereof in accordance with severally accepted accounting practices and submit in form acceptable to ENGINEER an itemized cost breakdown to. gether with supporting dais. 34 Carp Alfowanees. • I I.g. It is understood that CONTRACTOR has included in the Contract Price all allowances so named in the Contract Documents and shall cruse the Work so covered to be fur- nished and performed for such sums as may be acceptable to OWNER and ENGINEER CONTRACTOR agrees that: I I.g.1. the allowances include the- cost to CONTRAC- TOR (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the site. and all applicable taxes: and _ 11.8.2. CONTRACTOR's costs for unleadtog and han- dling on the site, hbor,'instalhtion costs. overhead. profit. and other expenses contemplated for the allowances have been included in the Contract Price and not in the allowances. and no demand for additional payment on &count of any of the foregoing will be valid. Prior to final payment. an appropriate Change Order w01 be issued as recommended by ENGINEER to reflect actual .amounts due CONTRACTOR on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.% Unk Price WO&* . 11.9.1. When: the Contract Documents provide that all or part of the Work is to be Unit Price Work. initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the rum of the established unit price for each separately idendfed item of Unit Price Work times the estimated quantity of each item.as indicated in the Agreement. The estimated quantities of item of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifica- tions of Unit Price Work performed by CONTRACTDR will be made by ENGINEER in accordance with paragraph 9.10. 11.9.L Each unit price will be deemed to include an - amount considered by CONT'RACMR to be adequate to cover CONTRACTOR's overhead and profit for each sepa- rately identified item. 11.93. OWNER or CONTRACTOR may make a claim for an adjustment in the Contract Price in accordance with Article I I if: 11.9.3.1. the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and sig- nificantly from the estimated quantity of such item in& cited in the Agreement: and 11.9.3? there is no corresponding adustment with respect to any other item of Work: and 11.933. if CONTRACTOR believes thin CONTRAC- TOR is entitled to an increase in Contract Price as a result of having incurred additional expense or OWNER be- lieves that OWNER is entitled to a decrcase in Contract Price and the parties are unable to agree ai to the amount of any such increase or dcc=cc, ARTICLE 12--CHANGE OF CONTRACT TIMES 12.1. The Contract: Tunes (or Milestones) may only be changed by a Change Order or,a Written Amendment Any claim for an adjustment of the Contract Times (or Milestones) shall be based an written notice delivered by the parry malting the claim to the other party and to ENGINEER promptly (but in no event law than thirty days) after the oc tttrrence of the even giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting. data shall be delivered within sixty days after such occurrence (unless ENGINEER allows an additional period of time to ascertain more -curate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment. claimed is the entire adjustment to .which the claimant has reason to believe it is entitled as a result of the occmronce of.said event. All claims for adjustment in the Contract Times (or Milestones) shall be determined by ENGI- NEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot. otherwise agree. No claim for an adjustment in the Contract Timcs (or Miestones) will be valid if not submitted in accordance with the requirements of this paragraph 12 I. 1� 1 All time limits stated in the Contract Doctmcnts are of the essence of the Agreement. 123. Where CONTRACTOR is prevented from complet- ing any part of the Work within the Contract Tunes (or - Milestones) due to delay beyond the control of.CONTRAC- TOR. the Cgnact Tunes (or Milestones) will be extended in an amour equal to the time lost due to such delay if a claim is made therefor as provided in paragraph 12_1. Delays beyond the control of CONTRACTOR shall include, but be limited to. acts or oeglect by OWNER acts or neglect of utility owners or other contractors perforating other work as contemplated by - Article 7, fim, floods. epidemics, abnormal'wcwher condi. tions or acts of God Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of CONTRACTOR. IZ A. Where CONTRACTOR is prevented from complet- ing any part of the Work within the Contract Tunes (or Milestones) due to delay beyond the control of both OWNER and CONTRACTOR. an extension of the Contract Times (or Milestones) in an amount equal to the time lost due to such delay shall be CONTRACTOR's sole and exclusive remedy for such delay. In no event shall OWNER be liable to CONTRAC- TOR. any Subcontractor. any SoppGer, any other person or orginiadon, or to any surety for or employee or agent of any of them, for daioages arising out of or resulting from () delays caused by or within the control of CONTRACTOR. or (u� 35 delays beyond the control of both parties including but not Gr limited to es• floods. epidemics, abnormal weather condi- jiens, acts of God or acts or neglect by utility owners or other contractors performing other work as contemplated by Article 7. ARTICLE 13—TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.1. Norice of Defects: Prompt notice of all defective Work of which OWNER or ENGINEER have actual knowl- edge will be given to CONTRACTOR. All defective Work may be rejrted, corrected or accepted as provided in this Article 13. Acc= to woriE 13-L OWNER, ENGINEER. ENGINEER's Consultants, Other representatives and personnel of OWNER, independent testing laboratories and governmental agenda with jurisdic- tional interests will have access to the Work at reasonable times for their observation, inspeedpg and testing. CONTRACTOR shall Provide them Proper and safe conditions for such access and advise them of CONTRACTOR's site safety procedures and programs So that they may comply therewith as applicable. Teas and Intpeedoa„ 13.3. CONTRACTOR shall give ENGINEER timely no - tic of readiness of the Work for all requited inspections, tests Or approvals and shall cooperate with inspection and testing Personnel to facilitate required inspections or tests, 13.4. OWNER Shan employ and pay for the services of an independent testing laboratory to perform all inspections; tests, or approyals required by the Contract Documents except: 13.4.1.., for inspectlons:'tests or approvals coveted by Paragraph 13.5 below; 13.4Z that wm incurred in connection with tests or inspections conducted Pursuant to paragraph 139 below. shall be paid as provided in said Paragraph 139; and 13.4.3. as otherwise spttfl=Hy provided in the Can. tract Documents. 133. If Laws or Regulations of any Public bady; having Jurisdiction require any Work (or Par thereon spec Ei + y to be inspected, tested or approved by an employee or other repre- sentative of such public body, CONTRACTOR shall assume full resPonsbiiity for arranging and obtaining such itupectiotu tests or approvals. pay 'an costs in connection therewith. and flunish ENGINEER the required certHlieatm of inspection. or approtal. CONTRACTOR shall also be responsible for arrang- ing and obtaining and shall pay all costs in connection with any inspections, tests or approvals required for OWNER's and ENGINEER's acceptance of materials or equipment to be incorporated in the Work, or of materials, mice designs, or equipment submitted for approval prior to CONTRACTOR's Purchase thereof for incorporation in the Work 13.6. If any. Work (or the work of.others) that is to be inspected, tested or approved is covered. by CONTRACTGR without written concurrence of ENGINEER, it must, if re quested by ENGINEER, be uncovered for observation. 13.7. Uncovering Work as provided in Pwagraph13.6 shay beatCONTRACTOR'S expense unless CO NIRACIUR has given ENGINEER timely notice of CONTRACMP's inter- don to cover the same and ENGINEER has not acted with reasonable prompmess in response to such notice. Uncovering wor.E U.S. If any Work is covered contrary to the written request of ENGINEER. it must, if requested by ENGINEER, be uncovered for ENGINEER's observation and replaced at CONTRACTOR's expense. 13.9. If ENGINEER considers it necessary or advisable that covered Work be observed by ENGINEER or ksprted or tested by others, CONTRACTOR, at ENGINEER's re- quest. shay uncover, expose or otherwise make available for Observation, inspection or testing as ENGINEER may requite, that portion of the Work in question; furnishing all necessary labor material and.equiPmenL If it is found that such Work is defeedve. CONTRACTOR shall pay all claims; costs, losses and damages caused by, arising out of or resulting from such uncovering, exposumt, observation, inspection and testing and of satisfactory replacement or reconstruction (including but not limited to all cbsts of repair or replacement of work of others); and OWNER shall be entitled to an appropriate decease in the Contract Price, and, if the parties are unable to agree as to the amount thereof. may make a claim therefor as provided in Article 11. If, however, such Work is not found to be defectne, CONTRACTOR Shen be allowed an increase in the Contract Price or an extension of the Contract Times (or Milestones), or body dbecdy attributable to such uncovering, exposure, ob- swvadon, inspccion, testing, replacement and reconstrnction; and, if the Parties are unable to agree as to the amount or extent thereof. CONTRACTOR may matte a claim therefor at prat vided in Articles I land IZ OWNFR May Smp the wont 13.10. If the Work is defective, or CONTRACTOR (arils to supply sufficient skilled workers or suitable materials or equip. meat,, or fans to furnish or Perform the Work in such a way that the completed Work will conform to the Contract Documents, OWNER may order CONTRACTOR to stop the Work, or any Portion thereof, until the cause for such order has best eliminated; however, this right of OWNER to stop the Work •36 shall not give rise to any duty on the part of OWNER to exercise this right for the bcocfit of CONTRACTOR or any Wrety or other party. Carremon or Removal of Defective Woric 13.11. If required by ENGINEER CONTRACTOR shall promptly, as directed. either correct all dgfeerive Work, whether or not fabricated, installed or completed. or, if the Work has been rejected by ENGINEi-3t,.remove it from the site and replace it with Work that is not defective: CONTRACTOR shall pay all claims, costs, losses and damages caused by or resulting from such correction Or removal dcluding but not limited to ( all costs of repair or replacement of work of others). 13.11 Common Period: 13.12.1. If within one year after the date of Substantial Completion or such longer period of time as may be pre- srnbed by Laws or Regulations or by the terror of any applicable special guarantee required by the Contract Doc. uments or by any specific provision of the Contract Docum. menu, any Work is found to be defective, CONTRACTOR shall promptly, without cost to OWNER and in accordance with OWNER's written (nsttuctions: 01 correct such deec- dye Work, or, if it has been rejected by OWNER, remove it from the site and replace it with Work that is not defective, and a satisfactorily correct or remove and replace any damage to other Work or the work of others.resulting therefrom If CONTRACTOR does not promptly comply with the terms of such instructions, or in an emergency -where delay would cause serious risk of loss or damage, OWNER may have the defective Work corrected or the rejected Work removed and replaced, and all claims. costs. losses and damages caused by.or resulting from such re- moval and replacement Cncluding but not limited to all costs of repair or replacement of work of others) will be paid by CONTRACTOR. . 13.12? In special drwatstances where a particular item of equipment is placed in continuous service before Substan- tial Completion of an the Work. the correction period for that, item may start to rum from an earlier date if so provided in the Specifications or by Written Amendment. 13.123. Where defective Work (and damage to other Work resrdting therefrom) has been comcted. removed or replaced under this paragraph 13.12, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or re- moval and replacement has bear satisfactonly completed. Acceptance gfDefective Work 13.13. If, instead of requiring correction or removal and replacemrnt of defective Work OWNER (and, Priest o ENGi- NEER's recommendation of final payment, also ENGINEER) prefers to accept it, OWNER may do so. CONT RACIOR shall pay all claims, costs, .___ts and damages attributable to OWNER's evaluation of and determination to accept such defective Work (sueh'costs to be approved by ENGINEER as to reasonableness). if any such acceptance occurs prior to ENGiNEER's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work: and OWNER shall be entitled to an appropriate decrease.in the Contract price, and, if the parties are unable to agree as to the amount thereof. OWNER may make a claim therefor as provided in Amide 11. If the acxptance oceans after such recommenda- tion, an appropriate amount will be paid by CONTRACTOR to OWNER OWNER May Correct Drfec ive Work. 13.14. if CONTRACTOR falls within a reasonable time after written notice from ENGINEER to correct defeerive Work.or to remove and replace rejected Work as required by ENGINEER in accordance with paragraph 13.1 I, or if CON- TRACTOR fails to perform the Work in accordance with the Contract Documents,' or if CONTRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days written notice to CONTRACTPR. correct and remedy any such deficiency. in exercising the rights and remedies under this paragraph OWNER shall pro- c=d expeditiously. In connection with such corrective and remedial action. OWNER may exclude CONTRACTOR float. all or pan of the site, take possession of all or part of the Work. and suspend CONTRACTOR'S services re!ated thereto, take possession of CONTRACIOR's tools, appliances. construc- tion equipment and machinery at the site and incorporate in the Work all materials and equipment stored at the she or for which OWNER has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow OWNER OWNER's "P. natives, agents and employees. OWNER's other can - tractors and ENGINEER and ENGINEER': Consultants ac- cess to the site to enable OWNER to exercise the rights and remedies. under this paragraph. AiI claims, costs, losses and damages incurred or sustained by OWNER in exercising such rights and remedies will be charged againstCONTRACTOR and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work. and OWNER shall be entitled to an appropriate decrease in the Contract Prim and. if the.parties are unable o agree as to the amount thereof. OWNER may make a claim therefor as provided in Article 11. Such claims. costs. losses and damages will include but not be limited to all costs of repair or replace— ment of work of others destroyed or damaged by correction. removal or replacement of CONTRACIOR's defecdve Work. CONTRACTOR shall not be allowed an extension of the Contract Tmra (or Mrlwtoros) because of any delay in the performance of the Work attributable to the exeraseby OWNER of OWNER's rights and remedies hereunder. ARTICLE 14—PAYMENTS TO CONTRACTOR AND COMPLETION Schedule'of Values: 14.1. The schedule of values established as provided in Paragraph' 9 will serve as the basis for progress payments and 37 will be incorporated into a form of Application for Payment acceptable to ENGINEER Progress pavments!on account of 4"n" Price Work will be based on the number of units com- pleted. Appiloidon for Progress poyme= 14 -' A' least twenty days before the date established for each Progress payment (but Oct more -often than once a month). CONTRACTOR shall submit to. ENGINEER for review an Application for Payment filled on and signed by CONTRACTOR covering the Work completed as of the due of the Application and accompanied by such supporting documentation as is required'by the Contract Documents. If Payment is requested on the basis of materials and equip. ment not incorporated in the Work but delivered and suitably stored at the site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice or -other documentation warranting that OWNER has received the materials and equipment free and clear of all. Liens and evidence' that the materials 'and' equipment are covered by appropriate property insurance and otherarrangements to protect OWNER's interest therein. all of which will be satisfactory to OWNER. The amount of retainage with respect to progress payments wll be as stipulated in the Agreement. CONTRACTOR Is WarorrryofTide. 14.1. .CONTRACTOR warrants and guarantees that tide to all Work materials and equipment covered by any Application for Payment, whether incorporated in the Project or not, will Pass m OWNER no later bran clear of all Ucns. the time of payment Cm and Review of APpB=dorer for prmgrea poymerrr: 14.'4. ENGINEER will, within ten days after receipt of each Application for Payment. either indicate in writing a recommendation of payment'and present the Application to OWNER, or return the Application to CONTRACTOR In& nuns in writing ENGINEER's reasons for refusing to recom- mend Payment In the latter caw. CONTRACTOR may make the new corrections and resubmit the Application. Ten days after 'presentation of the Application for Payment'to OWNER with ENGINEER's recommendation. the•amount recotrunended will (subject to the provisions of the last sen- tence of P-agraph 14.7) become due and when due will be paid by OWNER to CONTRACTOR, 14-5. ENGINEER's recommendation of any payment re- quested in an Application for Payment will constitute a repre. sentation by ENGINEER to OWNER, based on ENGINEER's on -site observations of the executed Work as an experienced and qualified design professional and on ENGINEER's review of the Application for Payment and the accompanying data and schedules, that to the best of ENGINEER's knowledge, infor. nation and belief:. 143.1: the Work has progressed to the point indicated, 143.2. the quality of the Work is gtnerally in accor. dance with the Contract Documents (subject to an evWu- ation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, to a final determination of quantities and clash =dote for Unit Price Work under paragraph 9.10. and to any other quali- fitatitions stated in the recommendation), and. 1433. the conditions precedent to CONTRACfOR's being entitled .to such payment appear to have been fidfiled in so far at it is ENGINEER's responsibility to observe the Work. However by recommending any such Payment ENGINEER will not thereby be deemed to have represented that n exhaustive or continuous on -site inspections have been made to check the quality or the quantity of the Work beyond the respowbilities specuiWlY assigned to ENGINEER in the Contras, Documents or u , that there may not be other matters Of issues between the parties that might entitle CO maacrs TOR to be paid additionally by OWNER or entide OWNER to withhold Payment to CONTRACTOR, :. 14.6. ENGINEER's recommendation of any payment, in eluding firm Payment, shall not mean that ENGINEER is respoadbleforCONTRACPOR's means, methods, techniques, sequences or procedures of construction, or the safety preau- dons and Programs incident thereto, or for any failure of CONTRACTOR tocomply with Taws and Regulations appli- cable to the furnishing or performance of Work, or for any failure of CONTRACTOR to perform or fitrnish Work in accordance with the Contras Documents. 14.7. ENGINEER may refuse to recommend the whole or any Part of any Payment if. in ENGINEER's opinion, it would be incorrect to snake dic'mpresentations to OWNER referred to in paragraph 143. ENGINEER may also refuse to recom- mend arty such payment. or, because of subsequendy d'tscov- Bred evidence or the results of subsequent, inspections or tests, nullify any such payment previously recommended, to such extent as may be necessary in ENGINEER's opinion to Protect OWNER from loss because: 14.7.L the Work is defective, or completed Work has been damaged requiring correction or replacement. 14.7? 'the Contract Price has been reduced by Writ- . ten Amendment or Change Order, 14.7or. Mvr worOWNER has been required to correct defec k car complete Work in accordance with paragraph 13.14. or 14.7.4. ENGINEER has actual knowledge of the oc- currence of any Of the events enumermcd in paragraphs I5=1 through 15Z4 inclusive, OWNER may refuse m make payment of the•fun amount recommended by ENGINEER because: 14.75. claims have been made against OWNER on account of CONTRAC1ORs performance or furnishing of the Work, 38 14.7.6. Liens have been filed in connection with the Work, except where CONTRACTOR has delivered a specific Bond satisfactory to OWNER to secure the satisfaction and discharge of such liens. 14.7.7. there are other iterru entitling OWNER to a setoff against the amount recommended. or 14.7.8. OWNER has actual knowledge of the occur- rence of any of the events enumerated in paragraphs 14.7.1 through 14.73 or paritilraphs 15.2.1 through 15.14 inclusive: but OWNER must give CONTRACTOR immediate written notice (with a copy to ENGINEER) stating the reasons for such action and promptly pay CONTRACTOR the amount so withheld, or any adjustment thereto agreed to by OWNER and CONTRACTOR, when CONTRACTOR cornets to OWN- ER's satisfaction the reasons for such action. Sab=mdal Camplenotr 14.8. When CONTRACTOR considers the entire' Work ready for its intended use CONTRACTOR shall notify OWNER and ENGINEER in writing that the entire Work is substantially complete (except for items specifically fisted by CONTRr\C-' TOR as incomplete) and request that ENGINEER issue a certificate of Substantial Completion. Within a reasonable time thereafter, OWNER, CONTRACTOR and ENGINEER shall. mace an inspection of the Work to determine the status of completion. If ENGINEER does not consider the Work sub- stamiaAy complete, ENGINEER will notify CONTRACTOR in writing giving the reasons therefor. if ENGINEER considers the Work substantially complete, ENGINEER will prepare and deriver to OWNER a tentative certificate of Substantial Com- pletion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before finial payment OWNER shall have seven days after receipt or the tentative certificate during which to make written objection to ENGINEER as to any provisions of the ecrtifiate or attached list If, after considering such objections, ENGINEER concludes that the Work is not substantially complete, ENGINEER will within fourteen days after submission of the tentative certificate to OWNER notify CONTRACTOR in writing, stating the Masons therefor. If, after consideration of OWNER's objections, EN- GINEER considers the Work substantially complete, ENGI- NEER will within said fauneen days execute and deliver to OWNER and CONTRACTOR a definitive certinote of Sub - sandal Completion (with a revised tentative rut of items to be completed or corrected) reflecting such changes from the tentative cerdfi=c as ENGINEER believes justified after consideration of any objections from OWNER. At the time of delivery of the tentative certificate of Substantial Completion ENGINEER will deliver to OWNER and CONTRACTOR a written recommendation as to division of responsibilities pend- ing final payment between OWNER and CONTRACTOR with respect to security, operation, safety, maintenance, heat uuli- ties, insurance and wanandes and guarantees. Unless OWNER and CONTRACTOR agree otherwise in writing and so inform ENGINEER in writing prior to ENGINEER's. issuing the definitive certificate of Substantial Completion. ENGINEER's aforesaid recommendation will be binding on OWNER and CONTRACTOR until final payment. 14.9. OWNER shall have the right to exclude CONTRAC- TOR from the Work after the date of Substantial Completion, but OWNER shall allow CONTRACTOR reasonable access to complete or correct items on the tentatve list -Parcel UnTaadMu 14.10. Use by OWNER at OWNER's option of any sub- stantially completed pan of the Work which: (i) has specifically been identifted in the Contract Documents, or (h7 OWNER, ENGINEER and CONTRACTOR agree •coratiiutes a sepa- rately functioning and usable pan of the Work that can be used by OWNER for its intended purpose without signifi=nt inter- ference with CONTRACTOR's performance of the remainder of the Work, may be.aceomplished prior to Substantial Com- pledon of all the Work subject to the following: 14.10.1. OWNER at any time may request CON- TRACTOR in writing to permit OWNER, to use any such part of the Work which OWNER believes to be ready for its intended use and substantially complete. If CON- TRACTOR agrees that such pan of the Work is substan- tially complete, CONTRACTOR will certify to OWNER and ENGTNEe'R that such part of the Work is substan- tially complete and request ENGINEER to issue a cerdf- it= of Substantial Completion for that pan of the Work CONTRACTOR at any time may notify OWNER and ENGINEER in writing that CONTRACTOR considers any such pan of the Work ready for its intended use and substantially complete and request ENGINEER to issue a certificate of Substnntral Completion for that part of the Work Within a reasonable tithe after either such request, OWNER: CONTRACTOR and ENGINEER shall make an inspection of that pan of the Work to determine its smrus.of completion. If ENGINEER does not consider, that part of the Work to be substantially complete; ENGI- NEER w$1 notify OWNER and CONTRACTOR in writ- ing giving the reosans therefor. If ENGINEER considers that pan of the Work to be substantially complete, the provisions of paragraphs 14.8 and 14.9 will apply with respect to cenifiation of Substantial. Completion of that. part of the Work and the division of responsibility in respect thereof and access thereto. 14.10.1 No occupancy or separate operation of pan of the Work will be ae.-omprrshed prior to compliance with the requirements of paragraph 5.15 in respect of property insmancr- Final InTecorr 14.11. Upon written notice from CONTRACTOR that the entire Work or an agreed portion thereor is complete. ENGI- NEER will make a final inspection with OWNER and CON- TRACTOR and will notify CONTRACTOR' in writing of all 39 Particulars in which this inspeetic veals that the Work is incomplete or defective. CONTF . OR shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. - Fins! App&emion Jar Payntemt: 14.12 After CONTRACTOR has completed an such car- rcwans to the satisfaction of ENGINEER and. delivered in atxordance with the Contract Documenu all maintenance and operating instructions, schedules, guarantees. Bonds, certifi- cates or other evidence of insurance required by Paragraph 5.4. certificates of iasp=don, marked -up record documents (as Provided in Paragraph 6.19) and other documents, CONTRAC. TOR may make application for final payment following the Procedure for Progress Payments. The final Application for Payment shall be accompanied (except as previously delivered) bY• 01 an documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by subparagraph 5.4.13, (h) consent of the surety, if any, to final payment, and m complete and legally effective releases or "rovers (Sa isfaaary to OWNER) of all Liens arising out of or filed in connection with.the Work In lieu of such releases or waivers of Liens and as approved by OWNER,*CONiRAC- TOR may furnish receipts or releases in full and an affidavit of CONTRACTOR that_ n the rcleases and receipts include all labor, services, material and equipment for which a Lica could be filed, and a an Payrolls, material and equipment bills and other indebtedness connected with the Work forwhich OWN ER . or OWNER's Property might in any way be responsible have been Paid ar,Od=wise satisfied. If -any Subcontractor or Supplier falls to furnish such a release or receipt in fun. CONTRACTOR may furnish a Bond or other collateral satis- factory to OWNER to indemnify OWNER against any Lien. Final Paymew and Acceptance. 14.13. If on the basis of ENGINEEER's obse.-vadon of the Work during construction and final inspection, and ENGI- NEER's review of the final Application for Payment and accompanying documentation as required by the Contract Documents: ENGINEER is satisfied that the Wort has been Completed and CONTRACTOR's other obligations under the Contract Documents have.been fulfilled. ENGINEER will. within ten days after recciPt of the final Application for Payment, indicate in writing ENGINEER's recommendation of payment and present the Application to OWNER for pay. runt- At the same time ENGINEER will also -give written notice .to OWNER and CONTRACTOR that the Work is acceptable subject to the provisions of paragraph 14.15. Oth- erwise, ENGINEER will return the Application to CON- TRACIOR. indicating in writing the reasons for refusing to recommend final payment, in which case CONTRACTORshall snake the n=Mary corrections and resubmit the AppGarion. Thirty days after the presentation to OWNER of the Appfica- Loa and accompanying documentation- in appropriate form and. substance and with ENGINEER's recommendation and notice of acceptability. the amount recommended by ENGI- NEER will become due and will be paid by OWNER to, 1 CONTRACTOR 14.14. If, through no fault of CONTRACTOR, final com- pletion of the Work is significantly delaved and if ENGINEER so confirms. OWNER shall, upon receipt of CONTRACTOR'S final Application for Payment and recommendation of ENGI- NEER, and without terminating the Agreement, make pay_ mew of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work not fully completed or corrected is less than the nxainage stipulated in the Agreement. and if Bonds have been ftmnished as required in Paragraph 5.1. the writtem con- sent of the surety, to the Payment of the balance due for that Portion of the Wort fully completed and accepted Shan be submitted by CONTRACTOR to ENGINEER with the Appfi- cation for such payment. Such Payment shall be made under the terms and conditions governing final Payment. except that it shall not constitute a waiver of claims. Watw Of Minty. 14.15- The making and acceptance of final payment will constitute: 14.I3.1. a waiver of all claims by OWNER against CONTRACTOR. except claims arising from unsettled Liens, from defective Work appearing after final inspection pursu. ant to Paragraph 14.11. from failure 'to comply with the Contract Documents or the temts of any special guarantees specified therein, or from CONTRACTOR'S continuing ob- ligations under the Contract Documents: and 14.15.1 a.waiverofallclaims byCONTRICIORagtunst OWNER other than those previously made in writing and Still unsettled. ARTICLE IS —SUSPENSION OF WORK AND TERMINATION OWNER Slay Suspend Wor$r IS.1. At any time and .without cause. OWNER may sus - Pend cite Work or any Portion thereof for 2:period of not more than aiaety days by notice in writing to CONTRACTOR and ENGINEER which will fix the date on which Work will be resumed. CONTRACTOR sha(1 resume the Work on the date so fixed, CONTRACTOR Shan be allowed an adjustmem in the Contract Price or an extension of the ContractTmies-'or both. directly attributable m any such suspension if CONTRACTOR makes an approved claim therefor as Provided in Articles 11 and 12 OWNER Uay T&e% =re: 15? Upon the occurrence of any one or more of the following events: 15 1.1. if CONTRACTOR persistently fails to perform 15.4? for expenses suit:fined prior to the effective date theWork in accordance with the Contract°Documents (in- of termination in'performing services and furnishing labor, chiding,but not limited to,failure to supply sufficient skilled materials or equipment as required by the Contract Door- workers or suitable materials-or equipment or failure to menu in connection with uncompleted Work, plus fair and adhere to the progress schedule established under paragraph reasonable sums for overhead and profit on such expenses; 2.9 as adjusted from time to time pursuant to paragraph 6.6): 15.4.3. for all claims,costs.losses and damages incurred 15 '2 'if CONTRACTOR disregards Laws or Regula- in settlement of terminated contracts With Subcontactors. lions of any public body having jurisdiction: Suppliers and others:and 15 2? ' if CONTRACTOR disregards the authority of 13.4.4. for reasonable expenses directly attributable to ENGINEER;ornati°" ' 15.2.4. if CONTRACTOR otherwise violates'in any sub- CONTRACTOR shall not be paid on account of loss of cranial way any provisions of the Contract Documents; anticipated profits or revenue or other economic loss arising out of or resulting from such.termination. OWNER may, after giving CONTRACTOR(and the surety. if any,) seven days' written notice and to the extent permit- ted by Laws and Regulations. terminate the services of CONTRACTOR M Slap Work arTmrunme: CONTRACTOR.exclude CONTRACTOR from the site and take possession of the Work and.of all CONTRACTOR's 15.5. .If. through no act or fault of CONTRACTOR. the tools,appliances.construction equipment and machinery at Work is suspended for a period of more than ninety days by the site and use the same to the full extent they could be used '" OWNER or under an order of court of other public author- by CONTRACTOR(without liability to CONTRACTOR for . •icy. or ENGINEER fails to act on any Application for trespass or conversion), incorporate in the Work all materi-, Payment within thirty days after it is submitted or OWNER als and equipment stored at the site or for which OWNER fails for thirty days to pay CONTRACTOR any sum finally has paid CONTRACTOR but'whichare stored elsewhere, determined to be due, then CONTRACTOR may, upon and finish the Work as OWNER may deem expedient. In seven days' written notice to OWNER and ENGINEER. such ease CONTRACTOR shall not be entitled to receive and provided OWNER or ENGINEER do not remedy such any further payment until the Work is finished.If the unpaid suspension or failure within that time, terminate the Agree- balance of the Contract Price exceeds all claims, costs, meat and recover from OWNER payment on the same terms losses and damages sustained by OWNER arising out of or as provided in paragraph 15.4. In lieu of terminating the resulting from completing the Work such excess will be paid Agreement and without prejudice to any other right or to CONTRACTOR. If such claims. costs. losses and dam- remedy, if ENGINEER has failed to.act on an Application ages exceed such unpaid balance.CONTRACTOR shall pay. for Payment within thirty days after it is submitted, or the difference to OWNER Such claims. costs, losses and OWNER has failed for thirty days to pay CONTRACTOR damages incurred by OWNER will be reviewed by ENGI- any sum finally determined to be due, CONTRACTOR may NEER into their reasonableness.and when so approved by upon seven day's written notice to OWNER and ENGI- ENGINEER incorporated in a Change Order, provided that NEER stop the Work until payment of all such amounts due when exercising any rights or remedies under this paragraph CONTRACTOR. including interest thereon.The provisions • OWNER shall not be required to obtain the lowest price for of this paragraph 15.5 are not intended to preclude CON- • the Work performed. TRACTOR from making claim under Articles II and 12 for an increase in Contract Price or Contract Times or otherwise 15.3. Where CONTRACTOR's services have boa so ter- for expenses or damage directly.attributabie to CONTRAC- urinated by OWNER the termination will not affect any tights TOR's stopping Work as permitted by this,paragraph. or remedies of OWNER against CONTRACTOR then existing . or which may thereafter aeaue. Any retention or payment of . ' moneys due CONTRACTOR by OWNER will not release CONTRACTOR from liability. ARTICLE,16—DISPUTE RESOLUTION 15.4. Upon seven days'written notice to CONTRACTOR and ENGINEER, OWNER may. without case and without If and to the extent that OWNER and CONTRACTOR have prejudice to any other right or remedy of OWNER. elect to agreed on the method and procedure for resolving disputes terminate the Agreement. In such case.CONTRACTOR shall between them that may arise under. this Agreement. such be paid (without duplication of any items): dispute resolution method and procedure.if any.shall be as set forth in Exhibit GC-A.'-Dispute Resolution Agreement."to be 15.4.1 for completed and acceptable Work executed in attached hereto and made a part hereof. If no such ag tment accordance with the Contract Documents prior to the effee an the method and procedure for resolving such disputes has five daze of termination,including fair and reasonable sums been reached.and subject to the provisions of paragraphs 9.10, for overhead and profit on such Work: 9.11. and 9.12. OWNER and CONTRACTOR may exercise 41 such rights or remedies as either may otherwise have under the act of the other party or of any of the other party's employes Contact Doctimenu or by Laws or Regulations in respect of or agents or others for whose acts the other Party is legagy }ray dispute. liable,claim will be made in writing to the other party witlda a rmsonable time of,the rust observance of such injury or ARTICLE 17—USCE NEOUS damage. The Provisions of this paragraph 17.3 shag not be construed as a substitute for or a waiver of the provisines of any applicable statute of Cunitations or repose. Giving?V*dM 17.1. Cumrdwe Rmrefim - Whenever any provision of the Contract Documents been the giving of wtiaen notice,it will be deemed to have 17.4. The duties and obligations imposed by these a member yo given the if delivered in person to the.irtdividual or to Conditions and the rights and remedies available hanmda to&m or to an ofca of the corporation for parties hereto,and,in particular but without itat on.the whom it is intended, or if delivered at or seat by registered or TRAC ties, guarantees and obligations imposed certified �. prepaid, to the last business address a upon CON- known to the v 13.12. 133.14.1433 and t3?and all of the rights and remedies giver of the motive available to OWNER and, ENGINEER thereunder: an in Cmrpmmcon oj2'mner addition to, and are not to be construed in any way as a • 17.11. When an - Nemlinm wcohi of,any.rights and remedies available to any or all of Contr�et Y Period oC time is referred to in the which are otherwise imposed or available by Laws or When nts by days, it will be computed to exclude Regulations, by special warranty or guaranty or by other the first and include the last day of such period. If the last day provisions of the Contract of any such Period falls on a thisDocumenu, and the provisions of such day holiday by the� of the or Sunday mr on a day the oCon�h be ue in(C connection ve as it pry applicable jurisdiction computation duty, gation„right and remedy to which they apply. • 17.1'— A calendar day of g �foui. hours dam u� pm j +gal Fen mrd Court Cora Inelrrded from midnight to the next midrri /yam ofC sin 173. Whenever reference is made to'•elainss,cost.lenses and damages it shap include in each tau,but not be Lmited 173. Should OWNER or COer to.all fees.and charges of engineers.architects, NTRACIy a or,or injury or other Dmfclssionals and all court or arbi ether dispute s and damage to person or property because of any error omission or resolution costs.: truion or ocher (The remainder of this page was left blank intentionally.] - 42 . SUPPLEMENTARY CONDITIONS OF THE AGREEMENT CLP Project No. 20004501 SC-1 PRECEDENCE: These supplementary conditions of the Agreement are a supplement and where in conflict; they take precedence over the General Conditions of the Agreement of this Specification. SC-2 OWNER/ENGINEER: The word "OWNER" in these Specifications shall be understood as referring to the City of La Porte, Texas. The word "ENGINEER" in these Specifications shall be understood as referring to the City Engineer for the City of La Porte, Texas. SC-3 SCOPE OF WORK: The work to be performed under this contract consists of furnishing all materials, labor, supervision, tools, and equipment necessary to complete the work. SC-4 SEQUENCE OF WORK: All work covered by this Contract shall be completed within the number of calendar days designated by the Contractor in the Bid Proposal. SC-5 TIME OF COMPLETION: The CONTRACTOR shall complete the work as provided in the Contract Documents and within the time limitations described in paragraph SC-4, Sequence of Work, unless otherwise stipulated to proceed. Calendar days shall be computed beginning and inclusive of the first day of the Notice to Proceed. CONTRACTORS shall notify OWNER in writing 48 hours prior to start of construction. The time of completion shall include delivery time of all equipment and materials required to complete the work in conformance with the Drawings and Specifications. SC-6 LIQUIDATED DAMAGES FOR DELAY: It is understood and agreed between the parties hereto that time is of the essence of this Contract, and that for each calendar• day of delay beyond.the completion date (after due allowance for such extension of time as provided herein) the•CONTRACTOR shall pay the OWNER as liquidated damages the sum of one hundred dollars ($100.00), it being understood between the parties hereto that such sum shall be treated not as a penalty, but as liquidated damages for loss of revenue to the OWNER. • SC-7 GUARANTEE: The CONTRACTOR shall furnish the OWNER with a written guarantee on all workmanship and materials provided by him for the project. The written guarantee shall be made out to the OWNER and in a form satisfactory to the OWNER, guaranteeing all of the work under the Contract to be free from faulty materials in every particular, and free from faulty workmanship, and against injury from proper and usual wear, and agreeing to replace or to re-execute without cost to the OWNER such work as may be found to be imperfect'or improper, and to make good all damage caused to other required replacement or re-execution. The guarantee shall be made to cover a period of one. year from the date of completion of all work under this Contract. This • guarantee must be furnished to the OWNER for approval, prior to acceptance and final payment. Neither the final certificate nor payment nor any provision- in the Contract Documents shall relieve the CONTRACTOR of the responsibility for neglect or faulty materials or workmanship during the period covered by the guarantee. Supplementary Conditions Page 1 of 10 SUPPLEMENTARY CONDITIONS OF THE AGREEMENT SC-8 MATERIALS AND WORKMANSHIP: No material which has been used by the CONTRACTOR for any temporary purpose whatever is to be incorporated in the permanent structure without written consent by the OWNER. SC-9 SANITARY FACILITIES: The CONTRACTOR shall maintain sanitary facilities at a location satisfactory to the OWNER, for use by the employees of the CONTRACTORS. They shall be well ventilated, but provide proper concealment, and shall be kept scrupulously clean at all times by the CONTRACTOR. The facilities shall be removed and the site restored to its original condition upon the completion of the work All such facilities shall conform to the requirements of the state and local health authorities, ordinance and law. SC-10 INCONVENIENCES TO THE PUBLIC: :It is declared and acknowledged intent of these specifications that all work such as backfilling of excavations, removing forms, repairs to roads and drives, and clean-up or other such operations shall follow as closely as practical to the laying or installing operations, in such a manner that the public is not unnecessarily inconvenienced nor a hazard to public safety created. Any specific limitation in the technical specifications referring to the control of the "follow-up" operations, such as the minimum distance of unfilled trench allowed behind the • excavating operations, shall be ,strictly enforced. The OWNER or OWNER'S representative will notify the CONTRACTOR if his forces and/or equipment are insufficient to such a degree that the public is unnecessarily inconvenienced and/or a hazard to the public safety is created. The CONTRACTOR, upon notification by the OWNER or OWNER'S representative shall make necessary changes to his forces and/or equipment. SC-11 PERMITS: Permits and licenses of a temporary nature necessary for the • prosecution of the work shall be secured and paid for by the CONTRACTOR. Easement, right-of-way and instruments of a permanent nature shall be secured and • paid for by the OWNER. CONTRACTOR shall obtain all required permits from the City of La Porte and any other affected agency. - SC-12 CLEAN-UP: The CONTRACTOR shall at all times keep the site and structures or facilities thereon free from accumulations of waste material, debris or rubbish caused by his employees or work; at the completion of the work he shall remove from the site all his tools, surplus materials, debris, and shall leave the site and his work "broom • clean" or the equivalent, unless otherwise noted on the drawings or specified by the OWNER. - SC-13 OPERATIONS AND BUSINESS OF THE OWNER: It is of great importance that the OWNER'S operations meet with a minimum of interference resulting from the work requiring by these Contract Documents. The CONTRACTOR shall, therefore, conduct • his work in such a manner as to permit these continued operations and so as not to • interfere with the business of the OWNER. The CONTRACTOR shall use the route of entry designated by the ENGINEER at the pre-construction meeting and restrict all his vehicle and personnel to this route and to the site. The blocking or hindering of traffic will not be permitted. Suoolementary Con icons PBQe 2 Qf 10 SUPPLEMENTARY CONDITIONS OF THE AGREEMENT SC-14 SEPARATE CONTRACTS: The OWNER reserves the right to let other contracts in connection with this work. The CONTRACTOR shall afford other contractors reasonable opportunity for the introduction and storage of their materials and the execution of their work and where required, shall properly connect and coordinate his work with theirs. SC-15 RIGHTS OF VARIOUS INTERESTS: Wherever work being done by the OWNER'S forces or by other contractors contiguous to work covered by this contractor, the respective rights or the various interests involved shall be established by the OWNER or his resident inspector, to secure the completion of the various portions of • the work in general harmony. CONTRACTOR shall issue work schedules in conflicting areas as requested by the.OWNER or his resident inspector. SC-16 STORAGE OF MATERIALS AND EQUIPMENT: Any material which has deteriorated, become damaged or otherwise unfit for'use, shall not be used in the work Any material or equipment must be stored at a location directed by the ENGINEER at • the pre-construction meeting. Upon completion of all work, or when directed by the OWNER, the CONTRACTOR shall remove such storage facilities or equipment form the site. SC-17 PUBLIC UTILITY OBSTRUCTIONS: Pipe lines and other existing underground structures in the vicinity of the work are shown on the drawings according to the best. information available to the OWNER. The OWNER does not guarantee the accuracy of this information. The CONTRACTOR shall make every effort to locate all underground utilities by prospecting in advance of trench excavation. The cost of repair of existing utilities damaged by the CONTRACTOR shall be borne by the CONTRACTOR, and shall be scheduled so as to cause the least possible inconvenience to the public. Any delay or extra cost to the CONTRACTOR caused by pipe lines or other underground structures or obstructions not shown on the plans -or found in different locations than those indicated, shall not constitute a claim for extra work, additional payments, or damages. . . . SC-18 SUBLETTING THE WORK:, The CONTRACTOR shall perform with his own organization and with the assistance of workmen under his immediate supervision, work not less than fifty percent (50%) of the value of all work embraced in the Contract exclusive of items not commonly found in contracts for similar work or which requires highly specialized knowledge, craftsmanship and/or equipment not ordinarily available •in the organizations of the contractors performing work of the character embraced in the Contract. No portion of the work covered by these specifications and materials, shall be sublet without written permission from the OWNER. If the CONTRACTOR sublets any part of the work to be done under this Contract, he will not under any circumstances be • relieved of his responsibility and obligations. All transactions of the OWNER will be with the CONTRACTOR. Subcontractors will be considered . only in the capacity of employees and/or workers and shall be subject to the same requirements as to character, competency, wages and hours. The OWNER will not recognize any subcontractor on the work. The CONTRACTOR shall at all times, when the work is in Supplementary Conditions Pale 3 of 10 SUPPLEMENTARY CONDITIONS OF THE AGREEMENT operation, be represented either in person or by a qualified superintendent or other _designated representative. A complete list of subcontractors must be submitted within ten (10) days after start-up. SC-19 PROTECTION OF EXISTING FACILITIES: The CONTRACTOR shall use construction equipment, labor, or techniques to insure that existing facilities such as but not limited to, existing utilities are not damaged. A careful pre-construction inspection of existing facilities will.be made wit 'the OWNER and the CONTRACTOR. SC-20 PROTECTION OF TREES AND SHRUBS: Any trees, shrubs, plants, or ornamental growth within the right-of-way, not directly interfering with the construction of the road bed, sidewalks, driveways or sewer shall be protected from damage by the CONTRACTOR. Any tree, shrub, plant or ornamental growth that interferes with the construction of the roadway, sewers, sidewalks or driveways shall be relocated to.a • location satisfactory.to the adjoining property owner outside of the street right-of-way. Large trees not conducive to moving shall be removed and disposed. SC-21 PROJECT SCHEDULING: CONTRACTOR shall coordinate all work'with OWNER. - SC-22 WATER FOR CONSTRUCTION AND TESTING: CONTRACTOR may obtain water for construction and testing from the City of La Porte at his cost. A construction meter will be provided at no cost to the CONTRACTOR for the duration of construction. SC-23 OPERATION OF EXISTING FACILITIES: The City of La Porte shall operate all •existing facilities (i.e., lift stations, valves, fire hydrants) during construction. SC-24 DELETION OF ARTICLES IN GENERAL CONDITIONS: Articles of the General Conditions covering OWNER'S liability insurance, Sections 5.5 through 5.10, are hereby deleted are not part of this Contract and is not required by the OWNER. SC-25 REQUIRED CONTRACTOR INSURANCE: CONTRACTOR shall obtain insurance as detailed. Each.policy obtained by, the CONTRACTOR for work with this • contract, with exception of the Worker's Compensation policy, shall name the OWNER and the ENGINEER as an additional insured. The coverage and amounts designated are minimum requirements and do not, establish limits of the contractor's liability. Additional coverage may be provided' at the CONTRACTOR'S option and expense. Insurance must include: General Liability: Commercial General Liability General Aggregate . $1,000,000.00 Personal Injury $1,000,000.00 Each Occurrence $1,000,000.00 Automobile Liability: Combined Single Limit $1,000,000.00 Supplementary't gnd&ns Page 4 of 10 SUPPLEMENTARY CONDITIONS OF THE AGREEMENT Excess Liability: Umbrella Each Occurrence $1,000,000.00 Each Aggregate $1,000,000.00 Worker's Compensation: A. Definitions: Certificate of coverage ("certificate"). A copy of a certificate of insurance, a certificate of authority to self-insure issued by the commission, or a coverage agreement (7WCC-81, TWCC-82, TWCC-83 or TWCC-84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractors work on the project has been completed and accepted by the OWNER. Persons providing services on the project - includes all persons or entities • performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, • owner-operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. . "Services" include, without limitation, providing, • hauling, or delivering equipment or materials, or providing labor, transportation, or other services related to the project. "Services" does not include activities unrelated to the project, such as food/beverage vendors, office supply deliveries, and delivery of portable toilets. B. The CONTRACTOR shall provide coverage,_ based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees.of the contractor providing services on the project, for the duration of the project. C. The CONTRACTOR must provide a certificate of coverage to the OWNER prior to being awarded the contract D. If the coverage period shown on the contractors current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate'of coverage with the OWNER showing that coverage has been extended. E. The CONTRACTOR shall obtain from each person providing services on the project, and provide the OWNER: (1) a certificate of coverage, prior to that person beginning work on the project, so the OWNER will have on file certificates of coverage showing coverage for all persons providing services on the project; and Supplerr�entsry G ndwonsP se 5 of tQ SUPPLEMENTARY CONDITIONS OF THE AGREEMENT (2) no later than seven (7) days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The CONTRACTOR shall retain all required certificates of coverage for the. duration of the Project and for one (1) year thereafter. G. The CONTRACTOR shall notify the OWNER in writing by certified mail or personal delivery, within ten (10) days after the contractor knew or should have known, of any change that materially affects the provisions of coverage of any persons providing services on the project. H. The CONTRACTOR shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the Project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The CONTRACTOR shall contractually require each person with whom it contracts to provide services on the Project, to: (1) provide coverage, based on proper reporting of classification codes and payroll amount and filing of any coverage agreements, which meets the statutory • requirements of Texas Labor Code, Section 401.011(44) for all of its employees • providing services on the Project, for the duration of the Project; (2) provide to the CONTRACTOR, prior to that person beginning work on the Project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the Project, for the duration of the Project; (3) provide the CONTRACTOR, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate ends during the duration of the Project; (4) obtain from each other person.with whom it contracts, and provide the CONTRACTOR: (a) a certificate of coverage, prior to the other person beginning work on the project; and (b) a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate ends during the duration of the Project. (5) retain all required certificates of coverage on file for the duration of the Project and for one (1) year thereafter; (6) notify the OWNER in writing by certified mail or personal delivery, within ten (10) days after the person knew or should have known, of any change that auoolememwy Go d' io s Eaas!1a SUPPLEMENTARY CONDITIONS OF THE AGREEMENT materially affects the provisions of coverage of any person providing services on the Project; and (7) contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing service. J. By signing this contract, the CONTRACTOR is representing to the OWNER that all employees of the CONTRACTOR who will provide services on the Project will be covered by workers' compensation coverage for the duration of the Project, that the coverage will be based on proper reporting of classification codes arid payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self-insured, with the Commission's Division of Self-Insurance Regulations. Providing false or misleading information may subject the CONTRACTOR to.administrative penalties, criminal penalties, or other civil action. K The CONTRACTOR'S failure to comply with any of these provisions is a breach of contract by the CONTRACTOR which entitles the OWNER to declare the Contract void if the CONTRACTOR does not remedy the breach within ten (10) days after receipt of notice of breach from the City. The CONTRACTOR shall be responsible for• insurance to cover equipment, tools, materials, supplies, etc. used in the performance of work, owned or rented, the capital value of which is not included in the cost of this Contract. • Insurance policies are to be written by companies authorized to do business under the laws of the State of Texas and on forms approved by the Insurance Commission of the State of Texas. The CONTRACTOR shall provide the,OWNER a copy of all insurance • policies. • All of the insurance required to.be carried by the CONTRACTOR shall be by policies which shall require on their face, or by endorsement, ten (10) days written notice to the OWNER before they may , be cancelled and within which ten day period the CONTRACTOR covenants that it will provide other suitable policies in lieu of those • about to be cancelled so as to maintain in effect the coverage required under the provisions hereof. Failure or refusal of the CONTRACTOR to obtain and keep in force the above required insurance coverage shall authorize the OWNER, at its option, to terminate this contract at once. The CONTRACTOR shall indemnify and save harmless the OWNER, its officers, employees, and agents from all claims and liability due,to•the activities of itself, its agents, or employees performed under this contract and which result from an error, omission, or negligent act of the CONTRACTOR or of any person employed by the CONTRACTOR. The CONTRACTOR shall indemnify and save harmless the OWNER from any and all expenses, including attorney fees, which might be incurred by the OWNER in, litigation or otherwise resisting said claims or liabilities which might be imposed on the OWNER as a result of such activities by the CONTRACTOR, his agents, or employees. • milemen ary Qgjjoac p j at iQ SUPPLEMENTARY CONDITIONS OF THE AGREEMENT SC-26 QUALIFICATIONS FOR SURETIES' ISSUING BONDS: As required by City of La Porte Ordinance No. 1773, approved July 22, 1991, corporate sureties issuing payment and performance bonds payable to the City of La Porte on public works projects shall meet all of the following criteria: a. The surety company must'be authorized to do business in the State of Texas, which authorization must be recorded in the files of the Texas State Board of Insurance; b. The surety company must be an approved surety company listed in the current United States Department of Treasury list of approved corporate sureties for payment and performance bonds for federal jobs, including specifically the rules to underwriting limitation; c. The surety company must be authorized to issue payment and performance bonds in the amount required for the Contract, which authorization must be recorded in the files of the Texas State Board of Insurance; d. . The person-executing the Payment and Performance Bonds must be a licensed Texas local recording agent and such licensing must be recorded in the files .of the Texas State Board of Insurance; and e. The person executing the Payment and Performance Bonds must be authorized by the surety company to execute performance and payment bonds on behalf of the company in the amount required for the Contract and such authorization must be • recorded in the files of the State Board of Insurance. f. Failure'to meet the criteria for acceptability of surety company issuing Payment and Performance Bonds will result in the disqualification of the bid. g. The Payment and Performance Bonds shall remain in effect at least one year beyond final acceptance of work under the Contract by the Owner. SC-27 RETAINAGE: If the total Contract price is greater than $400,000.00, five percent (5%) of the total contract price will be retained until final payment as described below. If the total Contract price is less than $400,000.00, ten percent (10%) of the total contract price will be retained until final payment as described below. On or before the tenth (10th) day of the month, the CONTRACTOR shall prepare and submit to the ENGINEER for approval or modification a statement showing as completely as practicable the total value of the work'done by the CONTRACTOR up to and including the last day of the preceding month; said statement shall also include the value of all sound materials delivered on the site of the work that'are to be fabricated into the work. For total Contract prices (Base Bid) greater than $400,000.00, the OWNER shall then pay the CONTRACTOR.on or before the fifteenth (15th) day of the following month of the following month the amount of the approved statement, less five percent (5%) of the amount thereof, which shall be retained until final payment, and further less all previous • payments and all further sums that be retained by the OWNER under the terms of the Agreement. $upplementary Co11ditlons Pang 8 of 14 SUPPLEMENTARY CONDITIONS OF THE AGREEMENT For total Contract prices (Base Bid) less than $400,000.00, the OWNER shall then pay the CONTRACTOR on or before the fifteenth (15th) day of the following month of the following month the amount of the approved statement, less ten percent (10%) of the amount thereof, which shall be retained until final payment, and further less all previous payments and all further sums that be retained by the OWNER under the terms of the Agreement. It is understood, however, that in case the whole work be near to completion and some unexpected and unusual delay occurs due to no fault of the CONTRACTOR, the OWNER may, upon written recommendation of the ENGINEER, pay a reasonable and equitable . portion of the retained percentage •to the CONTRACTOR, or the CONTRACTOR at the OWNER'S option, may be relieved of the obligation to fully complete the work and, thereupon, the CONTRACTOR shall receive payment of the balance due him under the Contract subject to those conditions under the General Conditions, Article 14, Payments to CONTRACTOR and completion. SC-28 PREVAILING WAGES: The CONTRACTOR and his subcontractors shall expressly comply with Article 5159A, Revised Civil Statutes of Texas, 1925, commonly known as, "The Prevailing Wage Act" including the latest provisions. Not less than the minimum prevailing wage for the Harris County area as attached at the end of these supplementary conditions shall be paid for labor which is employed • by the CONTRACTOR and his subcontractors for execution. of this contract. The CONTRACTOR and his subcontractors shall keep accurate records of the names, wage classifications, and hourly wages paid to each worker employed on this project. These records shall be open to inspection by the OWNER. SC-29 CONTRACT INTERPRETATION AND WORK ACCEPTABILITY: The Engineer will be the final interpreter of the requirements of the contract documents and sole judge of the acceptability of work thereunder. SC-30 DISPUTE RESOLUTION The parties will attempt in good faith to resolve any controversy or claim (other than matters described in the immediately preceding paragraph) arising out of or relating to this agreement promptly by negotiation between senior executives of the parties who have authority to settle the controversy. . The disputing party shall give the other party written notice of the dispute. Within ten days after receipt of said notice, the receiving party shall submit to the other a written response. The notice.and response shall include (a) a statement of each party's position and a summary of the evidence and arguments supporting its position, and (b) the name and title of the executive who will represent that party. The executive shall meet at a mutually acceptable time and place within twenty days of the date of the disputing party's notice and thereafter as often as they reasonably deem necessary to exchange. relevant information and to attempt to resolve the dispute. If the controversy or claim has not been resolved within thirty days of the meeting of the senior executives, the parties shall endeavor to settle the dispute by mediation under the Construction Industry Mediation Rules of the American Arbitration Association. 8uoelemeniwv Onnditione Pao 9 of 19 SUPPLEMENTARY CONDITIONS OF THE AGREEMENT • If the matter has not been resolved pursuant to the aforesaid mediation procedure • within ninety days of the commencement of such procedure, (which period may be extended by mutual agreement), or if either party will not participate in such procedure, the controversy shall be settled by arbitration,in accordance with "American Arbitration • Association Construction Industry Arbitration Rules" by a sole arbitrator. The arbitration shall be governed by the United States Arbitration Act, 9 U.S.C &'1-16, and judgement upon the award rendered by the Arbitrator may be entered by any court having 'jurisdiction thereof. The,place of arbitration shall be Harris County: The arbitrator is not empowered to award damages in excess of actual damages, including punitive damages. Supplementary Conditions Pane 100110 --- .a.s..a '.nr,txu. atxvicEs ®001 PREVAILING WAGE RATE DETERfllNATION • BUILDING CONSTRUCTION TRADES COUNTY NAME : HARRIS Data Printed: AprIl 16, 1997 ' CLASSIFICATION Rate Health Pension Vacation - Total Wage ASBESTOS WORKER $9.00 $0.00 $0.00 $0.00 S9.00 CARPENTER $16.23 $215 $1.17 $0:00 $19.56 CARPETLAYER/FLOORING INSTALLER . $8.00 - $0.00 $0.00 $0.00 - 58.00 CONCRETE FINISHER S10.00 ' $0.05 $0.25 $0.04 $10.34 DATA COMMUNICATION/TELECOM INSTALLER $11.99 $0.18 $0.00 $0.06 $1223 • DRYWALL INSTALLER/CElLING INSTALLER $11.00 $0.00 $0.00 $0.00 $11.00 ELECTRICIAN $13.27 ., -$0.79 $0.27 $0.41 $14.75 ELEVATOR MECHANIC $18.02 $3.85 $219 $1.50 $25.56 FIRE PROOFING INSTALLER $11.00 $0.00 $0.00 $0.00 S11.00 GLAZER $1253 $0.79 $0.00 $0.7 $14 HEAVY EQUIPMENT OPERATOR $13.48 $0.14 $0.16 $0, $13.79 INSULATOR •$15.78 $3.06 $1.64 $1.00 $21.48 IRON WORKER $13.37 $0.00 $0.00 $0.00 $1337 LABORER/HELPER $8.12 $0.32 -$0.07 $0.06 5858 • LATHER/PLASTERER 2 $15.10 $212 $1.00 $0.00 $18.22 LIGHT EQUIPMENT OPERATOR' L $11.46 . $0,30 $0.35 $0.02 $12.13 MASON $14.55 $0.48 . $0.24 $0.00 $1527 METAL BUILDING ASSEMBLER $10.00 $0.00 . $0:00 $0.00 $10.00 MILLWRIGHT $15.91 $1.63 $1.00 $0.00 $1854 PAINTER/WALL COVERING INSTALLER $11.63 $0.87 $0,43 $0,16 $13.10 PIPEFRTER $18.38 $3.25 $2.06 $0.00 ' $23.69 PLUMBER $1933 $240 $1.45 $0.54 $23.72 ROOFER $10.00 $o.00 $o.00 $o.00 $10.00 SHEET METAL WORKER $14.56 . $1.19 $0.62 $0.1 •$1647 SPRINKLER FRIER $18.25 $3.40 $2.24 $0.00 $23, TERRAZZO WORKER $0,00 $0.00 $0.00 $0.00 S0.00 TILE SETTER $10.00 $0.00 $0.00 $0.00 $10.00 WATEAPROOFER/CAULXER $1152 $0.00 $0.00 - $0,00 $11 .52 50.00 In the rate field Indicates Insufficient,data was race Wed to determine a prevailing wage rate for • this classification. Government Code Title 10, Section 2258,023, paragraph C states'A contractor ' or subcontractor does not violate this section If a public body awarding-a contract does not determine • the prevailing wage rates and specify the rates In the contract as provided in Section 2258.022' Ba d ona�Survey R Results .. . .. - General Services Commission 1711 San Jacinto-P.O.Box 13047 Austin,Texas 78711.3047 Web Site: www.;sesrate,tx.us (512)463-3035 • .Pertinent Information to All Public Entities Using Prevailing Wage Rate Determinations • Produced by the General.Services Commission , 1. The contracting entity awarding any contract for non-federally funded, public works construction projects . • (regardless of size or dollar value) shall include in bid specification documents and contract documents a prevailing wage rate determination of per diem wages for the locality in which the work is to be performed, •for each craft or type of workman or mechanic needed to exedute the contract The.Prevailing Wage Rate Determination is defined as (1) the Prevailing Wage Rate Determination Information sheet(document number WR1001.), (2).the Prevailing Wage Rate Determination for Building-Construction Trades, and(3) the Department of Labor(DOL) Heavy Highway Determination. The DOL Heavy Highway rates are to be paid to workers engaged in site work determined to be five (5) feet beyond the building, extending to the • property boundary. ' 2 It shall be the responsibility of the contracting entity to ensure that the.General Contractor posts the applicable Prevailing Wage Rate Determination In a prominent.easily accessible place at the work site. 3. It shall be the responsibility of the contracting entity to ensure that not.less than the posted,specified rates are paid to all classifications of workmen, mechanics.and laborers employed by the General Contractor and/or Subcontractors•, in-the execution of their contract with the contracting entity, and to ensure that an workers-fit Into one of the listed worker classifications for work of a similar character. For example; welders are to be paid the rate of pay for the trade they are working for. ' 4. It shall be the responsibility of the contracting entity to take cognizance of wage rate disputes and/or complaints of all violations of the provisions of Chapter 2258 Texas Government Code.Title 10. 5. It shall be the responsibility of the contracting entity to address the issue of fringe benefits in the-bid specification documents and contract documents. The Prevailing Wage Rate Determinations produced by the General Services Commission include fringe benefits in the total wages: The bid specification documents and contract documents need to specify whether the contracting entity is requiring that fringe benefits be.pald. ' 6. It than be the,responsibility of the contracting entity to address the Issue of the use of-apprentices and their payment rate in the bid specification documents and contract documents. The rates specified in the - Prevailing Wage Rate Determination produced by the General Services Commission are journeyman rates. Historically, the apprentice rate Is commensurate with the-experience and sidil o!the workur. For example, on GSC projects, apprentices are paid at a rate of not,more than 60%of the journeyman's wage. Also on GSC projects, at no time shall a journeyman.supervise more than one (1)apprentice. Note: The terns journeyman and apprentice apply to both union and Independent,workers, and are not Intended to imply that these positions are union workers only. 7. Some Prevailing Wage Rate Determinations for Building Construction Trades may Indicate$0.00 in the Total Wage' column, rather than a dollar amount .In such cases, The General Services commission did not receive sufficient survey data to tabulate a prevailing wage for this worker classification. In'the specified area, and can not provide a prevailing wage rate for this classification• Where this occurs, General Contractors and Subcontractors shall not be bound to a prevailing wage rate for the dasditcation In question. . vm,ac u ,in, General Services commission �•�� 1711 San Jacinto-P.O. Box 1 X041 'AuzQn,Texu 78711.3047 Web Site: www.uresraro.tx,us (312)163-3035 Prevailing Wage Rate Determination'Information " • The following information from Chapter 2256 Texas Government Code Title 10 should be included in your bid specification documents and contract documents: 2258.021. Duty of Governmental Entity to Pay Prevailing Wage Rates •• (a) The state or any political subdivision of the state shall pay a worker employed by It or on behalf of it (1) not less than the general prevailing rate of per diem.wages for work of a similar character In the • locality in which the work is performed;and. (2) not less than the general prevailing rate of per diem wages for legal holiday and overtime work. (b) Subsection (a) does not apply to maintenance work, (c) A worker Is employed on a public work for the purposes of this section If the worker Is employed by a contractor or subcontractor in the execution of a contract for the public work with the state, a political subdivision of the state, or any officer or public body of the state or a political subdivision of the state. 2258.023. Prevailing Wage Rates to be Paid by Contractor and Subcontractor, Penalty • (a) The contractor who is awarded a contract by a public body or a subcontractor of the contractor shag pay not less than the"rates determined underSection 2258.022 to a worker employed by it in the execution of the contract. (b). A contractor or subcontractor who violates this section shall pay to the state ora political subdivision of the state on whose behalf the contract is made, $60 for each worker employed for each calendar day- • or part of the day that the worker is paid less than the wage rates stipulated in the contract. A public bocy awarding a contract shall specify.this penalty In the contract- Note:'This penalty applies even if the contractor or subcontractor and the worker come to an agreement on the underpaid wages (see Aftomey General Opinion DM-469), (c) A contractor or subcontractor does not violate this section If a public body awarding a contract does not determine the prevailing wage rates and specify the rates in the contract as provided by Section • 2258.022.• (d) The public body shag use any money collected under this section-to offset the costs incurred in the administration of this chapter. (e) A municipality is entitled to collect a penalty under this section only if the municipality has a population• , of more than 10,000. 2258.051. Duty of Ptibllo Body to Hear Complaints and Withhold Payment (a) A public body awarding a contract, and an agent or officer of the public body, shall: • (1) take cognizance of complaints of"ail violations of this chapter committed In the execution of the contract; and (2) withhold money forfeited or required to be withheld under this chapter from the payments to the contractor under the contract, except"that the public body may not withhold money from other than the-final payment without determination by the public body that there is good cause to • believe that the contractor has violated this chi'apter. Worker Classification Definition Sheet estos Wacker Woricer who removes and disposes of asbestos materials.Carpenter Worker who bu�7 is wood structures,or stnrctures of any materiai replaer,d wood. Includes rough and fudsh carpentry,hardware an t l ayor/FToorin9 Installer Worker who installs carpet and/or friar coverings vinyl Wi . to Finisher Worker who floats, trowels, and finishes concrete. Data Communkatbn/refecom Insialfer Worker who installs data/tale ne ant and accessories. ° and tit!ovision cable and equipment 4ssociated Drywall In.-WenlCelling Installer Worker who Installs metal framed waifs and ceilings, • Electrician grids and ceilings. drywafi coverings.°QMV Skilled craftsman who installs or repairs electrical wiring and devices. Includes fire alarm systems, and HVAC electrical controls. Elevator Mechanic Craftsman skived in the InstallationInstaller and maintenance of elevators. Glazier Worker who sprays or applies fire proormg materials. Worker who Installs glass, glazing and glass(turning. eavy Equipment Operator lnclud�but not limited to an cat tractors,all dertrdk cranes,back P machines. Cw hoe• back filler,power operated shovel wl truck,all trenching• nsulator ' Worker who applies;sprays, or installs Insulation. Iron Worker Skilled craftsman who erects structural steel framing and installs structural - rerMefper • Worker qualified for only unskilled. i , dea orsertd-skNedwork IJfttng,carrying materials and loots, hauling,digging, dean-up. r/Plasteref Worker who Installs metal framing and lath. Worker who • and ins(-ins associated accessories. applies plaster to Lathing light Equipment Operator. Includes but not limited to air compressors,truck crane driver,flex plane,buliding • elevator, form grader, concrete mixer(less than 14 ct),conveyor. Mason Craftsman who works with miasonry products, stone,brick, block or any material substituting for those materials and accessories. Metal Building Assembler Worker who assembles pre rtade metal buGdtngs. hlrllwright Meek specializing in the installation of hew .y dock levelers, hydraulic lifts and vY oonveyerioe,' align pumps' PalrmteoWaG Covering Installer yy orker who prepares wall surfaces and applies paint and/or wag coverings, tape and bedding. Pipofrtt r Tralnedworker who Installs piping systems,chilled water PiPkg and hot water (boiler)Piping.pneumatic tubing controls,chillers,boilers,and associated rrrecimankal equipnment. Plumber Skilled craftsman who installs domestic hot and cold water piping,waste Piping, storm system piping,water closets,sinks,urinals and related work Roofer Worker who installs roofing materials.Bitumen(asphalt and cold tar),felts, flesh' ,all types roofing membranes and associated products. heel Metal Worker Worker who installs sheet metal products. Roof metal, flashings,end curbs, ductwork,mechanical equipment,and associated metals. Anklet F Worker who Installs fuo s rinkler attune Worker p systems and(lie protection equipment. Craftsman who places and finishes Terazzo. de Senor Worker who prepares wall andlor,floor surfaces and applies ceramic isles to the" surfaces. aterproofer/Caulker` Worker who applies water proofing material to buildings. Products Include sealant,caulk,sheet membrane, fiquld membranes.sprayed, rolled,or brushed on. TECHNICAL SPECIFICATIONS CLP Project No.2000-4501 ITEM I REMOVING EXISTING CONCRETE SIDEWALK AND CURB 1. DESCRIPTION 1.1 This section governs the furnishing of all equipment, superintendence, labor and materials, and performing of all operations.in breaking up.and removing existing concrete pavement, curb, sidewalks, and disposing of the old concrete or other materials satisfactorily in a manner and place to be determined by Contractor and approved by Owner. . 2. CONSTRUCTION METHODS 2.1 Where only a portion of the existing concrete pavement, curb, or sidewalk is to be removed, special care shall be exercised to avoid damage to that portion of the concrete to remain in place. Where concrete pavement is removed at locations between joints, the existing concrete pavement and curbs shall be saw cut the full depth to a neat line as indicated on the plans or in the specifications. If any existing concrete beyond the neat line so established is damaged or destroyed by these operations, it shall be replaced at the contractor's entire expense. 2.2 Existing concrete to be removed shall be broken up into pieces by air-driven machinery or by other suitable means. The use of explosives for breaking up old concrete to be removed is not permitted. 2.3 Work performed under this item shall be inaugurated at such time and prosecuted in such a manner as to cause a minimum of inconvenience to traffic or to the owners of adjacent property. Any area where pavement has been broken-up and/or removed shall require standard barricades, fencing, or other approved safety devices as will exclude public traffic until such time that the material has been properly replaced and approved by Owner. I. .3. MEASUREMENT . 3.1 Removing existing concrete sidewalks will be measured in linear feet in its original position regardless of its thickness. Removal of concrete curb shall not be measured or included or considered in the total quantity of material removed. All broken concrete removed shall become the property of the Contractor, and any disposal shall be considered incidental to the pay item. 3.2 Full depth saw cut will be measured by linear feet as cut. Technical Specifications Page 1 of 19 • TECHNICAL SPECIFICATIONS 4. PAYMENT 4.1 All work performed as required herein and as provided under "Measurement" will be paid for at the unit price bid per linear feet, which payment shall be full compensation for furnishing all labor, tools, equipment, hauling and disposal of broken concrete and all other incidentals necessary to complete the work. No payment shall be made for removal of curb but shall be considered incidental. 4.2 All saw cut shall be made to the full depth of materials that are required to be cut. This shall include all existing curb to be removed for handicap ramps. No separate payment shall be made for Saw-cutting but shall be considered incidental Technical Specifications Page 2 of 19 TECHNICAL SPECIFICATIONS ITEM II FOUR FOOT CONCRETE SIDEWALK REPLACEMENT 1. DESCRIPTION 1.1 This section covers the furnishing of all equipment, superintendence, labor, and materials necessary in construction of concrete sidewalks including handicap ramps in accordance with the plans and specifications. 2.. MATERIALS 2.1 Concrete shall conform with requirements specified in Technical Specification "Concrete for Structures". • 2.2 An approved type of commercial pre-molded expansion joint (3/4" thick) or redwood (1"thick) shall be placed. 2.3 Reinforcing steel shall be at the required spacing shown on detail sheet Bars: New billet-steel, deformed, ASTM A 615, Grade 60, bent dimensions complying with ACI 315 Wire mesh reinforcement a. Welded steel wire fabric. b. Wire complying with ASTM A 82. c. Mesh construction complying with ASTM A 185. d. Placement complying with ACI 318 2.4 Cushion sand shall be clean and well graded and free of clay and humus • material. 3. . CONSTRUCTION METHODS 3.1 Stripping: All grass and humus material shall be stripped and removed from the area of the sidewalk 3.2 Grading: After stripping and removing of grass, humus material, and tree roots, any soft or otherwise unsuitable material within the sidewalk area shall be removed and replaced with approved fill materials and compacted. The grade shall then be brought up to the bottom of the proposed level of the sidewalk with a maximum of four inches (4") of bank sand fill. 3.3 Forms: The sidewalk shall be formed and braced with, forms.of,wood or metal, straight, free from warp and of a nominal depth of four inches (4") prior to pouring of concrete. The•forms shall be braced so that no horizontal or vertical displacement occurs during the concrete pour or during the period for curing. 3.4 Expansion joints shall have a maximum spacing of thirty feet (30') between joints'or as shown on the plans and according to this specifications or as directed by the • Owner's Representative. Expansion joints shall be required where all sidewalks intersect Technical Specifications Page 3 of 19 TECHNICAL SPECIFICATIONS .3.5 During the placing of the concrete, the reinforcement shall be held in a position parallel with the surface plane of the sidewalk as shown on the plans or as called for in the specifications by the use of plastic chairs or other methods approved by the engineer. .3.6 The concrete surface shall have a rough, non-skid type finish. The concrete surface shall be free of any graffiti or writings. It shall be the contractor's responsibility to protect the freshly poured concrete and finish on the surface a sufficient length of time to allow the concrete to set up. Any concrete with graffiti and/or writing shall not be accepted and shall be removed and replaced by the contractor at no cost to the owner. 3.7 The dummy groove joint shall be edged in the surface of the concrete at every six foot (6') intervals. 3.8 The outer edge and joints shall be troweled to give a smooth surface and rounded to a 1/4 inch radii. 4. CURING 4.1 After the concrete has obtained a final set, the concrete surface shall be sprayed with membrane curing compound to protect it against loss of moisture for a- period.of not less than 72 hours from the beginning of curing operations. 4.2 Failure to provide the proper curing or other failures to comply with curing requirements shall be cause for immediate suspension of concreting operations. 5. CYLINDER OR BEAM TESTS 5.1 During work progress, the Owner, at his discretion, shall provide all cylinders or beam tests as specified herein. The laboratory testing and services shall be provided by the Owner. The Owner does hereby reserve the right to collect all cylinder samples himself, if desired, and deliver same to .the testing laboratory approved to perform the tests prior to the placement of concrete. The tests will be performed to maintain a check on the compressive or flexural strength of the concrete that is actually placed. The test shall be defined as the average of the breaking of three cylinders or two beams as the case may be. Test beam or cylinder specimens shall be required for each 167.5. cubic yards, or a portion thereof, placed each day. For smaller concrete placements, the Owner's Representative may vary the test specimens to 25 cubic yard placements, over a several day. period. Cylinders or beam specimens shall be placed, covered and stored in curing water tanks at temperatures between 70 degrees F. and 90 degrees•F., until transported to the testing laboratory. The test specimens shall be cured . in accordance with TI-ID Bulletin C-11. 6. PROTECTION OF SIDEWALK 6.1 . The contractor shall erect and maintain the barricades required by the plans and/or the specifications, or such other standard barricades and approved devices as will exclude public traffic and traffic of his employees and -agents from the, newly placed sidewalk. All barricades shall remain in place Technical Specifications Page 4 of 19 TECHNICAL SPECIFICATIONS until such time as the concrete has cured sufficiently to a point where it is safe to be used by the public and not be damaged by that use. Barricades shall not be removed until all form materials, surplus wood and steel or any other surplus materials have been removed from the site,to provide for the safety of the public. All areas adjacent to sidewalks where forms were removed shall be badkfilled and graded prior to removal of the barricades. 7. CLEAN-UP 7.1 The contractor shall remove all rubbish and waste materials from the site. The dean-up operation shall be kept up behind the construction at all times. 8. MEASUREMENT 8.1 The concrete sidewalk, complete in place, to the dimensions and limits ' detailed on the plans and as described in these specifications will be measured by linear feet of sidewalk placed. Curb shall be incidental to the job and will not be measured. 9. PAYMENT 9.1 The payment for the concrete sidewalk measured as indicated in paragraph 8 will be made at the contract unit bid price per linear feet for concrete sidewalk, complete in place. Payment will constitute full compensation for cost of furnishing all plant equipment, superintendence, labor, and materials and performing all operations required for a completed installation including stripping, grading, fill materials, furnishing and placing concrete and reinforcing, clean-up, and all incidental operations required for a complete foundation. 9.2 Wheel chair,ramps shall not be measured, but shall be paid for by lump sum at the contract bid price per each type of concrete wheel chair ramps identified on the Plans (Types A, B). Placement of sand cushion and concrete curb shall, be considered incidental and no separate pay item will be allowed. Technical Specifications Page 5 of 19 TECHNICAL SPECIFICATIONS • ITEM III CONCRETE FOR STRUCTURES • 1. DESCRIPTION. • • 1.1 This section shall govern the materials and methods used for the proportioning and mixing of concrete for pavement, driveways, pre-stressed concrete, • and other concrete incidentals required to complete the construction of the project. The concrete shall be composed of Portland cement, mineral filler, and natural aggregates, proportioned and mixed as provided in this specification. 2. MATERIALS 2.1 Cement The cement shall be Type I, Type II, or Type III of a standard brand of Portland Cement conforming to ASTM Designation C-150. Only one brand of cement will be permitted in any one structure. 2.2 Mixing Water. The water used with the cement shall be clean and suitable for drinking or for ordinary household use. 2.3 Course Aggregate: The course aggregate shall consist of gravel, crushed stone, or a combination of these two. 2.3.1 Gravel shall consist of durable particles of crushed or uncrushed gravel of • uniform quality throughout. It shall have a wear of not more than 40 percent when tested according to AASHO Method T-96. .2.3.2 Crushed stone shall consist of durable particles of stone of uniform quality and having the same wear as that required for gravel. 2.33 The course aggregate shall be free from an excess of salt, alkali, roots, and other objectionable matter. The maximum size aggregate shall be governed by the type • of structure in which the concrete.is used and as shown in Table I. Technical Specifications Page 6 of 19 TECHNICAL SPECIFICATIONS 2.3.4 The grading requirements of the course aggregate_ shall conform to the following: TABLE I Percentage Retained No. Maximum 3" 2 iCC 2" 1 ia, 1', No. 4 size 1 2 ln" 0 0-5 0-20 15-50 • 60-80 95-100 2 1 tin" 0 0 0-5 20-70 95-100 3 1" , 0 0-5 15-45 50-70 95-100 2.4 . Fine Aggregate: Fine aggregate shall consist of natural sand and be free from frozen material, foreign material, excess salt, alkali, or vegetable matter. It shall contain not more than 0.5 percent by weight of day lumps. 2.4.1 The grade requirements of the fine aggregate shall conform to the following: Sieve I Percent Retained 3" 0% • No. 4 0-5% No..8 0-20% No. 16 15-50% No. 30 40-75% No. 50 70-90% No. 100 90-100% 2.4.2 The fineness modulus of the fine aggregate shall be between 2.40 and 2.90. When this fineness modulus varies more than .20 than that being used in the current design, then the batch will be redesigned in accordance with standard Highway Department methods. 2.5 Admixtures: An air entrained concrete will be .used for all bridge superstructures. Air entrainment will also be required during hot weather placement. when, in the opinion of the Owner's Representative, the admixture is needed. 2.5.1 The air entrainment agent shall be of a standard commercial type conforming to the requirements of ASTM Designation C-260. Technical Specifications Page 7 of 19 TECHNICAL SPECIFICATIONS 3. PROPORTIONING AND CLASSIFICATION • 3.1 Concrete shall be proportioned as determined by the Owner's • Representative and using the method as outlined in the Texas Highway Department Bulletin C-11. The concrete shall be uniform and workable. The minimum cement content, maximum allowable water content, and maximum slump of the various classes shall conform to the following: Type of Construction Min. Min. Comp. Max Water Slump , Coarse Coarse SK/CY Strength 28 Cement Inches Aggregate Aggregate Day PSI Ratio Class No. Foundations 5 3000 7.0 2-3 1-2 A General Concrete 5 3000 7.0 3-4 2-3 'A Drilled Shafts All Superstructure 5 3000 6.5 2-3 2-3 A Concrete Riprap &Sidewalks 4.5 2500 7.0 3-4 1-2 B Pre-stressed 6-7 6000: 5.75 2-3 . 3 C Concrete Seal Concrete 6 . 3000 7.0 5-6 1-2 • D 3.2 The dry loose volume of course aggregate shall not be more than .82 cubic foot of the finished concrete. , 3.3 The net amount of water will be the amount added at the mixer, plus the free water in the aggregate, and minus the absorption of the aggregate based on a 30 minute absorption test as defined in THD Bulletin C-1 1. 3.4 Where flexural test beams are used the 7-day flexural strength shall be equal to or greater than one-sixth of the 28 day compression test. 3.5. Where the difference between the actual amount of concrete placed and the calculated theoretical amount required is more than 3%, the Owner's Representative shall require the re-design of the batch. . 4. CONSISTENCY 4.1 Concrete shall be of such consistency as to insure the required workability .and result in compact masses having dense, uniform surfaces. The quantities of the mix design shall not be varied unless authorized by the Owner's Representative. In cases where the characteristics of the aggregates are such that, with the maximum allowable amount of water the consistency requirements cannot be satisfied, the contractor may • furnish additional aggregates, mineral filler, or aggregates of a different character which will produce the desired results. If the contractor does not provide these materials, the Owner's Representative will modify the mix design with additional cement to produce proper workability. The addition of water to the approved batch design to provide workability will not be permitted. • Technical suede Ate innns Pane a of 19 TECHNICAL SPECIFICATIONS 4.2 In general, the consistency of concrete mixtures shall be such that: 4.2.1 The aggregates will not segregate and mortar will cling to the coarse aggregate. 4.2.2 The concrete when dropped from the discharge chute will flatten out at the center of the pile, but the edges will not flow. 4.2.3 The concrete will not show free water. - 4.2.4 The concrete will slide and not flow into place when discharged from the metal chute at an angle of 30 degrees with the horizontal. 4.2.5 The surface of the finished concrete will be free of laitance. 4.3 Any concrete mix failing to meet the above consistency requirements will be considered unsatisfactory although the concrete meets the required slump test. In cases where the characteristics of the aggregate furnished are such that, with the maximum allowable amount of water, the specified slumps and consistency requirements are not met, the contractor may provide aggregates of an improved grading, or the Owner's Representative, will modify the mix design to meet the slump and consistency requirements by adding cement. 4.4 The slump tests will be provided by the approved Testing Lab according to the standard ASTM testing procedures. 5. TESTING OF CONCRETE 5.1 During the progress of the work, the Laboratory will cast test cylinders for testing in order to maintain a check on the compressive strength of the concrete actually placed. 5.2 A test shall be defined as the average of the breaking strength of three cylinders. 5.3 Test cylinders for job site. control will be tested according to ASTM Designation: C-39 "Method of Test for Compressive Strength of Molded Concrete Cylinders". Test cylinders shall be made in accordance with Test Method Tex-7041. 5.4 All test specimens, beams, or cylinders representing tests for removal of forms or falsework for pre-stressed or post-tensioned beams shall be cured under the same conditions, subjected to the same curing materials, and to the same weather conditions as the concrete represented. 5.5 Other cylinders will be cured in accordance with THD Bulletin C-11. Technical Specifications Page 9 of 19 TECHNICAL SPECIFICATIONS 6. CONDITIONS 6.1 The concrete shall be mixed in quantities required for immediate use and in concrete not in place within the following : Air Temp. or Concrete Temp. Maximum Time in Mixer (Highest Value) 40 degrees F. to 74 degrees F. 90 minutes 75 degrees F. to 89 degrees F. 60 minutes 91 degrees F. and above 45 minutes 6.2 In threatening weather, which may result in conditions that will affect the quality of the concrete, the Owners Representative may order postponement of the work. Where work has been started and changes in weather conditions require protective measures, the contractor shall furnish.adequate shelter to protect the concrete against from rainfall or freezing temperatures. 6.3 Concreting will not be permitted when the temperature is 40 degrees Fahrenheit.and falling. 7. MEASUREMENT 7.1 Unless provided for in the proposal, the quantities of concrete of various classifications will not be measured directly but shall be included in the itemized bid structures. 8. PAYMENT 8.1 Payment will not be made but shall be incidental to the item for which it pertains. Technical Specifications Page 10 of 19 TECHNICAL SPECIFICATIONS ITEM IV UNDERMINED SIDEWALK POINT REPAIRS 1. DESCRIPTION 1.1 This item shall govern all excavation and backfilling of areas under or• around'existing sidewalks that have voids created by storm sewer lines, sanitary.sewer lines, manholes, or inlets that.have cracks or openings allowing materials under the sidewalk to be washed and carved away: It shall govern the furnishing of all equipment, supervision, labor, and materials to perform the repairs as specified. 2. MATERIALS 2:1 . . Materials' shall consist of cement stabilized sand as specified under the specifications Item 9. 3. CONSTRUCTION METHODS 3.1 The existing concrete sidewalk shall be removed in accordance with the specification Item 1. After the sidewalk is removed, the Owner's Representative shall • inspect the site.to determine the extent and cause for the voids. Based on the inspection, the Owner's Representative may instruct the contractor to just add cement stabilized sand in the void and compact it in an approved manner or he shall instruct the contractor as to the size,-location, and depth of any required excavation in order to allow the placement • and compaction of the cement stabilized sand. The size,.location, depth, and estimated volume of excavation shall be agreed upon by the Contractor and the Owner prior to proceeding with the repair. The normal width of any excavation of material down along side of any pipe or manhole shall be maintained as near as possible to a width of 12 inches. The maximum depth for 'the excavation shall not exceed 6 feet in depth as measured from the top of the existing natural ground. All excavated material shall be removed and disposed of as per the Owner's instructions. 3.2 If in the opinion of the Owner's Representative, more extensive repairs are warranted; the Owner shall have the option of making the additional repairs with City . personnel or negotiating with the Contractor for the additional repairs. All additional work • contemplated other than that described under section 3.1 shall only be done by Change Order. Technical Specifications Page 11 of 19 TECHNICAL SPECIFICATIONS 4. MEASUREMENT 4.1 Excavation and removal of existing soil materials and compaction of cement stabilized sand shall, be measured in cubic yards based on the amount of agreed excavation as specified in Section 3.1. Cement stabilized sand shall be measured as `'specified under cement stabilized sand. 5. PAYMENT 5.1 Excavation and removal of existing soil materials and compaction of cement stabilized sand shall be paid for by the cubic yard of excavated material as measured and agreed upon by the Owner and Contractor as specified in Section 3.1 and based on the unit.price bid for this item. . Technical Specifications Page 12 of 19 TECHNICAL SPECIFICATIONS ITEM V ADJUSTMENT OF METER BOXES, VALVE BOXES. AND MANHOLE RINGS AND COVER NONE REQUIRED IN THIS CONTRACT Technical Specifications Page 13 of 19 r TECHNICAL SPECIFICATIONS. ITEM VI CONCRETE DRIVEWAY REPLACEMENT NO DRIVEWAY REPLACEMENT REQUIRED IN THIS CONTRACT Technical Specifications Page 14 of 19 TECHNICAL SPECIFICATIONS THIS PAGE DELETED Technical Specifications Page 15 of 19 } TECHNICAL SPECIFICATIONS THIS PAGE DELETED Tgrhnirnl Snpcjflcatjnn&Panp i&rsf 1Q TECHNICAL SPECIFICATIONS ITEM VII BANK SAND 1. DESCRIPTION 1.1 . The work covered by this section consists of furnishing all plant equipment, labor, materials, and performance of all operations for placement of sand used as a cushion for sidewalks, driveways and wheelchair ramps, as well as extra sand ordered by the Engineer. 2. MATERIALS 2.1 Sand: The sand shall be a river sand free from roots and other objectionable matter. 3. CONSTRUCTION METHODS 3:1 Sand shall be placed, as directed by the Owner, in not more than four (4) inch layers, loose measured and compacted with mechanical tamps or other approved equipment. 4. MEASUREMENT 4.1 Sand ordered by the Engineer will be measured by the cubic yard based on delivery haul tickets which shall be provided to the Owner's representative on the day of the delivery. The sand tickets shall be subject to inspection and verification by determining the load capacity of the delivery vehicle(s). Sand used as a cushion for sidewalks, driveways and wheelchair ramps is considered incidental to the work, and will not be measured separately. 5. ' PAYMENT 5.1 Sand ordered by the Engineer will be paid, by the unit price.bid per cubic yard. Sand used as a cushion for sidewalks, driveways and wheelchair ramps is considered incidental to the work, and payment is included in the unit cost for each of these items. Technical Snnrlfiratlnna Pan 11 of 1,Q TECHNICAL SPECIFICATIONS ITEM VIII ST. AUGUSTINE BLOCK SODDING This Item consists of preparing ground, providing and planting St. Augustine grass, providing and distributing fertilizer, and subsequent watering, only on those areas approved by the Engineer. Materials: Sod: • 1. Use sod consisting of live, healthy, dense, vigorous, well rooted St: Augustine grass. 2. Sod to be free of debris, weeds ,or other grasses. 3. Sod to be a minimum. soil thickness of 1-inch. 4. Do not use sod which is dried out or which contains debris, weeds or other grasses. 5. Plant sod which has been excavated for this project within three days. Fertilizer: 1. Use Media Plus for new solid sod. 2. Apply in accordance with manufacturer's printed instruction. Payment: No separate payment will be made for grass and fertilizer unless it is considered extra • and ordered by the Engineer. TECHNICAL SPECIFICATIONS ITEM IX CEMENT STABILIZED SAND This section deleted. END * CITY OF LA PORTE P.O.BOX 1115 LA PORTE.TEXAS 77572.1115 TELEPHONE 281-471-5020 EN ERING CONSTRUCTION REPORT Job &'7v/M4 J�FN/LC/ Contractor _ _ Date Project No. 7.1/ Weather O Sunny D Rain Temp High Type of Work A Report No. Cloudy D Dry Low Pay' Location Description or Comments(Station,etc.) Quantity Item ct47ZC7l 0 3yz /�Fi�b!'.oG ct GirOE s/ti/ ate F.S I N /0330 lr a 4 Ir tr M /0506 k u I/ If I r ZD-L tf 4WevP/ '710411 /0330 r1 rr 4 rr 27 Sri `f Fy /0 SU tt 4 n 11 l r it Y/ /0493 h q it if iZVtr n rr O7 it n Tt a rr 37. V tF I I! I' 0 !I If rI rI It 5. 3 4F FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by LAS J TIME CHARGES Day Charged NO. CONTRACT y0 D Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS /Qd LEFT p/f Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance eflz'ztrS cli Inspector Supervisor Contractor MPECTOR SHA L MARE REPORTS IN TT PUCNE EACH DAY BEGINNING WITH REPORT NO.INC RUNNING cor4óiv TGfOUGH TIE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE RAPECt R. ISE A SEPARATE SHEET TO L5L SIOCH OR EXTEND REMANS CITY OF LA PORTE P.O.BOX 1115 LA PORTE.TEXAS 77572-1115 TELEPHONE 281-471.5020 ENGINEERING CONSTRUCTION REPORT Job 1lY!✓ID� N Contractor 4ttt rs 41,V*+'z- Dore SO/ Project No.24W— O Sunny �Raln High Qt' Type of Work eiQA0 i Report No. Z Weather %CIS ❑Dry Temp Low 1i Pay. Location Description or Comments(Station,etc.) Quantity Item __ ______ 7gN ___ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by GA S TIME CHARGES 0 Day Charged NO. CONTRACT 90*Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT c" Description Location Remarks Unusual Occuronces,Special Directions or reasons for non-performance GD s G '7. --- - /4/ , ',Vb Inspect« Supervisor Contractor INSPECTOR SMALL MAIQ REPORTS N TRIPLICATE EACH DAY BEGWMNC WITH REPORT NO.1 AND RUNNING C Lv ThROUGH THE a WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RFWNFD BY THE OR. -IRE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTS TEXAS 77572-1115 per,, �/ TELEPHONE 261-471-5020ENGINEERING CONSTRUCTION REPORT 1'1O4 [ Job G//l"/t//�iLG✓ / Contractor AX-MlO 4Z C4 Date O! Project No.______ ❑Sunny ❑Roin High . Type of Work Report No. Weather Temp I>o Cloudy ❑Dry LOW Pay. Location Description or Comments(Station,etc.) Quantity Item `11P,Q/ 11J. � 'o / ,c MAw OF f'/.t✓/ae ealW -SAv /6. 9 I W /3-#/7 T/ If ,, r1 $Oo if Jf �/ l 1 tG e ZZZ N y l/ /, g- / tic / • " çZ!0 fl /i /r /r N 1 ti // 5-1/9 iF Fr Jf /i i/ 7 Zfr $- 11 // 570/ N IY q N Z/ // /f /i // !/ O Lf H 3 /F It /r r/ /Y z-3 Gf FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by L ___________ $t92Z*(Si( / ___ s,e;cee j-_ TIME CHARGES Day Charged NO. CONTRACT 9a O Day Not Charged DAYS Reason for NO. Not Charged DAYS Z USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT Fj Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance Inspector Supervisor Contractor N9RUC11O G: INSPECTOR SHALL MAKE REPORTS N TRIPWANE EACH DAY BEGNMNG WITH IEPORT NO.I AN)RUNMNG C lY T}POUGH THE JOB. W/1RE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PRR(COPy REUWED BY THE •USE A SEPARATE SHEET TO UST SIETCH OR MEND REMAIN• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 7,sTELEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job U!/�/���✓ Contractor fl Date 'W Project No.z2vG'-/��d/ Weather O Sunny ,Y�Roin Temp High Type of Work Ctt'- Report No. _________ Cloudy ❑Dry Low 76 Pay. Location Description or Comments(Station,etc.) Quantity Item _______ ye__7/ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES O Day Charged NO. CONTRACT /7 Day Not Charged DAYS Reason for NO . Not Charged DAYS Z USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT ever /,N Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance D ,eg/d Inspector Supervisor Contractor lATRUCTgN5: INSPECTOR SHALL MAKE REPORTS W IRTPOCATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING EC LY THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE CT�iR. -TAE A SEPARATE SKEET TO ISI SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE.TEXAS 77572-1115 TELEPHONE., 281-471-5020 ENGINEERING CONSTRUCTION REPORT 14'0No.______ Job &774 �/w✓k-� Contactor G Y c,�S DD Date Project Weather O Sunny ❑Rain Temp Hroh Type of Work GD.Lex Report No. loudy O Dry Low Pay' Location Description or Comments(Station,etc.) Quantity ttem %W 3W 3 R *w of 'wi#t 4tl. .fl, /7 I " czoe Lf Ir 2/ H r7 /r it �. 7L L,F AC/6 O /i // /Fl tF N Yr 'J N N If /r I GF N /O N / /f nr 2 /f If /r ii n 3. L .F 972 ' a /, /, /� 5 l✓ !�' SK S1 1 it ,f e z (f S. !, :?z Z N • 1 r, Ir / - 6 LF H ZZ „ Ir 173 /t FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Subb Cont. No. Hrs. Equipment No. In Use Stand-by _______________ __ 4m-ffi& L_ TIME CHARGES CWSay Charged NO. CONTRACT 10 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS - USED NO. O- Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS / LEFT tT Description Location Remarks.Unusual Occurances,Special Directions or reasons for non-performance ,CEs9.'L Inspector Supervisor Contractor RSPECTOR WALL MARE REPORTS W TRIPLICATE EACH DAY BEGWNWG YAM REPORT NO.I AND RUNNWG C ROUGH THE JO& WHITE COPY FOR OFFICE YELLOwCOPY FOR CONTRACTOR AND PWI(COP'RETAWED BY THE TOR -USE A SEPARATE SHEET TO USt SI ETCH OR EXTEPD REMNL6 CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /, p �� ,OTELLEEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job c�/��/�%//W✓✓/LLB Contractor L�/`r✓(/.��i C St Date ________ Project No._______ O nnySu >A Roln High 75 Type of Work Weather ,,� ' \ Temp Report No. ,4loudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item _____ /0 // __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES O DbCrged NO. CONTRACT a Day Not Charged DAYS /9 Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves Figs.,etc.) DAYS Qi LEFT (t/�jT Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance /ro 49ZC. 1CIM" Inspector Supervisor Contractor mcnluCilatc: INSPECTOR SHALL MAKE REPORR W TRIPLICATE EACH DAY BEGINN ING WITH REPORT NO.I AND RUNNING cCrvtiY THROUGH THE JOB. WHTIE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECTOR. •ISE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281.471-5020 ENGINEERING CONSTRUCTION REPORT Job 'J contractor G5�Vt *l Dote Project No. � unny O Raln High Weather Temp Type of Work Report No. O Cloudy O Dry Low Pw' Location Description or Comments(Station etc.) Quontity Item ZZó li of "!.//Of- fl ,t tF / 'i Zz-/ /i 3 rf t33 ii /1 it FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO, CONTRACT A ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances.Special Directions or reasons for nonperformance O o� c'IX ' SAF/. Inspector SupeMsor Contractor M1ThJCmt4: INSPECTOR SHML MAKE REPORTS IN TRIPLICATE EACH DAY BEGWNWG WITH REPORT NO.I MD RUNNWG C IV THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR MD PBM COPY REWNED BY THE YSPE OR. •USE A SEPARATE SHEET TO Lt SKETCH OR EXTEW REMARKS CITY OF LA PORTE 0 P.O.BOX 1115 LA PORTE.TEXAS 77572-1115 TELEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job C/'r �F%�9 6Ud'Contractor f 2? frF Date �Z_______ Project No. �`//� / 1 Weather Temp CGC O Rain High�� Type of Work Report No. O Cloudy O Dry Low Pw' Location Description or Comments(Station,etc.) Quantity Item Z- 1WA4/ .zit/ ' /46 Sc-a Z &72&K /0 Z Z /T 0 ti „ / le, Z I/ 06 H H // Zrl.z i /,4'/# /L 0 O l r " u n 27. S 2 .r " /p35?.) lE A N N /I ll 03 /' N /Y /ZY f /I ll O x // J, M [f II a /+ // // /S. 3 <f Z C- v/*uE £20 Y .A flY 2. ({ / /I M // 4 /r [ ,f 11 S JT JI Jr D GF ll l/ // r/ /r I, S3 LF Z MA4*AIC 2/ a /, I 36.2 Z N sr Z N R 11 Y/ /7.C [f n !J SZzG // 4 I/ /I GF L c<M e/'/ !r/ ST,16 n y `/ '/ 0.8 <F // /f Zz ry ti 4 r/ . 3 LF FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No, His. Equipment No. In Use Stand-by GA I __ TIME CHARGES y Charged NO. CONTRACT �v O Day Not Charged DAYS Reason for NO. Not Charged DAYS / USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance , 1i Ii -. - Inspector Supervisor Contra�c HAL Jtt] INSPECTORSL MAKE R IN EPORTS TRIPLI CATE EACH DAY BEGWNWG WITH REPOW NO.I AND RUTARIC��ONSEC Of THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PRM COPY RETAINED BY CT •USE A SEPARATE SHEET TO LIST.SKETCH OR EXTEND REMARKS• 7 CITY OF LA PORTE c2 P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 �i o®,arr,,,�� TELEPHONE 281-471-5020 ENGINEERING ENGINEERING CONSTRUCT1ONPEEPO�RTd�,,� Job & AAK�� /*,W/Gc/Contractor ! 'cis tSebtt' Date Z G� Project No,4' ,nny O Rain High <7A $Weather Temp g p v Type of Work Report No.K ❑Cloudy ❑Dry Low Pw' Location Description or Comments(Station,etc.) Quantity item Z / / 9'/ ws 4te Z 9 Z a Z Yi y ' $ ti y z,z FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES tGay Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditlorns(Describe) Incidental Items(Valves Figs.,etc.) DAYS LEFT Description Location Remarks Unusual Occuronces Special Directions or reasons for nonperformance ,ccCi/ T Inspector Supervisor Contractor WrRUCTIONS: INSPECTOR SHALL MAKE REPORTS N 71tPLCAE EACH DAY BEGNNNG WITH REPORT NO.I AND RUNNNGc LY 7MOUGH THE JOB. WHITE COW FOR OFFICE YELLOW COW FOR CONTRACTOR AND PM coW REWNED BY THE ICE •USE A SEPARATE SHEET TO LLSL SKETCH OR EXIEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ��77�'l`� TELEPHONE 261-471-5020 ENGINEERING CONSTRUCTION REPORT Job��y/✓/ '&'///'�G(/�GY Conhactor AiGCi'CJ /3Z/-'U`S�li Date b Protect No.z —M'Znny Cl Rain High / 7 Weather Temp Type of Work Report No. zq O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item /a cSte , P .s Z 7 tf E. fi4Ac/tG L t/ y it !f // .,3 Lf . /r /r /Yry iY // !/ // // Lf - ) F SN.CCOR. .rrR rpn \I to / r // .J NiC0iz. r.tr;,- .n'4 rl rr I I n C /. 1 0 Lr FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use tand-by / TIME CHARGES Charged NO. CONTRACT QO O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Protect Site Conditions(Describe) Incidental items(Naives.Figs.,etc.) DAYS 5( LEFT v Description Location Remarks,Unusual Occuronces,Special Directions or reasons for non-performance O d Oq/ Inspector Supervisor Contractor NSIRIICIgNS: INSPECTOR SHALL MAKE REPORTS N 1RIPUCNE EACH DAY BEGINNING WITH REPORT NO.1 AND RUNNNG c 96OuGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PNN COPY RETAINED BY THE •USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 / TELEPHONETELEPHONE 281.471.5020 ENGINE RING CONSTRUCTION REPORT Job C;w w/4d % Pc.i&t Contractor took c (tea ncjrw h8 Dote N Project No.2000— 65unny O Rain High Type of Work L2 Pt e. . Report No.�� Weather Temp O Cloudy D Dry Low Pay. Location Description or Comments(Station,etc.) Quantity item __ / 5p p __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIE$ Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES BDoy Charged NO. CONTRACT 10 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS 27 LEFT Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance Inspector flar Contractor PSTRUCr10FS: INSPECTOR SHALL MAKE REPORR W TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AID RUNNING LY THROUGH THE JOB. WHITE COW FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PBIK COPY RETAINED BY THE 11 PECTOR. •IRE A SEPARATE SHEET TO LIST SKETCH OR EXTEND REMARKS f CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 Q TELEPHONE NE 281-4715020 EN INEE INC CONSTRUCTION REPORT JoK� ► �✓ I 'r Contractor Lookc (! -Pllctet Date �f Project No. � L9'Srunny O Rain High Weather Temp Type of Work Ca/l C. Report No. /! 0 Cloudy ❑Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item tea . C./. o•r$ytvt t t r I I 2 . - C.r. rt n r' + a t t / r I CO . I. .r i.ASroNt �•• ea-. . .rn For- + it t G allr. .M1 s'grps.- t It r! I L° FORCE AND EQUIPMENT ON JOB LABORATORY ACTNfTIES Labor Force/Sub Cont. No. His. Equipment Na In Use Stand-by TIME CHARGES Doy Charged NO. 9� CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED VVV NO. Si Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occuronces,Special Directions or reasons for non-performance O ✓`r r Inspector Supervisor Contract40R I STRUCTIONS: INSPECTOR SHALL MATS REPORTS W TRIPL ICATE EACH DAY BEGINNING YAM REPORT NO.I AND..INNING CMRaUGH RIE.g8. WHIM COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AID PINK COPY RETANED BY THE INSPE •USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS- CITY OF LA PORTE P.O.BOX1115 LA PORTE,TEXAS 77572-1115 ����// TELEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job6r Wi e S Contractor Bfo0ks £Co/tGr&t-e Date �6 O ProjectNo,2 70/ unny Weather O Rain Temp High Type of Work C e ri tt Report No. /1 O Cloudy ❑Dry Low Pay' Location Description or Comments(Station,etc.) Quantity ttem r FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. D CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT e i r Description Location 1 Remarks,Unusual Occurances,Special Directions or reasons for non-performance N Inspector Supervisor Contractor P507UCTIOM: MKCT R SHALL MAKE REPORTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO,I AID RUNMNG cj&c LY THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AID PINK COPY RETAWED BY THE CTOR. •USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE/NE 281-471-5020 E GINEERING CONSTRUCTION REPORT J 4/ Contractor B M0kS �--DVI c,tt° Date 94t61Project No. unny O Rain Weather Temp High Type of Work r.,1/_- Report No. /3 O Cloudy D Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Mem '/ ) / W' S n 2 /r / Rr o 1, l r / (/ / / , 1 //2. S. o , I rr /1 Ir rl rl j_ , I' VI / 2 . 1 11 11 rl FI 7 . / Ir �r Ir I ! I r / !7n I / 72 r / n FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont, No. Hrs. Equipment No. In Use Stand-by LF 3 TIME CHARGES Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for DO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance i Inspector Supervisor Contractor WSIRUCTIOM: IWPECTOR SHALL MA*REPORTS W TRIPUCNE EACH DAY BEGWNING WITH REPORT NO.I AND RUNMHG COtC .AOJGH THE O. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PWK COPY REWNED BY THE WSPE •USE A SEPARATE SHEET TO REE S KTCH OR EXTEND REMARKS• CITY OF LA PORTE P.O.BOX 1115 IA PORTE,TEXAS 77572-1115 D u Q TELEPHONE I 281-4715020 ENGINEERING CONSTRUCTION REPORT Job W J E I I r Contractor Rrooks, cCp AGte re Date e MQ Project No.�0/ Weather unny ❑Rain Temp High Type of Work (Cpi C Report No. /4 O Cloudy O Dry Low Pw' Location Description or Comments(Station,etc.) Quantity Item _____ ______________/ $J0 ty ______ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. q CONTRACT lO 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance r C • N r& .'r r Inspector 1I Supervisor Contractor INSTRUCTIONS: I SPECTOR SRAU MAZE REPORTS N TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.R ANC PUP*NC &Cttiv TOUGH TIE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE Ci •USE A SEPARATE SHEET TO ISL SKETCH OR E%IEND IEMARC CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job" W; 'pCrcontractor L00 ks Co✓tc rere Date (/2%/O Protect No. 2400- of unny D Rain High T of Work ran -_. Re ort No. Weather Temp ypB P D Cloudy ❑Dry Low Pay. Location Description or Comments(Station,etc.) Quantity item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES labor Force/Sub Cont. No. Hrs. Equipment Na In Use Stand-by a Chi TIME CHARGES D'lSoy Charged NO. CONTRACT QO O Day Not Charged DAYS I Reason for NO. Not Charged DAYS /2 USED ( 7 NO. 77 Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance Sr fc . Inspector Supervisor Contractor WSIRUCIK7N5: INSPECTOR SHALL MAKE REPORR W TRIPLICATE EACH DAY BEGWNWG WS I}4 REPORT NO.I AND RUNNNG LY MR%IGH THE a WHRE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY REWNED BY THE •USE A SEPMAIE SHEET TO Lt SKETCH OR EXTEND REMMKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 2281-471-5020 ENGINEERING CONSTRUCTION REPORT Jo 54'u ontractor ii coo k C(nn C(C fr Dote G/Tl Project No. ztVO- 5-O1 unny O Rain High Type of Work _L'a 0 • Report No. Weather O Cloudy O Dry Temp Low Pay. Location Description or Comments(Station,etc.) Quantity item 3 l 6 R r 9 ?N 2'-t. IL./( k 99416 2U rF�cn� 97 51 3 . rt lbaO B l 7127N. 2 OoO.2 0 30. / 0002 00 3 FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment Na In Use Stand-by ___________ 4-aborwc /O ______ IL_/ ____ TIME CHARGES Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. """��/ Not Charged DAYS /G/ USED NO. Project Site Conditions(Describe) Incidental Items(Vatves.Ftgs.,etc.) DAYS LEFT •r Description Location Remarks Unusual Occurances,Special Directions or reasons for non-performance s r W- G. `S Inspector [ Supervisor Contractor INSTRUCTIONS INSPECTOR SHALL MAKE REPORTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING cat t400GH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PIN(COPY RETAPRED By THE YSPf •TAE A SEPARATE SHEET TO IA[SKETCH OR EXTEFD REMARKS . . c. ...r.. . - _ 1• .l Yr -. -y- r;n .. -{:.o •-Y`. lt>'^;�.[i4'w'yJF'•c i^'.r ryyKp j ..Y.lt.+'^���r�,Mr.....�. ________________- fCv.r & (o�� i r to re vv�m141 Q !DO 0 2 I/ovcrr (!4O O 3 Srs•.n ,, ,oar gcu6 ç[ // t CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 Bran TELEPHONE/2281-471-5020 ENGINEERING�f CONSTRUCTION REPORT Job / P r*Contractor B r a o ks Eoa t c re i-P Date L 01 Project No. 2P00 -'C01 Weather ❑Sunny 94�aln Temp High Type of Work C_onc.- Report No._________ 9'Eloudy 0 Dry LOW Pw' Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by TIME CHARGES ❑ Day Charged NO. I D CONTRACT Day Not Charged DAYS Reason for NO Not Charged DAYS /L/ USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFTijp Description Location Remarks Unusual Occurances,Special Directions or reasons for non-performance AL /ALrk a Inspector SupeMsor Contractor W61RUCWM: RISPECTOR SWILL MA*REPORTS W TT PUCNE EACH DAY BEGINMNG WITH REPORT NO.1 MO RuPnNG C LY THROUGH TI*JOB. WHITE COPY FOP OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY REWNEO BY THE IP6PE . USE A SEPARATE SHEET TO LLSE SKETCH OR EXTEND REMAIL6 CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ` , TELEPHONE 281-471-5020 E GINS RING CONSTRUCTION REPORT '. /Job et«-v W,YC - L Pct-eT'r%ct- Contractor /Sp rook c !/erl C . Dote 1- Project No. 2g50-gCnny SD� O Rain High Type of Work C. h G Re rt No. Weather TempReport O Cloudy ❑Dry Low Pw' Location Description or Comments(Station,etc.) Quantity item ___ ________ __j\Jh_ LI3k ___ ____ / _________________________ _____ 0.� FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS /S USED NO. Project Site Conditions(Describe) Incidental Items(Valves Ftgs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances Special Directions or reasons for non-performance Inspector Supervisor Contractor IVSIRUCTpN5: INSPECTORWHITE CoUIrra on S W 7 L10W C EACH DAYCONI NNMG AND PMPCXfl CO Y I AND TI UNNWG C IV THROUGH II1E JOe. WHITE CO%FOR OrEICE.YELLOW CO%TOR CONTRACTOR AND Plra(CO%rEWw BV 1NE •USE A SEPARATE S HET TO Lt SQTCH OR EXTEND REMATL6 I_. CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ' ',/, I S/� p TELEPHONE 281.471.5020 ENG I NES ING CONSTRUCTION REEP,ORRT, Job� Controctor B r01)kS (p4 C(B tC Date / Project Na. — �L�� ' 1 Weather O Sunny ain Temp High Type of Work n 0 _- Report No. 44 Qtloudy O Dry Low Pay. Location Description or Comments(Station.etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES 0 Day Charged NO. CONTRACT R(Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT LL aAy Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Inspector ! Supervisor Contractor ItSCPUCTIN5: INSPECTOR SHALL MAKE REPORTS IN TTPLICCE EACH DAY BEGINNWG WRH REPORT NO.I AND RUNMNG cot { LY RWORGH THE JOB. WHTIE COPY FOR OFFCE.YELLOW COPY FOR CONTRACTOR AND PINK COPY REWNED BY THE CROR. •USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS CITY OF_LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /, /� TELEPHONE� 281-471-5020 ENGINEERING CONSTRUCTION REPORT RT " Job •1-Yt y 1' lA. /w o±Krontractor Rn'o k- , &n c re f e Date c 2 Project No. , '�0 BSunny O Rain High Type of Work yL C-. Report No. ___ Weather O Ckwdy O a9 TemP LOW Pay. Location Description or Comments(Station,etc.) Quantity Item Q FORCE AND EQUIPMENT ON JOB LABORATORY ACTTVfTIES Labor Force/Sub Cont. NO. Hrs. Equipment No. In Use Stand-by r TIME CHARGES Day Charged NO. O • CONTRACT A 13 Day Not Charged DAYS Reason for NO. Not Charged DAYS /6 USED NO. Project Site Conditions(Describe) Incidental items(Valves,Ftgs.,etc.) DAYS LEFT 7 a I r Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance . G. 's ' .. P.,- Inspector Supervisor Contractor NSIRUCTEN5: INSPECTOR SHALL MAKE REPORTS N TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNNG cotdculltncouGH RE JOB. WINE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PIW COPY REWNED BY THE Y6PECIOR. -WE A SEPARATE SHEET TO USE SKETCH OR MEND REMAIM CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE I_' 281.471-5020 ENGINEERING CONSTRUCTION REPORT Job(R fl/ W t), 51, (J) r�PL-r Contractor Q 1,ranks ( _p nc ctP Dote b �� Project No. 2 00 L1SO I B' ain High �� / WeaTher Temp Type of Work nA _. Report No. _ate I9€oudy O Dry LOW Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES 0 Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. ,/ Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS 1 LEFT Description Location Remarks.Unusual Occurances Special Directions or reasons for non-performance A5 k)ork /tiit Inspector SupeMsor Contractor INSTTICTIOIc: INSPECTOR SHALL MAKE REPORTS IN TRIPLICATE EACH DAY BEGINNING WTIH REPORT NO.I AID RUNNING C LV THROUGH THE.DO. WHITE COPY FOR OFFICE YELLOW COW FOR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECT •USE A SEPARATE SHEET TO UST SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 2281-4715020 ENGINEERING CONSTRUCTION REPORT JobtC+ Dy '•�r'de I jcclControctor &oaks ( t^c ??rt Dote Project No. 'C ' — SO/ Wye E nny O Rain Temp High Type of Work (1iv�t G . Report No. O Cloudy ❑Dry Low Pay • Location Description or Comments(Station,etc.) Quantity Item _/_'_c ___ ____ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. HIS. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS /7 USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS 73 LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Inspector/&/'1 Supervisor Contractor I STRUCTvta: INSPECTOR SHALL MAKE REPORTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING COtqtUTr4Lt fl OUGH THE JOB. WHRE COW FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PRO(COW RETAINED BY THE MPE •USE A SEPARATE SHEET TO LLSE S*TCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 EN INEE ING CONSTRUCTION REPORT Job C F- W1')6 Z ' ' Itonftactor R�mO Ic$ C0✓l Gr'e(e Date 4 Project No. Weather vCnny O Rain Temp High Type of Work efdl a(-- Report No. 0 Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Doy Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance Inspector Supervisor Conhactor INSTRUCTION$: INSPECTOR SHALL MAKE REPORTS IN TWn1CAYE EACH DAY BEGINNING WITH REPORT NO.I MV RUWRNG C LY THROUGH THE JOB. WHITE COPY FOR OFFICE FELLOW COPY FOR CONTRACTOR AND PRR(COPY REIANED BY THE TNSPE OR. •I.&A SEPARATE SHFFT TO UST.SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-,1115 TELEPHONE 281-471-5020 EN INEERI G CONSTRUCTION REPORT `nC_ s Job i Pfe ontractor [X'Q(2kc (1I#ICcI2ft /Date 2 Project No. 2a — "r(/≤ol Weather °Cnny O Rain Temp High Type of Work Co„.a, Report No. __________ O Cloudy O Dry LOW Pay Location Description or Comments(Station,etc.) Quantity Item a S 3 3 " Ft F f H 26 . 7 FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by r ✓ ' ri TIME CHARGES Day Charged NO, CONTRACT D 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Condmons(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT y Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance kemnr T ✓ S . G . . s r-i t'G Inspector Supervbor Contractor WSMUCTIOM: WSPECTOR HA i MAKE REPORTS W 1WPUCNE EACH DAY BEGWFING WITH REPaRI NO.1 AND RUNNING CONSEC ouGH DC 8. WHRE COPY FOR OFFICE FELLOW COPY FOR CONTRACTOR AND WI(COPY REtAIIED BY THE INSPECTOR. •USE A SEPARATE SHEET TO Lt SIh1CH OR EXTEND FEMNrl6 • CITY OF LA PORTE P.O.BOX 1115 LA PORTS TEXAS 77572-1115 TELEPHONE 281-471-5020 ErGIN RING CONSTRUCTION REPORT Job ' y m'ectontactor!ff0O f C nc&te Date Project No. C 2 SO/ unny O Pain High Temp Type of Work Cllr\G ?. Report No. / 0 Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item r^ • 3 /1/C EeKJ°o / // • Gr. ee 60. 3 '1 ' II / r a 3 r. U I e- N&at. H I 1 y 3 r. I 2 ecru I < . f 2 .r. l.o � II /I I C I , z A/W I' /f // If ll I ! u r ' , l I I rr -76 M' rI r f ( II It It ' I /2 . O1-F 2VtCet. Flee r I It /I I ' S FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES fyDay Charged NO. Q CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. / Project Site Conditions(Describe) Incidental Items(Valves Figs.,etc.) DAYS !� LEFT ` Description Location Remarks.Unusual Occurances,Special Directions or reasons for non-performance fiG S © v 00 Inspector& Supervisor Contractor INSIRUCTOFC: INSPECTOR SHALL MAC REPORTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING CONS EC LY IROJGH THE JO B. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACFORAND PINK COPY REUINED BY THE INSPECT -USE A SEPARATE SHEET TO USI SIQTCH OR E%TENI)REMARKS • CITY OF LA PORTE PO. BOX 1115 LA PORTE,TEXAS 77572-1115 // D p LTELEPHOONE 281-471-5020 GIN ERING CONSTRUCTION REPORT Job(�r'fY W ide ?/%jAC Contractor b rooks (; one Date E 7/7/of Project No. -DSO/ B'St nny High Weather O Rain Temp Type of Work Cc's-C. Report No.________ ❑Cloudy O Dry Low Pw' Location Description or Comments(Station,etc.) Quantity item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Standby TIME CHARGES ay Charged NO. O Day Not Charged DA S Reason for NO. Not Charged DAYS • USED NO. Project Site Conditions(Describe) Incidental Items(Wives Ftgs.,etc.) DAYS LEFT y- Description Location Remarks.Unusual Occurances Special Directions or reasons for non-performance B Inspector LA? Supervisor Contractor NSBAICTONS: INSPECTOR SHALL MAKE REPORTS N TWPUCATE EACH DAY BEGNMHG wrrH REPORT Na.RUNMNG C UTNELY THE JOB. WHITE COPY FOR OFFICE,YELLOW COPY FO R CONTRACTOR AND PIN(COPY REMPED BY THE I ECr •USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 7 GI EERING CONSTRUCTION REPORT ,/ ± c1 o� Contractor Eros/cc ( D►lorr_t Date _L� Project No. 2G `1Sol Weather E Sunny Raln Temp High Type of Work — Cfl C-. Report No. 2 t O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item ( } . t2 LABORATORY ACTIVITIES FORCE AND EQUIPMENT ON JOB Labor Force/Sub Cont. No. Hrs. Equipment Na In Use Stand-by _____________________ __ ______-____ TIME CHARGES Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. ^ Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance YTAA/ G, Inspector E'L Supervisor Contractor IIBTRUCT1Ot : INSPECTOR SHALL MAKE REPORTS IN TRIPUCATE EACH DAY BEGINNING WUH REPORT NO.1 AID RUNNING Co7W7011GH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINT(COPY REWNED BY THE •USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281.471,5020 E GIN ERING CONSTRUCTION REPORTT Job ` e f 103pctc0n#actor Looks ncftf6 Dare 7 O Project No. , t unny O Rain Weather High Type of Work Report No. O Cloudy O Dry Temp Low Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stond-by TIME CHARGES Day Charged NO. CONTRACT qD 0 Day Not Charged DAYS Reason for NO. p Not Charged DAYS 1 USED NO. / Project Site Conditions(Describe) Incidental Items(Naves.Figs.,etc.) DAYS LEFT r Description - Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance Inspector j ' Supervisor Contractor V$IRlICT10N5: R6PECTOR SWILL MM Q REPOR1$14 mIPlICMEEACH DAY BEGWNWGWin REPORT NO.I MID RUNNWGC CNNELY TIW(A1OH ThE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR MID PWK COPY REWNED BY 7NE OR. -USE A SEPARATE SHEET TO LISL SKETCH OR EXTEND REMAIN • CITY OF LA PORTE P.O.BOX 1115 IA PORTE,TEXAS 77572-1115 1./ 5/ D TELEPHONE 281-471-5020E IN ERING CONSTRUCTION REPORT Jobe' Wrde ! /ojBGl" contract« �/2rokc £l ytt(etd Date 7// Of Project No._______ L'7tinny ❑Raln Highf� Weather Temp Type of Work ( \.C�YC Report No. 0 Cloudy 0 Dry low Pay. Location Description or Comments(Station,etc.) Quantity Item I " k" ;J 6,r-c. s rr IIr r �, �r 3.9 LP it /223 T F 1It t 2I_ a /7O ° ' ' t r 7•S /17/( jO. jf rf V7, OLF /1731 /t FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by 4er� . rAtk t TIME CHARGES Day Charged NO. CONTRACT 9O ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Condtllons(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-pert«monde fr Inspector Supervisor contractor IPSIRIlCTIOIG: INSPECTOR$IIAIl MAKE REPORTS W 7PoPDCRE EACH DAY BEGWNWG WITH REPORT NO.1 MO RUNNVJG COU &Y T} OuGH THE JOB. WHRE COPY FOR OFFICE.YELLOW COPY FOR CONTRACTOR AND PINK COPY REWNED BY THE OR. •USE A SEPARATE SHEET TO l5[SKETCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 / k/-d. ,{/n_ TELEPHONE 281-471-5020 ENGINEER NG CONSTRUCTION REPORT C/ JobCiI t)/ S11J tect-Confractor !/7f k's if ✓ cC&t e DDate �17 Project No.260O EKnny O Raln High weather Temp of Work GfI✓l C-. Report No. _ 0 Cloudy 0 Dry Temp Low Pay. Location Description or Comments(Station,etc.) Quantity Item i 1'Olti ' /� ' S O x I ' ' / T ,T 3. 91-F i2..23 „ 1., 2 Lr /1-702 7. LP 171 " d 6 F 1-7 .o 2 rn≤ / '' H '' K 17. O LF 2 /173 / Yf s . 3 !s FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by 8 TIME CHARGES Day Charged NO. CONTRACT RQ O Day Not Charged DAYS Reason for NO. Not Charged DAYS 31 USED NO. Project Site Conditions(Describe) Incidental Items(wlve&Ftgs.,etc.) DAYS LEFT c Description Location Remarks.Unusual Occurance&Special Directions or reasons for non-performance sYt'lt Inspector dPi. Supervisor Contractor P61FUCfIOM: INSPECTOR SHALL MAKE REPORTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNPmG CO C YMTOOGH THE A& WHITE COPY FOR Off CE.YELLOW COPY FOR CONTRACTOR AND PINK COPY REIAMD BY THE INSPECTOR. •ESE A SEPARATE SHEET TO LSL SIQTCH OR WEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 �- TELEPHONE 281.471.5020 NGI ERING CONSTRUCTION REPORT Job�i• rO'r! 1 t6ed!! on tractor 22 fl'ro Date7/1170 / ProjectNo. __ E75rilnny O ROIn Weather Temp High Type of Work G• Report No. O Cloudy 00w LOW Pay. Location Description or Comments(Station,etc.) Quantity Item __ (/ (i) A' ) __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental ttems(Valve&Figs.,etc.) DAYS LEFT p r r Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance o r inspector /'7 Supervisor Contractor N61RUCT l5: INSPECTOR SHALL MALE REPORTS N TRIPIICATE EACH DAY BEGINNING YAM REPORT NO.I AID RUNNING C C TEROUGH TIE JOB. WHITE COW FOR OFFICE YELLOW COPY FOR CONTRACTOR AID PINK COPY REINED 8Y THE INSPECTOR •WE A SEPARNE SHEET TO USE SKETCH OR OTEID REMN86- • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /' W1'0? '/ LOO E GIN ERING CONSTRUCTION REPORT'/ Jotc a*y O? %I ' AjPCtContractor LOO kc LO/L G ft ? Date 7 Q/ Project No. s��O1≤o/ 65unny O Raln High Type of Work C,D•nl Report No. 7 Weather Temp - Po 0 Cloudy Dory Low Pw' Location - Description or Comments(Station,etc.) Quantity Item __ / __ V v FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No, Hrs, Equipment No. In Use Stand-by TIME CHARGES Doy Charged NO. CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occuronces,Special Directions or reasons for non-performance m Inspector 6T/'( Supervisor Contractor VSIRUCIION5: INSPECTOR SNAIL MAKE rEPORTS N TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUI*ING COt4tJ&THOUGH TE JOB. WIRE COPY FOR OFFICE YELLOW COPY FOR CONRACTOR AND PVB(COW RETAf1ED BY 11*NSPE •ISE A SEPARATE SHEET 10 Lt SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572.1115 I,' n /[// TELEPHONE 281-471-5020 E GIN RING CONSTRUCTION REPORT JotYq'f r/ W j� s�41&0�Y Contractor /marl Inc 61 G�I` Date b Project No.2090 / �ny ❑Rain High Type of Work Report No. - Weather O Cloudy O Dry Temp Low Pw' Location Description or Comments(Station.etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by �E r TIME CHARGES DoyCharged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Navies.Figs..etc.) DAYS LEFT ` Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance tm0 w l Inspector jQ/r r Supervisor Contractor WRUCTIONS II'GPECTORSHALL MAI*REPCRIS W TMPLICA1E EACH DAY BEGWNWG W7IH IEPORT NO.I AND RUNNPIG CONSEC LV UGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FIX CONTRACTOR AND PRU(COPY REIAYJED BY THE WSPECTOR. •USE A SEPARATE SHEET TO List SI(ETCH OR EXTEND REMAIN CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 E GIN �ERING CONSTRUCTION REPORTT - Weather r - Contractor /`BDIcS (1J✓lct t—e Date _ 1C / Project No. .1000 " C Sunny O Rain Temp High Type of Work �(. Report No. O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity item 6 2 / w Q] . 11 /r It /Y // II H 310 /1 1, I' /1 310.2. 11 311 2 310.2 .1 /I 1 Ir T 7 FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No, Hrs. Equipment No. In Use Stand-by r N` o l TIME CHARGES Day Charged NO. CONTRACT 0 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS 6 USED NO. Project Site Conditions(Describe) Incidental items(Naives.Figs.,etc.) DAYS LEFT Q, 'r Description Location Remarks.Unusual Occuronces,Special Directions or reasons for non-performance Inspectoy& Supervisor Contractor INSTRUCTIONS: INSPECTOR SHALL MAKE REPORTS W TRIPLICATE EACH DAY BEGWMNG MATH REPORT NO.I AND PUMING CONSEC LY H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR MO PINK COPY RETAINED BY THE I SPECTOR. •ISE A SEPARATE SHEET TO LST SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281.471.5020 GIN RING CONSTRUCTION REPORT S I_ Job�a ontroctor tfltck c LOn c p', /f Date Project No. Weather unny O Rain Temp High Type of Work :4 Report No. O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item 92 ; s g . 1 2 rr < 0 7 . S 310 F� . 0 rR Fn 3102 a r Fr Fr / 3 1 S " r 2O. 31O rE it Ir - II i / . 9 2 O0 u r rr 71 . 0 FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by r g r✓. TIME CHARGES Day Charged NO. O CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS 37 USED NO. /., Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS 5 LEFT Description Location Remarks Unusual Occurances•Special Directions or reasons for non-performance Inspector Supervisor Contractor NSRRUCROG: tGWTOR$HAIL MAKE REPORTS N TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AID RUNNING COHSE H THE JOB. WHRE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PV&COPY RELINED BY THE INSPECT •USE A SEPARATE SHEET TO LEE SKETCH OR EXrE D REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ',fJ ` //�� TELEPHONE NE 281-471,5020 GPING CONSTRUCTION REPORT JaKd�`114 4l e % //t-,3 e cftontroctar /00 kS CCO C✓f t Date 7//7/0/ Project No.2000— SOI psunny O P' High Type of work CO✓l C-. Report No. 19'2- Weather O Ckwdy O Dry Temp .Low Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES // Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by L rb Fr f TIME CHARGES Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFTFc r Description Location Remarks Unusual Occurances Special Directions or reasons for non-performance G Inspector/SL_f Supervisor Contractor NSIRIICTON5: NSPECTOR SHALL MANE REPORTS N TRIPLICATE EACH DAY BEGNNNG WIM REPORT NO,I MO RUNNNG CONSEC Y H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE NSPECT •TAE A SEPARATE SHEET TO USE SKETCH OR EMEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /� TELEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job ) 5L n Contractor I'00 k≤ ( tr, ttO Date 7 Project No. ≤O( unny ❑Rain High Type of Work �,eMG - Re rt No.�� Weather - O Cloudy 0 Dry Temp Low Pw' Location Description or Comments(Station,etc.) Quantity Item __ ( RU __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs, Equipment No, In Use Stand-by TIME CHARGES DoyCharged NO. 90 CONTRACT 0 Day Not Charged DAYS Reason for Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance µ Inspector Supervisor Contractor N57FUCTnc: INSPECTOR SMALL MAKE REPORTS N WIPUCNE EACH DAY BEGINNING YAM REPORT NO.I AND RUNNING CONSEC t H TIE JOB. WHITE COPY FOR aFFICE.FELLOW COPY FOP CONTRACTOR AND PINK COPY RE4NED BY THE 1APECTOR. •LISE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS- CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /(/J /TELEPHONE 261-471-5020 ENGINEERING CONSTRUCTION REPORT Job v S Contractor ibakS (1>ne/etr Date O Project No. —7 unny Weather 0 Rain Temp High Type of Work S..O Y C . Report No. 0 Cloudy Cl Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. �1 Not Charged DAYS % I USED NO. Project Site Conditions(Describe) Incidental Items(Valves Ftgs.,etc.) DAYS LEFT Description Location Remarks Unusual Occurances.Special Directions or reasons for nonperformance Inspector /' Supervisor Contractor WBIRUCTDNS: INSPECTOR SHALL MATE REPORTS W TRIPLICATE EACH DAY BEGINNING WITH REPORT Na.1 AID RI1Hr1W(s COHSE LY T} O1KH THE JOB. WHITE COPY FOR OFFICE FELLOW COPY FOR CONTRACTOR AND PINX COPY RFTANED BY THE WSPECr •TAE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS CITY OF LA PORTE P.O.BOX1115 LA PORTE,TEXAS 77572-1115 /' �� J 1 TELEPHONE 281-471-5020 GINEERING CONSTRUCTION REPORT ��[! Job( J *7 IN 4dr ontractor tr kS 1.O11 C4 ?f-'8 /Date 7/23(1OProject No. ,1/ LEI Sunny O Rain High Type of Work Vi/�C , Report No. Weottler O Cloudy O Dry Temp LOW Pw' Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. O CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS Z USED NO. Project Site Conditions(Describe) Incidental Items(Wtves.Ftgs.,etc.) DAYS LEFT 'r Description Location Remarks,Unusual Occurances.Speed Directions or reasons for non-performance 0 Inspector don Supervisor Contractor NSIRUC11CM: INSPECTOR SAE MARE REPORTS IN TRIPLICATE EACH DAY BEGWNNG WIM REPORT NO.1 AID RUNANG C LY THROUGH THE JO& WHITE COPY FOR OFFICE YEUOW COPY FOR CONTRACTOR AND HIM COPYRETM*D BY TIE INSPECTOR •THE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMMl6 • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 ENGINES ING CONSTRUCTION REPORT Job��Wide sew Pr1,3err contractor l3rookS `iu1t8 Dare �ProlectNo.21JGb - O/ ❑Rain High Weather Temp Type of Work ( i.6 YI C. Report No. � O Cloudy ❑Dry Low Pa)'' Location Description or Comments(Station,etc.) Quantity Item l0. S1 MO c. S !q Z ,/ 219'.S / „ 2 /( // „ ,/ (/ r It j c7 I J ii „ ll r t r f rt + N // U / 0. VLl FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES trDay Charged NO. CONTRACT O O Day Not Charged DAYS Reason for NO. 4 Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances Special Directions or reasons for non-performance O Inspector,! Supervisor Contractor WCIRUCDDFA: NSPECTOR SHALL MAKE REPORTS N TRIPLICATE EACH DAY BEGNICIG WRN REPORT NO.I AND RUNNNG CONSEC g1GH THE JOB. WHITE COPY FOR OFFICE YELLOW COW FOR CONTRACTOR AND PINK COPY RETANED BY THE NSPEC •RAE A SEPMAIE SHEET TO USE 9ETCH OR EXTDC REMARKS• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572.1115 �,///J "C TELEPHONE 281-471-5020 ENGINES NG CONSTRUCTIONREPORT Jot�`7r'V Y✓/vC /!n1 p0�fuL;ontractor ��(- nZ-(`tL Date � Project No..20OO — 'I ySO� Weather o'Sunny O Rain Temp High Type of Work COIL t_ Report No.�Z O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity item 2 sz 5 Z Z it Fr � ( t/ r( 222 „ U U Y( w - eb .G 3 Ufc . E u arr II )/ fi WQ 3 E ., (N F( FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance e a / Inspector Supervisor Contractor I NTRUCTIN5: NSPECTOR SHALL MANE REPORTS N TRIPLICATE EACH DAY BEGNNNG WRH REPORT NO.I AND RUNNING coME ,tLvn4sH THE JOB. WHITE COPY FOR OFRCE.YELLOW COPY FOR CONTRACTOR AND PPM COPY REWNED BY THE POE C1 . •USE A SEPARATE STFET TO USE 9GTCH OR C(TE1D REMNEG CITY OF LA PORTE P.O.BOX 1115 LA PORTS TEXAS 77572-1115 /� TELEPHONE 281.471.5020 ENGINEERING CONSTRUCTION REPORT J tJi e <J % • C contractor/rot'/ Yl�/P //Date 7 3 i/o i/of Project No. 2LV0— Co I unny O Rain HIgh Type of Work 6 y",r - Report No. Weather Temp Cloudy p Dry Temp LOW Pay. Location Description or Comments(Station,etc.) Quantity Item af Jy,sp4( i4 . C. k. J F• LABORATORY ACTMTIES FORCE AND EQUIPMENT ON JOB Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by Cp9er I V r TIME CHARGES Day Charged NO. CONTRACT 9O O Day Not Charged DAYS Reason for NO. Not Charged DAB 0 USED NO. Project Site Conditions(Describe) Incidental Items(Valves Ftgs.,etc.) DAYS LEFT Description Location Remarks Unusual Occurances Special Directions or reasons for non-performance W G. Inspector , Supervisor Contractor I NTRUCTIONS: INSPECTOR SHALL MANE REPORTS W TRIPLICATE EACH DAY BEGINNING WITH REPORT NO,I AND RUNNRKG coP&cuu4uGH THE JOB. WHRE COPY FOR OFFICE YELLOW COPY FOR COMRACTCR AND PIN(COPY RELINED BY THE ICtCTCR. •LSE A SEPARATE SHEET TO LISL SKETCH OR O(IEND 1EMAWS• • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE281-471-5020 EN INEERING CONSTRUCTION REPORT Job(/T J S Contractor S (�YII�I'Yh4 Date Project No. ttD( Weather Vbnny O Rain High Type of Work CO/1 t Report No. O Cloudy O Dry Temp Low Pay' Location Description or Comments(Station,etc.) Quantity Item_________ALQ / FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES ' Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. O CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS ' USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFTFL r?i. Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance pk,Ioktorjt inspector_____________________________ Supervisor Contractor I STRUCTINS: INSPECTOR SHALL MAKE REPORTS IN T PLICATE EACH DAY BEGINNING YAM REPORT NO.I AND RUNNING COSEC L H 11E JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY REWNFD BY THE INSPECTOR. •USE A SEPARATE SHEET TO USL SKETCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 EN INE RING CONSTRUCTION REPORT � � 1 so/ Job�/ Wi/i!l�>`'V /W / i'b�oL4'COnfractor O�eO�< /�SYlcre/'f� /Date Project No.Temp ORain High Weather Type of Work Le J1 C.-.. 27 Report No. O Cloudy O Dry Low Pay' Location Description or Comments(Station,etc.) Quantity Item s O ' YI 'I // / / / 1 / , '7 . t L rr 1 . I LE rr rl rr rt rr 40qtr O r ' ' / / / . OLF O 3 " Q tt // '/ /s su L F FORCE AND EQUIPMENT ON JOB LABORATORY ACTTVRIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by t TIME CHARGES Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance &/ . ✓s Inspector Supervisor Contractor 16IRLCTIM: INSPECTOR SHALL MAKE REPORTS IN TI PUCNE EACH DAY BEGINNING WITH REPORT NO.I MO RUNNING CONSECUTIVELY H THE B. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PPB(COPY REUNSD BY THE INSPECTOR. -WE A SERN NE SHEET TO(AL SKETCH OR EXTEND REMARKS- CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 E GI EERINGCONSTRUCTIONREPORT Job s r �,QG1Contractor ne J S l�/1L/P/-B. Date 74/01 oject , Pr No. r7�-V ' s'Gny D Rain High Type of Work l�Y�-45 Report No. Weather D Cloudy D Dry, Temp LOW Pay' Location Description or Comments(Station,etc.) Quantity Item r 419/0 s ,o LF f/ ZC z // Tj LF r Z do, O LF FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by r TIME CHARGES Doy Charged NO. CONTRACT 90 ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS 3 USED NO. 7 Project Site Conditions(Describe) Incidental Items(VONes.Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance G(e w Inspector Supervisor Contractor W'TRUCrcN5: INSPECTOR SHALL MAO REPORTS IN TRPLCXE EACH DAY BEGINNWG WIN R:PORT NO.I AID Rulte1G caecrMw H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY REIANED BY THE ECTOR. •USE A SEPARATE SHEET TO USE 9QTCH OR MIND REMXd6- CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 Q TELEPHONE 281-471-5020 EN INE ING CONSTRUCTION REPORT Job ,% j /►C ontract« 1&'bok 6AC-f �° pare y 4( ProlecrNo. 2000 Weather D<nny O Rain Temp High Type of Work C C . Report No. zp I ❑Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity item f a ___ 7/ ___ __ ______ k2or __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. HIS. Equipment No. In Use Stand-by TIME CHARGES 0 Day Charged NO. VD CONTRACT 'I d ayNotCharged DAYS Reason for NO. - Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS '7 F LEFT Description Location Remarks.Unusual Occurances.Special Directions or reasons for nonperformance Inspector Supervisor Contractor YSIHUCTION5: R6PECTOR SHALL MAZE REPORTS Nl TRg1CAIE EACH DAY BEGWMNG WITH REPORT NO.I AND RUNNNG CONSE LY H THE JOB. WHITE COPY FOR OFFICE FELLOW COPY FOR CONnRACTOR AND PIW COPY RETAPCO BY THE WSPECTOR -USE A SEPARATE SHEET TO USE 9QTCH CR DTEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /I TELEPHONE 281-471-5020 E INEE ING CONSTRUCTION REPORT JobU' w'' 4 �[✓ PO T ew Contractor e00&5 Go'tp M ///Date Project No. OCV' �/ 6&nny O Rain High Weather Type of Work o s�G . Report No. ❑Ctoudy ❑Dry Temp Low Pay' Location Description or Comments(Station,etc.) Quantity Item tr'tc,rla 'V S 7. / IF Iioc. II rY I , // ,.I 9 ur, tr tl I( / r It // Lr r6 G.r. It tl I/ // tJ it ' r .ZSO L/: E.r. rt tT - / 1 Ii yr // 2q , S LJr #&r: ee / / r t / / r / r ' NøC.r, r It I , I t 2 . S 1-F $ ,r. /t tr / I rt tr 3.SLF FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No, Hrs, Equipment No. In Use Stand-by a £L.&pYr'acLL_V ___ TIME CHARGES B'Doy Charged NO. CONTRACT 90 ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT r Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance co W C s Fleer or) Inspector/LY Supervisor Contractor INSTRUCTIONS INSPECTOR SHALL MAKE REPORTS N 1RIPICCAXE EACH DAY BEGNNNG WITH REPORT NO.I AND RUNNING caiccu1 IH75i4 to. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACT R AND PINT(COW REUINED BY THE NSPECTOR. •IRE A SEPARATE SHEET TO 115E 9QTCH OR EXTEND REMAIM CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572.1115 TELEPHONE 281-471-5020 ENGINE ING CONSTRUCTION 'R7E�P,ORTT � Jo • f Contractor LS rock S I. YIC G t? Date Project No.��" j nny Ra C Weather in High Temp Type of Work ___ Report No. O Cloudy ❑Dry Low Pay. Location Description or Comments(Staflon,etc.) Quantity item _ ____ I _ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No, In Use Stand-by Zahinrs ___ __ ______ __ ____ TIME CHARGES Day Charged NO. - CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental items(' We Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Inspector eQM Supervisor Contract WSRRUCTDN5: INSPECTOR SHALL MME REPORTS N TWNDNE EACH DAY BEGNNRRG W TH REPORT NO.I AND RUNNNG C ' gc1Kaa1 RE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR MD PINK COPY REWNED BY TFE tE9tW. •USE A SEPARATE SHEET TO uSE STFTCH OR D(TEtD REMAW6 • CITY OF LA PORTE P.O.BOX 1115 LA PORTE.TEXAS 77572-1115 , TELEPHONE 281-471-5020 EN INEE GCONSTRUCTIONREPORT JP4fry Z D, ,contractor /,D/`AO k c r nn ft Date 7 7 Protect No. 5// unny O Rain� High Type of Work (�n C Report No. Weather O Cloudy C Dry Temp Low Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Charged NO. CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Protect Site Conditions(Describe) Incidental Items(WNes.Figs.,etc.) DAYS LEFT 13-r Description Location Remarks Unusual Occurances,Special Directions or reasons for nonperformance Inspector Supervisor Contractor NSIRUCIIDF6: INSPECTOR$MALL MAIE REPORTS W ITdPI1CAlE EACH DAY BEGINNING WIN REPORT NO.I AND RUMRIG cotGctw H THE JOB. WMRE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COW RETAINED BV 711E WSPECr .. -ESE A SEPARATE SHEET TO LEE SUCH OR EXEEFD REMAPoG • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 T E LE P H O N E 281-4715020 ENGINEING CONSTRUCTION REPORT 6• ix4 J � � Contractor CS 2OkS ! i�/lc- Ce e Date 7/20 Project No. N C!SO Q's O Rain High Type of Work Report No. WeatherrO Cloudy O Dry Temp LOW Pw' Location - Description or Comments(Station,etc.) Quantity Item _ ___ 'V _ ___ ________ 0 O '_k ___ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No, Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remark&Unusual Occurances,Special Directions or reasons for non-performance Inspector, /_'! Supervisor Contractor WSIRUCIDN5: INSPECTOR SIWS MARE PORS W IWPUCAIE EACH DAY BEGWMNG WTM REPORT NO.I AID RUNMNG COICátLY H THE JOB. W/BIE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AID PINK COPY REWED BY THE WSPE . •USE A SEPARATE SHEET TO USE SKETCH OR DDEID REMARKS .. _ ' CITY OF LA PORTE _ P.O.BOX 1115 LA PORTE,TEXAS 77572.1115 ` n TELEPHONE 281-471-5020 ENGINE RING CONSTRUCTION RREEPOORT JLob i _ ( f/M) I-rosectontroctor e,- &c �nc/GJf'6 Date 7,42,4/ ProjectNo.2 —�/<6/ Weather tr�unny O Rain Temp High Type of Work c. Re rt No. J2 Po ❑Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item troije ' ` S FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Q'Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves Ftgs.,etc.) DAYS LEFT Description Location Remarks Unusual Occurances Special Directions or reasons for non-performance J s r . C. Inspectors Supervisor Contractor INSRNCTIONS: MKCTOR 9IALL MAID fEPOFM W WIPUCAYE EACH on BEGWNNG WITH FEPa n NO.I AND RUNG CONSEC I H THE JOB. WHRE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PN(COPY REUWED BY THE INSPECTOR •11%A SEPARATE SHEET TO USL SCTCH OR EXIEN)REMARIG• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1)15 a I 0 TELEPHONE 281-4715020 ENGINEERING CONSTRUCTION REPORT JotLTrty NI d e %N If eject Contractor ro4c c A e tomDate9-2/-0( Protect No. �OO-410t p nny ❑Rain High Type of Work 4�O r. Report No. $O Weather ❑Cloudy 00w Temp Low Pay. Location Description or Comments(Station,etc.) Quantity Item If II rr a . 3 rl 3 , I /N 3 a r j1 II Q . 3 /1 11 11 I se.. . 3 Dover 3 N1 r4 a . 3 S I, It der 4 Ir [f . rvs .. e ' GEC • r o• q FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by TIME CHARGES 0 Day Charged NO. CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO, Project Site Cor diflons(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occuronces.Special Directions or reasons for non-performance Inspector ___'v Supervisor Contractor RGTRUCIgl6: INSPECTOR SHALL MAKE REPORTS N TMPU LATE EACH DAY BEGRNNNG WITH REPORT NO.I AND RUNMNG CONSECUMELY THROUGH RH AOe. WHITE COPY FOR OFFICE FELLOW COPY roR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECTOR •USE A SEPARATE SHEET TO UST SKETCH OR EXTEND REMARKS• • CITY OF LA PORTE P.O. BOX 1115 LA PORTE,TEXAS 77572-1115 t S.! ��n TELEPHONE 281-471-5020 E IN ERING CONSTRUCTION REPORT /' 1 Job( ,.+v IV��I[ ContractorILLA S �r(P_ f'P Date ProjectNo. z — 22/ i SSunny O Raln High Weather Temp Type of Work `ir�✓l( . Report No. �� ❑Cloudy Dory LOW Pw' Location Description or Comments(Station.etc.) Quantity Item brag S ' s 6 Cr " G FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by r ✓ r i I TIME CHARGES Day Charged NO. CONTRACT 90 O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental items(Valdes,Ftgs.,etc.) DAYS LEFT Description Location Remarks Unusual Occurances,Special Directions or reasons for non-performance C. 62—c. Inspector Supervisor Contractor WIPI1CfgN5: INFECTOR SHALL MAKE REPORTS W IILPOCATE EACH DAY BEGWNING YAM REPORT NO.I AND RUNNING CONEC Y THE JOe. WHUE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECTOR •TAE A SEPARATE *ET TO Wt SKETCH OR E%IEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ����// 1 n !L/� TELEPHONE I� 281-471-5020 $/oGINEEERING CONSTRUCTION REPORT Jo 'h! Mk Yro pl�Coniractor groy ^-5 (.OYI LI'E Date Project No. Q'Sfunny Weather Temp Roln High Type of Work ✓l L Report No. O Cloudy Dory Temp Low Pw' Location Description or Comments(Station,etc.) Quantity Item fl 5&v 3 0 fI ff " tf fF O If /f // r F // /, if f/ /S5 FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Standby i so l TIME CHARGES Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS O USED NO. Project Site Conditions(Describe) Incidental Items(Valves Figs.,etc.) DAYS LEFT Description Location Remarks Unusual Occurances Special Directions or reasons for non-performance d Inspector Supervisor Contractor ISTRUCTIONS: INSPECTOR%ML ALINE REPOTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUHIMN(i CONSECUfNELY JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE MPECTOR. •USE A SEPARATE SHEET TO LSL WICH OR EXIEID REMARIG • CITY OF LA PORTE - P.O. BOX 1115 LA PORTE,TEXAS 77572-1115 9q ���� �l./ 1ro yQn TELEPHONE 261-471-5020 E GI ERING CONSTRUCTION REPORT Job s/ �efrfi e'JG decfcontractor Brooks Cn/�Crtft /Date 3O ProjectNo. tunny a Ran High Type of Work 1A11 G. Report No. Weather O Cloudy ❑Dry Temp Low Pw' Location Description or Comments(Station,etc.) Quantity Item 922 r y' % y 3 30? 'V, O // /r ,r „ ,I , , of FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS 7 USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances,Special Directions or reasons for non-performance _____ _______ 7/ ___ Inspector Supervisor Contractor P61RLICTIM: INSPECTOR SXNL MAKE REPORTS N TRIPIICATE EACH DAY BEGINNING Will REPORT NO.I MD RUMRIG COHSE Y T ROUGH THE JOB. NMITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR MD PPM COPY RETAINED BY THE INSPECT •USE A SEPARATE SHEET TO Lt SKETCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 W / ��9 TELEPHONES 281-471-5020 EN TIN RING CONSTRUCTION REPORT Job t-// je jiJ!vA fe Contractor /tO0 k S (Cofl&t 'K Date 'T Project No. O Roln Weather Temp High Type of Work G , Report No. O Cloudy O Dry Low Pay' Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labs Force/Sub Cont. No. HIS. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT O O Day Not Charged DAYS Reason for NO. Not Charged DAYS Zia USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance Inspector (Z!=! Supervisor Contractor NSIGUCTIONS; INSPECTOR SHALL MAKE REPORTS N RLPUCATE EACH DAY BEGINNING WITH IEPOM NO.1 AM RUNNNG CONSECURM 1HR011GH THE a WARE CON'FOR OFFICE FELLOW COPY FOR CONTRACTOR AND vu COPY RETAINED BY THE INSPECTOR. •TAE A SEPARATE SHEET 10 Lt SKETCH OR MEND REMARC CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ��9 ] ���� /� TELEPHONE 281.4715020 ©EEN�GIINEEE�RING CONSTRUCTION REPORT Job6 f-/ W IOP / r a ief�'Contractor Lr48 C S (il✓ e— fete e Date O/b/tom! Project No. - Sunny O Rain High Weather Temp Type of Work L lut . Report No. O Curdy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item 6G aei.swv# 4" w (iona . s r r ' rl rr rr ,r „ . O • „ I Jr n If I fr I/ I !9 UFr It i . O I ar sp4 2. I Yr ,r FL It, rr go /! /I / V G OQ Liar (0 &k Of F, r! 7, It r' FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No, Hrs. Equipment No. In Use Stand-by TIME CHARGES _ Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves Figs.,etc.) DAYS LEFT D Description Location Remarks Unusuall�Occuronces Special Directions or reasons for non-performance Lfn/ r Inspector w" ' Supervkor Contractor MSirNC110M: INSPECTOR STALL MAKE REPORTS W MPLX;ATE EACH DAY BEGINNRIG WITH REPORT G.I AND RUNNWG CONSECUTIVELY THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK CORY REIARIED BY THE r5PECIOR. -TAE A SEPARATE SREETTO LEE SKETCH OR EXTEND MARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 �� TELEPHONE 281-471.5020 ENGINEERING CONSTRUCTION REPORT Job W Te r.troctor �f019 M tt 9/7/of Dote 97 Project No. — unny O Rain High S Weather Temp Type of Work (,n✓1 Report No. O Cloudy O Dry Low Pay' Location Description or Comments(Station,etc.) Quantity item / l4 G. s '/ 7 I /I J K /r l r /r / ' I I' ! I ft /r / ' Ir N '1 /r I f I r I I It S(v2S t l t t I ' 1 /I r / Ir rI it 000 11 . ? /3 !' lr 7.25 r1 rr /r tt 7 r t .t J I ifii 100e9 Ir rt cr rI rl FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by I TIME CHARGES Day Charged NO. CONTRACT 1] Day Not Charged DAYS IC Reason for NO. Not Charged - DAYS / USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance f Inspector SupeMsor Contractor ICTRUCIloIC: INSPECTOR SHALL MAKE REPORTS IN TRIPLICATE EACH DAY BEGWNWG WITH REPORT NO.I MD RUNMNG CONSECUWELY H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RELATED BY TIE INSPECTOR. •LEA PMATE SHEET TO LEE SKETCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 2281-471,5020 ENGINEERING CONSTRUCTION R, j,EP�OR�T� Job` S Fn,• cr Contractor / 7raOkc 4�011G twe Date / Project Na.No . �/ unny O Raln High Weather Temp Type of Work (CO/IC. Report No. icçg D Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item 2 r / / C r• r/ of 11 It // /70/ ll 3 !7 /r IF /I / I 11 l/ I/ 11 6. 6 Crtsfr �4 ' / Il L/ 111 2. /r IF 7/ It Ir it / I r 2 jvrt s /t / P It /I If It (. 8 rbi Cregt iD If Ir r tr FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by ≤yceruicoc TIME CHARGES Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. 3 Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT _ Description Location Remarks Unusual Occurances,Special Directions or reasons for non-performance four I ✓ . tc-. Inspector{1 Supervisor Contractor P87RUCTCN5: INSPECTOR SHALL MANE REPORTS N TIdRXCATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING COFCECUTML H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECTOR. •USE A SEPARATE SHEET TO LLSE SKETCH OR E%TEND REMAIN• CITY OF LA PORTE P.O.BOX 1115 lA PORTE,TEXAS 7 7572-1 1 15 TELEPHONE 281-471-5020 �,E7NNGJNEERING CONSTRUCTION REPORT JobA A� S /'ncect Contractor books 61^e- 62 Date ` r! Project No.IXO' OSunny Rain ig 6D Weather Temp Hh Type of Work CTC/l_G . Report No. O Cloudy ❑Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item / 5 FT n " " CX 2 So 2 k !OO D l 2 Wills CMPk. 71S • 7 zs CS n rr 31 £ 7 z FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Lobo Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO.CONTRACT 13 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Votves,Figs.,etc.) DAYS LEFT Description Location Remark Unusual Occuronces,Special Directions or reasons for non-performance Inspector Q - Supervisor Contractor INSRNCTIONS: INSPECTOR SHALL MAKE REPORTS N TRIPICATE EACH DAY BEGINMG WTIH REPORT NO.I AND RUNNING CONSECUTIVELY THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAWED BY THE INSPECTOR. •WE A SEPARATE SHET TO USE PETCH OR EXTEND REMARKS• - • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 E INE RING CONSTRUCTION REPORT Jot`-t.v wiJ'. Sl / rojecrContractor aro0k E2 s (D✓l.Lcerf Date //o/o Project No. - 4<unny O Rain High Type of Work Go hC , Report No. V!/ Weather O Cloudy O Dry Temp LOW Pay. Location Description or Comments(Station,etc.) Quantity Item cut Ak '7g4 G F Ga 93 �� 9 .. I ti it yl19 1 w FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by Lobo r TIME CHARGES Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Vahres Ftgs.,etc.) DAYS LEFT ; Description Location Remarks.Unusual Occuronces,Special Direction or reasons for ran-performance C � . - s-(rw�O Inspector /__ Supervisor Contractor ►SIRuclvN5: INSPECTOR SHALL MAKE REPORTS N WIPUCAIE EACH DAY BEGINNNG WITH REPORT M.I AM RUNMNG CONSECUTIVELY THROUGH THE JOEL YMRE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY REWNED BY THE NSPECTOR. •USE A SEPARATE SHEET TO USE SKETCH OR E%TEM REMARIG• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 �� TELEPHONE 2//81.471.5020 E GIN RING CONSTRUCTION REPORT �p Jo & 'Ahdj! 4n r ectContraCtor 6 roo fk c ( _OrR t rC Date Prgecf No.20tO f�D� of Sunny 0 Roln Temp High Type of Work <�/� WeatherG . Report No. O Cloudy ❑Dry Low Nam Location Description or Comments(Station,etc.) Quantity FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES 9'Day Charged NO. CONTRACT 6 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT C f- Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Inspector z5 Supervisor Contractor ICTPUCTIO1C: INSPECTOR SMALL MANE REPORTS W TRIPLICATE EACH DAY BEGWNNG WITH REPORT NO.I AND RUNNNG CONSECUTNELY THROW H THE O. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AM PW(COPY REWHED BY THE WSPECQOR •USE A IATE SHEET TO UST BIQTCH OR EXTEND REMAINS• • CITY OF LA PORTE - P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 Md . �, 1 y TELEPHONE_ 281-4715020 ,QE GIN ERING CONSTRUCTIONNREPORT[�/l� JObI„gTFI/ „�i d G I Contractor 8r[�KS LOVY C✓o f'e Date v � I Project No.�` CO —/�/ �y ❑Rain High Type of Work �nG . Report No. ` 37 Weather Temp Po O Cloudy ❑Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item _______ / ' o __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. nqo O Day Not Charged DAYS �ACT l Reason for NO Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT ` Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance •n r Inspector(__ Supervisor Contractor I6NUCIgn6: HSPECTOR SHALL MAZE REPORTS N IIIPUCAIE EACH DAY BEGNNNG WIN REPORT NO.1 AND INNING COICECUIIVELY THROUGH THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR C0NTRACiOR AND PIN(COPY RETANEO BY DIE MPECTOR. •TAE A SEPARATE SHEET TO USE$RETCH OR MEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 �/ TELEPHONE 281-471-5020 E GPING CONSTRUCTION REPORT Job 't s /S contractor r oo k 5 L 28 e re to We 9/17/c! Project No. 20190 4cci vg;jnny O Rain High Weather Temp Type of Work (. 4✓\C• Report No. O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item _ ___ _Al__() _ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by �"r TIME CHARGES Day Charged NO. (� CONTRACT 0 Day Not Charged DAYS Reason for NO Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT pC•r Description Location Remarks,Unusual Occurances.Special Directions or reasons for non-performance � - u Inspector J9/ L Supervisor Contractor V4'INUCTKM: INSPECTOR SXAIL WAIT REPORTS W REPLICATE EACH DAY BEGWMNG WIM REPORT NO I MD RUMING CONSECUMELY TNTOUGH THE JOB, WINE copy FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PW COW RETAWED BY THE WSPECTOR. -IRE A SEPARATE SHEET TO LSL SQTCH OR EXEC REMAW CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 /�J/ TELEPHONE 281.471-5020 NG NEERING CONSTRUCTION REPORT J K s ontractor €rlsl cfrs Cc rete Date //�8 D Project No. 0Q-7$6/ Donny O Rain High Weather Temp Type of Work C.81I'`l Report No. O Cloudy O Dry Low Pay. Location - Description or Comments(Station,etc.) Quantity item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. His, Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT �0 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS 6 3 USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS 27 LEFT n r Description Location Remarla,Unusual Occurances.Special Directions or reasons for non-performance Inspector Supervisor Contractor ICIRUCTIOW: INSPECTOR SHAU.MAKE REPORTS N TRIPLICATE EACH DAY BEGNNNG WITH REPORT NO.I AND RUNNNG CONSECUTIVELY H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPYREWNED BY THE NSPECTOR. -USE A SEPARATE SHEET TO USt SKETCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX1115 LA PORTE,TEXAS 77572-1115 , I TELEPHONEE..281-471.5020 ENGI EERING CONSTRUCTION REPORT /� Jol'f�rFyIAA e 7 I- 'CCi' Contractor SrOOt LO/IGR 1-e Date ____ProjectNo.22?e-VSOl T y Rain Hlgh Type of Work 6 p l C. Report No. 1 6 Weather Temp O Cloudy O Dry LOW Pay' Location Description or Comments(Station,etc.) Quantity Item 0 w . 9 A-ckyr'e if � r YF iY ii Fi 2 21`, /r L / r 7r YI 20 32 IT H Hit ' 1 3S /S rI rl fF �r lI 3 • 0 It /l !I /' 95 FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by S TIME CHARGES Day Charged NO. CONTRACT qD 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(VONes,Ftgs.,etc.) DAYS LEFT &• Description Location Remarks Unusual Occurances.Special Directions or reasons for non-performance 1t00k G :ems Inspector 4$ SupeMsor Contractor PSIRUCTIOM: INSPECTOR SHALL MAKE REPORTS N TWUCNE EACH DAY BEGINNING WITH REPORT NO.I ND RUNNNG CONSECUTIVELY H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR ND PRIX COPY REWNED BY 1W NSPECTOR. •TAE A PMATE SHEET TO TAE SKETCH OR EXTEND REMNB6 CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 ', • /�mTEEL'EPHOONE 281-471-5020 E GINE ING CONSTRUCTION REPORT I Jo •F �'v s Contractor Aok≤ CAr\c re+-C Date / Project No. Zooc� Sunny Rain High T 6010 . Weather Temp Type of Work Report No.___U ______ O Cloudy O Dry LOW Pay. Location Description or Comments(Station,etc.) Quantity Item __ / lay __ FORCE AND EQUIPMENT ON JO8 LABORATORY ACTMTIES Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by L4rerc TIME CHARGES Day Charged NO. CONTRACT O Day Not Char forged DAYS Reason ea urged NO Not . DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs..etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance o r- I l K Iectortf Supervisor • Contractor M RUCTIONS: INSPECTOR SHALL MAKE REPORTS IN TT PLICATE EACH DAY BEGINNNG WRH REPORT NO.I AND RUNMNG CONSEC LY H THE O. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PWK COPY WDUNED BY DE II NPECTOR. •TEE ASEPMATE SHEET TO L$t SKETCH OR EXIEFD REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572.1115 TELEPHONE 281.471.5020 ENGINEERING CONSTRUCTION REPORT ZJob C-i -,ki j M p, f'C k Contractor LW) Co,IC S r tf Date 02,4/ Project No. d o B'tunny O Rain High Type of Work 6r%_- Report No. Weather Temp O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item 2 82'M' C5 - II �_ 5 i12 23 f ' , / 8119 ff f / ,/ / 12. PoAGIE- 22/9 /r / f , if ' r 3 . 2. 32 f ( S f ' r ( r f S 8"IL/s ,r I I L ,( , I 2 l f L I l o.Y- o NL 94 G. AID 2 /' ' r�tl 4 II 'I '( 0. 3 32- 7 fl f1 FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs, Equipment No. In Use Stand-by TIME CHARGES V'Day Charged NO. O CONTRACT O Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental items(Valves,Figs.,etc.) DAYS LEFTr Description Location Remarks.Unusual Occurances,Special Directions or reasons for non-performance r , Inspector 1&n Supervisor Contractor Ic1RUCnIONS: INSPECTOR 9W1 MAKE REPORTS N IMPLICATE EACH DAY BEGINIING WITH REPORT NO.I APO RUWAW.CONSECUTIVELY THROUGH THE JOB. WHRE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOP AND PIN(COPY PENNED BY THE PG'ECTOR. •I.&A SEPARATE SHEET TO USE SKETCH OR EXTEND REMARKS- CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 11 /-4/1, /� TELEPHONE 281-471-5020 ENGINEERING CONSTRUCTION REPORT Job✓/�fly WiP/P fi'04 f Contractor Rcaak S 6iNc/L Date 2 O Project No. Weather �unny O Rain Temp High Type of Work (a,\r . Report No. /9 O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Rem ___ ________ / L10 Icy ___ __ 7 ___________ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by Ab TIME CHARGES Day Charged NO. qD CONTRACT 13 Day Not Charged DAYS Reason for NO. Not Charged DAYS 67 USED NO. 2-'3Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT �' Description Location Remarks Unusual Occurances,Special Directions or reasons for non-performance Inspector Supervisor Contractor ISIRUCIgN5: NSPI:CTOR SHHL W REPORTS N TRIPWATE EACH DAY BEGNNNG WITH REPORT NO.I AID RUNNING COlSEc YTMOUGH THE JOB. WHITE Cow FOR OFFICE YELLOW COPY FOR CONTRACTOR AID PINK COPY RETAINED BY THE INSPECTOR •USE A SEPARATE SHFET 10 USE SKETCH OR EXTEND REMARKS • CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 QQ& oje TELEPHONE 281-471.5020 E �GIINEERING CONSTRUCTION�REEPPOrIRT Jo S Contractor oo k c (1 is rpte Dote Prct No. �0 Sod Sunny O Rain High Weather Temp Type of Work Q r'\C Report No. 7O O Cloudy ❑Dry Low Pay, Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO, CONTRACT ❑ Day Not Charged DAYS Reason for NO. Not Charged DAYS 68 USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT r Description Location Remarks.Unusual Occuronces,Special Directions or reasons for non-performance G ✓� Inspector /1 SupeMsor Contractor NSIRUC 1ONS: INSPECTOR*IA 1L MAKE REPORTS N TdPUCAJE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING CONSECUMEL H THE JOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETARCO BY THE NSPECTO . •TAE A SEPARATE SHEET TO US[SKETCH OR EXIEFD REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 2288'1-471-5020 QE INE RING CONSTRUCTION �RREEPP�ORT �/!� Jo S COntrodor erHCAk S (n c T2E"e Dote v ZS ProjectNo. !-v^�O`T�"I O Sunny O Ro n High Weather Temp Type of Work Ca port No. O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item __ 7 t/tboek __ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMfIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT 0 KKDay Not Charged DAYS Reason for NO. Not Charged DAYS 9 USED NO, I Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances,Special Directions or reasons for non-performance ca- a a G Inspector IF Supervisor - Contractor INSTRUCfgW; INSPECTOR SHALL MAZE REPORTS N RBRICATE EACH DAY BEGINMNG WITH REPORT NO,I AND RUNNING CONSECUTIVELY H TIE Joe. WHITE COPY FOR OFFICE FELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECTOR. •USE A SEPARATE SHEET TO US[SKETCH OR F%TEND REMARKS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471-5020 E GINEE ING CONSTRUCTION REPORT /,L ' 1 r D I- /� '// Job CI�"ll �'V l)9 Z-`1 h ontractor Rrt1K S C,o✓\C n?-t-P Date 7_ Project No. 2000 4 b ❑Sunny R' Oin High / —7� Weather Temp Type of Work C�J�'L-[ Report No. O Cloudy ❑Dry Low Pw' Location Descriptlon or Comments(Station,etc.) Quantity Item __ ________g-27- o/ o4 ff - 3 / ___ FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. HIS. Equipment Na In Use Stand-by TIME CHARGES 0 Day Charged NO. —/ CONTRACT qv IR Day Not Charged DAYS Reason for NO. Not Charged DAYS G' USED NO. Project Site Conditions(Describe) Incidental Items(Valves.Figs.,etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance A)O Inspector s/fl Supervisor Contractor INSTRUCTIONS: INSPECTOR SHALL MANE(REPORTS W TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I MV RUNNING CONSECUIMELY THROUGH THE B. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE INSPECTOR. •TAE A SEPARATE SHEET TO(EL s ETCH OR EXTEND REMMIG CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 -• - '',,,kFff TELEPHONE II-- 281-471.5020 E GINEERING CONSTRUCTION REPORT JOY( j 1 Contractor r oO YC-S 2C_ 1`'�i Dote �Project No. —4'$O/ // ❑Sunny train HIgh Type of Work _ ✓l C . Report No. Weather 0 Cloudy Cl Dry Temp LOW Pay. Location Description or Comments(Station,etc.) Quantity Item FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES 0 Day Charged NO. CONTRACT 9/Day Not Charged DAYS Reason for NO. Q NotChorged DAYS 1 USED NO. rI Project Site Conditions(Describe) Incidental Items(Valves,Figs..etc.) DAYS LEFT Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Inspector (4 Supervisor Contractor _ NStRUCIJN5: INSPECTOR SHALL MAKE REPORTS N IIBPUCATE EACH DAY BEGNNNG W7IH REPORT NO.I AND RUNNWG CONSECUTIVELY 1I OuGH THE JOB. YMRE COPY FOR OFPICE YELLOW COPY FOR CONTRACTOR AND PRd(COP'RETANED BY THE NSPECTOR. •I.&ASEPARATE SHEET TO LLSL SKETCH OR EXTEND REMARKS ( CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 / TELEPHONE 2281.471-5020 EN INEERINGCONSTRUCTION�REPORT Jol{� S ' ,seonfractor to F—S L A✓11�1^P'f't Date _�� ProectNo. 260OI Weather O Sunny am n Temp High Type of Work (�:5A/t-. Report No. _____ _ O Cloudy ❑Dry LOW Pw' Location Description or Comments(Station,etc.) Quantity Item /A (; FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES 0 Day Charged NO. CONTRACT $(Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. �� Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT VL%Y\..` p Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Inspector kil Supervisor Contractor WSITNCIK)NS: IFSPFCTOR$M KE ALL MA REPORS W 1rPLICAT BE EACH DAY BEGWNWG Will IEPORT NO.I AND RUNNING CONSECUTIVELY H THE O. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PINK COPY REUWED BY THE INSPECTOR. •USE A SEPARATE SHEET TO Lt SETCH OR EXTEND REMARKS• CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 J /J TELEPHONE 281.47 1.5020 GI ERING CONSTRUCTION REPORT PrOi0G LStContractor n fel0kS nt Y'e tr. Date _ ____ Proect Na., ❑Sunny aln High Type of Work (tVI e:. Report No. ____< Weather Temp Cloudy O Dry Temp LOW Pay. Location Description or Comments(Station,etc.) - Quantity Item ___ __________9i' O / 7- 7- O/ __ _______ N____ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES O Day Charged NO. CONTRACT O VDay Not Charged DAYS Reason for NO. Not Charged DAYS ys USED NO. Project Site Conditions(Describe) Incidental Items(valves Ftgs.,etc.) DAYS 24 LEFT Description Location Remarks Unusual Occurances Special Directions or reasons for non-performance Inspector It Supervisor Contractor I SIRlICIENIS: INSPECTOR 9WL MAKE REPORTS IN TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AND RUNNING CONSECU1NELY THROUGH THE B. WARE COPY FOR OFFICE.YELLOW COPY FOR CONTRACTOR AND PRM COPY REtwD BY THE INSPECTOR -TAE A SEPARATE SHEET TO USL SIIFTCH OR EXTEND REMARXS CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 6 I, I TELEPHONE 281-471-5020 EN INE RING CONSTRUCTION REPORT �C/J Jobt1M-`' % 'fCt Contractor /f MOks [„n/1G/t--e Dote Project No. 2070-c Weather 1dSunny O Rain Temp High Type of Work C�G . Report No. O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item ______ / I_ __ ___ / IL/ C1 ___________ V ___ FORCE AND EQUIPMENT ON JOB LABORATORY ACTMTIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by TIME CHARGES p Day Charged NO. CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS 1 ' USED NO. '� Project Site Conditions(Describe) Incidental Items(Valves.Ftgs.,etc.) DAYS LEFT - WetDescription Location Remarks.Unusual Occurances,Special DIrections or reasons for non-performance s r Inspector /34 Supervisor Contractor VClRUCTOPC INSPECTOR SHALL MAKE REPORTS W TRIPLICATE EACH DAY BEGINNING WITH REPORT NO.I AID RUNNING col&cuThH THE JOB. mnE COP/FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PIN(COPY RETAINED BY THE INSPECTOR. -USE A SEPARATE SHEET TO USE SKETCH OR EXTEND REMAR1c CITY OF LA PORTE P.O.BOX 1115 LA PORTS TEXAS 77572-1115 TELEPHONE 281-471-5020 OE GIN ERINGCONSTRUCTION REPORT � Job(/r D A S/r✓ 1 raj ec t Contractor /Sr00 kS [in N G n tr � Date r �0 O/ Project No. �0N cot p�urny O Weather Rain Temp High Type of Work Report No. O Cloudy ❑Dry LOW Pay. Location Description or Comments(Station,etc.) Quantity Item pp ef" 2c o✓ /3 ii /r 2o9- 2p II it /r If rr 2."-/. 9 D /1 rf I' II it it 96_' 19t/7 I t II It r tH ,J 7 FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by bec ✓s 9 r I L11Z4 1 TIME CHARGES Day Charged NO. 90 CONTRACT 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS 7 USED C NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT / W r Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance Si J 6(eY. Inspector 6/-r Supervisor Contractor M47RUCipNS: INSPECTOR SHALL MAJE REPORTS W REPLICATE EACH DAY BEGKJNWG WIN REPORT NO.I AID RUNNNG CONSECUINELY THROUGH THE JOB. WHITE COPY FOR OFFICE FELLOW COPY FOR CONTRACTOR AND PINK COPY REWPCD BY THE INSPECTOR. •115E A SEPARATE SHEET TO USt SKETCH OR EKIEN)REMAR16 CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 1 /!n TELEPHONE 281-4715020 ENGINEERING CONSTRUCTIO N REPORT JohC,r•W k ;dl l'X e Contractor UfoOkl incy'te Date 9/fl/Ol Project No. o1 O Rain High Type of Work //-- _ Weather Temp Writ- Report No. O Cloudy O Dry LOW Pw' Location Description or Comments(Station,etc.) Quantity Item 2 ti _ rz /f `f' r' 20 2 yt n tt n Y � 1 2 bod MoS r1 rr r T � ei v p/`103 11 rr It if it S 2. 606k ≤ole I oe r1 i` n tt it FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES labor Force/Sub Cont. No. His, Equipment No. In Use Stand-by er ≤prvicor TIME CHARGES Day Charged NO, CONTRACT O 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS 7� USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Ftgs.,etc.) DAYS LEFT Description Location Remarks Unusual Occuronces,Special Directions or reasons for non-performance oo Inspector Iii Supervisor Contractor NSIRUCtOt5: YSPECTOR SHAT MAZE REPORTS N TRIPUCAE EACH DAY BEGINNING WIN REPORT NO.I AND MIMING CONSECUMEIY RROuGH THE JM WHITE CO%FOR OFFICE,YELLOW COPY FOR CONTRACTOR AND PINT(COPY PENNED BY THE NSPECTOR. •ICE A SEPARATE SHEET TO USI SIZCH OR EXTEND REMAMG- CITY OF LA PORTE P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 281-471.5020 ENGINEERING CONSTRUCTION REPORT Jol,4, %,Prp3 e&- Contractor OOL5 (1,.i care Date 9 O Project No. I miunny Weather 0 Rain Temp High Type of Work Cie Y'.C• Report No. 7'? O Cloudy O Dry Low Pay. Location Description or Comments(Station,etc.) Quantity Item 2 ' Sw FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES Labor Force/Sub Cont. No. Hrs. Equipment No. In Use Stand-by L<6erer TIME CHARGES Day Charged NO. CONTRACT q0 0 Day Not Charged DAYS Reason for NO. Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT / • Description Location Remarks,Unusual Occurances,Special Directions or reasons for non-performance N at ;r Cl Inspector /s Supervisor Contractor NSTRUCTINS: INSPECTOR SHALL MAKE REPORTS N TMPUCAIE EACH DAY BEGINNING WITH REPORT NO.I AND PInING CONSEC Y TROUGH THE JOB. WHITE COPY FOR OFF CE YELLOW COPY FOR CONTRACTOR AND PINK COPY RETAINED BY THE P&PECTOR. •TAE A SEPARATE SHEET TO KJSL 9FTCH OR EXTEND REMARKS • CITY OF LA PORTE - P.O.BOX 1115 LA PORTE,TEXAS 77572-1115 TELEPHONE 2281-4715020 ENGINEERING CONSTRUCTION REPORT Job l 7 / ✓ Contractor 8 oD K 5 n rI L/ OEt'B Date G D Project No. 2p0O Chf 9'S Jnny weather O Rain Temp 4 High Type of Work a rl G . Report No.2 O Cloudy O Dry Low Pay' Location Description or Comments(Staflon,etc.) Quantity Item 0 FORCE AND EQUIPMENT ON JOB LABORATORY ACTIVITIES - Labor Force/Sub Cont. No. His. Equipment No. In Use Stand-by TIME CHARGES Day Charged NO. CONTRACT O Day Not Charged DAYS Reason for NO Not Charged DAYS USED NO. Project Site Conditions(Describe) Incidental Items(Valves,Figs.,etc.) DAYS LEFT Description Location Remarks.Unusual Occurances.Special Directions or reasons for non-performance Inspector ___�/'! Supervisor Contractor IFSIRUCTIOS: INSPECTOR 9WL MAIQ REPORTS IN TRIPLICATE EACH DAY BEGINNNG YAIH REPORT NO.I AND RUNNING COFSEC THROUGH THE AOB. WHITE COPY FOR OFFICE YELLOW COPY FOR CONTRACTOR AND PIN(COPY RETAMIED BY THE I SPECTOR. •TEE A SEPARATE SHEET TO LEE SKETCH OR EXTEND REMARKS' CHANGE ORDER No. PROJECT: City-Wide Sidewalk DATEOFISSUANCE: Replacement Project9-5-01 OWNER: FY 2000 City of La Porte OWNER'S PROJECT NO. 2000-4501 604 West Fairmont Parkway La Porte, Texas 77571 CONTRACTOR: Brooks Concrete Allen Genoa Pasadena, TX 77504 CONTRACTFOR: $26 , 605. 60 You are hereby directed to make the following changes in the Contract Documents: Description: Various locations throughout the. City; increase quantities for : 1 Remove 555.9 LF @ $ 00/LF 2 Replace 543. 4 LF 10. 0 /LF 3 Wheelchair Ramps @ 225. 00 EA Purpose of Change Order. PA Increase the estimated quantities for removal , replacement, of 4 ' wide sidewalks and wheelchair ramps . Attachments: (List documents supporting change) CHANGE IN CONTRACT PRICE: CHANGE IN CONTRACT TIME: Original Contract Price Original Contract Time $ 26 , 605 . 60 90 days or date Previous Change Orders No._to No. Net change from previous Change Orders $ N/A N/A days Contract Price prior to this Change Order Contract time Prior to this Change Order $_26, 605 . 60 90 days or date Net Increase (Oeerease3 of this Change Order Net Increase (Decrease) of this Change Order $ 7 ,670. 80 0 days Contract Price with all approved Change Contract Time with all approved Change Orders Orders $ 34 , 276 . 40 90. days or date RECOMMENDED: APPROVED: APPROVED: by IC✓+ by by Engineer cJ Owner Contractor PAGE : 1 / 'RECEIVING REI ' R T % SHIP TO: P.O. NO. : C02006 DATE : 10/23/01 VENDOR: BAYSHORE SUN, THE VENDOR NO. 20520 DELIVER BY SHIP VIA F .O .B . 9/27/01 CONFIRM BY CONFIRM TO REQUISITIONED BY ANN MILLER FOR ADVERTISE GINGER SHAW CE PEGGY FREIGHT , CONTRACT NO. REQ. NO . REQ. DATE 10/23/01 LINE QUANTITY NO. RECEIVED UOM ITEM NO. AND DESCRIPTION UNIT COST 12 2 . 00 EA 270 010 90 . 9500 PRINTING/ADVERTISING ADVERTISING PL CITY-WIDE SIDEWALK REPLACEMENT BID NOTICE RECEIVED, BY: LEE, PEGGY RECEIVED DATE : 10/23/01 • The Bayshore St P.O. Box 1414 • La Porte,TX 77572-1414 Phone 281-471.1234 • Fax 281-4713763 10/08/2001 01100138-000 REMIT To: Peggy Lee 414 City of La Porte'Planning [7e P.O.BOX Texas arming pt. Le none,Taxes 77572-1414 604 W. Fainront Pkwy. La Porte, Tx. 77571 PLEASE RETURN TOP PORTION OF THIS STATEMENT WITH PAYMENT TERMS-NET 30 DAYS-ALL PAST DUE CHARGES SUBJECT TO SERVICE CHARGE 1'/•%PER MONTH.$1.00 MINIMUM I t„ � 04/11/01 CLP Project No. 2000-4501 f , ` 90.95 h «, 90.95 04/18/01 CLP Project No. 2000-4501 5 ^ 90.95 • - 181.90 05/13/01 CLP Project No. 2001-7101 � " 96.90 " , 278.80. 05/20/01 CL� Project No. 2001-7101 96.90 ° c ?. 375.70 . .' tia :7y •Y. \liJlCE FORWAi10 TOTAL PAYMENTS Y ADJUSTED MTE TOTALINCHES • � x . 375 70. _,f rvY v�t. Mi f ..fl •. _ r'l ,HanCowy,Thns The Bayshore Sun N M t 820 Soutli 8th Street 281-471-1234 La Porte, Texas 77571 ..�s Fax: 281-471-5763 E I$£�ek££ Fyz % Et ads xLL5 eF F x }; idmn ' y�- 'Serving The Bay chore Area Since 1947' City of La Porte County of Harris State of Texas Before me, the undersigned authority, on this date came and appeared Karolyn Kellogg, a duly authorized representative of The Bayshore Sun, a semi-weekly newspaper published and generally distributed in the City of La Porte, Harris County, Texas and who after being duly sworn, swears the attacheçl no ice was published in The Bayshore Sun dated /i 6 / Lr m'r Karolyn Kellogg Authorized Representative Sworn and subscribed before me this I ' N day of __ , 2001 Sandra E. Bumgarner Notary Public Harris County, Texas SANDRA E. BUMGARNER,k ` ±®b NOTARY PUBLIC,STATE OF TEXAS MY COMMISSION EXPIRES 'foF1E+ FEB. 19,2002 [Company, OTICE TO BIDDERS A.M. the Contract Documents. CLP Project p, I' 5. The City of La Porte No.2000-4501 _ 3. Interested contractors _ hereby notifies all bidders may obtain plans, specifi- that in regard to ahy { cation and necessary bid- Agreement entered Into Sealed bids, in dupli- -ding information at no cost pursuant to this advertise- on the original forms, from: ment, minority business d by an officer of the enterprise will be afforded and addressed equal opportunities to sub- to Martha Gillett, City Sec- CITY OF LA PORTE mit bids in response to this retary, City of La Porte, PLANNING invitation and will not be 604 W. Fairmont Parkway, DEPARTMENT discriminated against on P.O. Box 1115, La Porte, 604 W.'FAIRMONT the grounds of race, color, Texas 77572,-1115 will be i PARKWAY sex, age,•religion, or na- • received until :00'P.M., LA PORTE,TEXAS tional origin In considera. April 30,2Q01, r th con- 77571 - tion for an award, struction of! •(281)471.5020 ' l! 6.The Owners reserve the CITY OF LA PO E V4.E PROPOSAL shall right to reject any and all CITY-WIDE SIDE LK mpanied by a bids and to waive informal- PROJECT FY 2000-2001 check, or bid bond from a ambiguity or lack of clear- surety company licensed ness in stating the prices in the State of Texas in an in the bid, the Owner re- amount not less than five serves the right to consid- 2. Bidders are requested percent (5%) of #is total er the most advantageous 10 attend a pre-bid confer- amount bid; as guarantee construction thereof or to once to be held in the -that the successful bidder reject the bid. Council'.Chambers at City will enter Into a'Contradt .Parkway, La Porte, Texas, required, within ten (10) CITY OF LA PORTE Hall, 604• W. Fairmont and execute the Bond(s) if, _ April 23, 2001, at 10:00 days after the receipt of Martha Gillett 820 South 8th Street 281-471-1234 La Porte, Texas 77571 Fax: 281-471-5763 x"' xs Z f b 8}ps 'tg�k`y $� z ti E§,z, Eyr Gg G2 ithfl TRR AlS 'Serving The Bayshore Area Since 1947' City of La Porte County of Harris State of Texas Before me, the undersigned authority, on this date came and appeared Karolyn Kellogg, a duly authorized representative of The Bayshore Sun, a semi-weekly newspaper published and generally distributed in the City of La Porte, Harris County, Texas and who after being duly sworn, swears the attached notice was published in The Bayshore Sun dated______________ Karolyn Kellogg Authorized Representative Sworn and subscribed before me this I ' day of Q�e , , 2001 Sandra E. Bumgarner PJJJJ/rJIJ!!!!J!!!J!lrJW'� Notary Public .J % SANDRA E. BUMGARNER k Harris County, Texas NOTARY PUBLIC,STATE OF TEXAS MY COMMISSION EXPIRES• +r" (c* FEB. 19, 2002 C. r. THE BAYSHORE SUN-.t WEDNESDAY,APRIL 18,2001 •Page 5 struction or: n casnie�s check, certified serves the right to� d- \�fS check, or bid bond from a or,the most edvn jnus surety company licensed CITY OF LA PORTE in the State of Texas in an construction thereof-or to CITY-WIDE SIDEWALK amount not less than five reject the bid. REPLACEMENT percent (5%) of the total PROJECT FY 2000.2001 amount bid, as guarantee that the successful bidder will enter into a Contract CITY OF LA PORTE and execute the Bond(s) if Martha Gillett 2. Bidders are requested required, within ten (10) to attend a ore-bid confer- days after the receipt of once to be held in the the Contract Documents. - Council Chambers at City - Hall, 604 W. Fairmont Parkway, La Porte, Texas, April 23, 2001, at 10:00 A.M. 5. The City of La Porte hereby notifies all bidders that in regard to any Agreement entered into pursuant to this advertise- 3. Interested contractors ment, minority business may obtain plans, specifi- enterprise will be afforded -cation and necessary bid- equal opportunities to sub- TICE TO BIDDERS ding information at no cost mit bids in response to this i . ' from: invitation and will not be CLP Project discriminated against on No.2000501 the grounds of race, color, CITY OF LA PORTE sex, age, religion, or na- ' eM0NT NG tional origin in considers- ' ated bids, in pli- ENT Hon for an award. on the ongi o by an officer o the AV any, and addres ed - TEXAS rtha Gillett, Ci Sec- f City of La Porte, - 020 right to e Owners eject any ndtall .Fairmont Parkway, bids and to waive informal- ox 1115, La Porte, ities in bidding. In case of 77572,-1115 will be ambiguity or lack of clear- ed until 2:00 P.M., 4. Each PROPOSAL shall ness in stating theprices, 0,2001,for the con- be accompenietl by a- in the bid, the Owner re-r I ' City of La Porte Accounts Payable Check Requisition Vendor #: Due Date: Vendor : BROOKS CONCRETE, INC. 4018 ALLEN GENOA PASADENA TX 77504 You are required to attach receipts with all check requisitions. Description PAYMENT FOR CITY-WIDE SIDEWALK REPLACEMENT; PROJECT FY2000-2001,CLP NO. 2000-4501 Account# Project # Invoice S Commodity Date Amount$$ Code 01598927091100 999-999 7/17/01 7899.66 Total Amount Due: $ 7899.66 Remarks:SEE ATTACHED DETAIL Prepared By SHERRY JENNINGS Apprpyed By- y Date: Date7/17/01 Revised 8115197 APPLICATION AND CERTIFICATION FOR PAYMENT PROJECT: CITY-WIDE SIDEWALK REPLACEMENT TOTAL AMOUNT WORK DONE TO DATE: $8,777.40 PROJECT FY 2000-2001, CLP No. 2000-4501 ORIGINAL CONTRACT AMOUNT: $26,605.60 AMOUNT RETAINED (10%): $877.74 NET CHANGE BY CHANGE ORDERS: $0.00 PREVIOUS PAYMENTS: $0.00 REVISED CONTRACT AMOUNT: $26,605.60 TOTAL DEDUCTIONS: $877.74 OWNER: La Porte AMOUNT DUE CONTRACTOR: $7,899.66 City of 604 W FAIRMONT PARKWAY La Porte TX 77571 CONTRACTOR: ESTIMATE NO. 1 Brooks Concrete Inc. 4018 Allen Genoa Pasadena, Tx 77504 (713) 947-8448 CONTRACT DATE: 05/08/01 WORKING DAYS TO DATE: 20 CERTIFICATE OF THE CONTRACTOR OR HIS DULY AUTHORIZED REPRESENTATIVE To the best of my knowledge, I certify that all items, quantities and prices of work and materials shown on the face of the estimate are correct;that all work has been performed and materials supplied in full accordance with the terms and conditions of the corresponding construction contractual documents between the Owner and the Contractor, all changes authorized thereto;that the foregoing is a true and correct statement and of the contract amount up to and including the last day of the period covered by this estimate and that no part of the"AMOUNT DUE CONTRACTOR" has been revised. I further certify that all just and lawful bills against the above named Contractor, for labor, material and expendable equipment employed in the performance of said contract have been paid in full accorda ce with the contract requirements. DATE: BY: TITLE: 44 SIGNED and SWORN before me, a Notary Public in and for the State of Texas this t t0day of 20 tiNtiilR`I 8fi! RMNINGS BY: MY COMMISSION EXPIRES:___________________________ 01,42 ENGINEER'S CERTIFICATION FOR PAYMENT In accordance with the contract documents, based on on-site observations and the data comprising the above application, the Engineer certifies to the Owner that the quality of the Work is in accordance with the Contract Documents, and the Contractor is entitled to payment of the AMOUNT DUE CONT CTOR. BY: w DATE: PROJECT NAME: CITY-WIDE SIDEWALK REPLACEMENT PROJECT FY 2000-2001 PROJECT NUMBER CLP 2000-4501 CONTRACTOR: BROOKS CONCRETE INC DATE: 7/13/2001 Quantity Dollars Installed Installed Total This Previous Total Item Est. Unit Estimated This Previous Installed Period Periods Income No. Description of Work Oty. Unit Price Value Period Periods To Date Income Income To Date 1.0 CONCRETE SIDEWALK 1979.80 L.F. $ 2.00 $ 3,959.60 904.2 0 904.2 $ 1,608.40 $ - $ 1,808.40 REMOVAL COMPL IN PLACE) 2.0 4' WIDE CONCRETE SDWLK 1387.10 LF $ 10.00 $ 13,871.00 539.4 0 539.4 $ 5,394.00 $ - $ 5,394.00 • COMPLETE IN PLACE 3.0 WHEELCHAIR RAMPS 39.00 EA $ 225.00 $ 8,775.00 7 0 7 $ 1,575.00 $ - $ 1,575.00 4.0 EXTRA BANK SAND 0.00 TN $ 18.00 $ - 0 0 0 $ - $ - $ - 5.0 EXTRA SOD 0.00 SY $ 4.50 $ - 11111 0.00 $ - $ - $ 26,605.60 $ 8,777.40 $ - $ 8,777.40 CF L .4O A p ti 4 "u City of La Porte Accounts Payable Check Requisition Vendor #: Due Date: Vendor Name: Brooks Concrete 4018 Allen Genoa Pasadena,Texas 77504 (713) 947-8440 You are required to attach receipts with all check requisitions. Description: City-wide Sidewalk Replacement Project CLP Project 2000-4501 Account# Project# Invoice # Commodity Date Amount$$ Code 01598927091100 GEN709 2 8/9/01 11,422.44 Total Amount Due: $ 11422.44 Remarks; Invoice Attached Prepared By: Crystal Sco App ved By Date: Date: Au ust 21 2001 'Revised 8/15/97 • ots- 9 '91- 709 -/! QO APPLICATION AND CERTIFICATION FOR PAYMENT —_...._ PROJECT: Cit i4Me Sidewalk Re aernent Pro ed,FY 2000-2001 TOTAL AMOUNT WORK DONE TO DATE: S21,419.00 ORIGINAL CONTRACTAMOUNT: _ $26,605.60 AMOUNT RETAINED110%): 52,141.90 NET CHANGE BY CHANGE ORDERS: $0.00 PREVIOUS PAYMENTS: $7,854.66 REVISED CONTRACT AMOUNT_ $26,605.60 TOTAL DEDUCTIONS: $2,141.90 OiAW City Of La Pone AMOUNT DUE CONTRACTOR: 111,42244 PO Box I l l s La Porte, TX 775T2-1115 CONTRACT — ---Brooks Concrete ESTIMATE NO. 2 4018 Allen Genoa Pasadena, TX 77504 (713)947-8440 mL I CONTRACT DATE 5/812001 WORKING DAYS TO DATE: 50 CERTIFICATE OF THE CONTRACTOR OR IjIS DULYAUTHORLZE_pREPRESENTATIVE To the best of my knowledge,I certify that a0 items,quantities and prices of work and materials shown on the face of the estimate are correct that all work has been performed and materials supplied In IUD accordance with the terms and conditions of the corresponding construction contradual documents between the Owner and the Contractor,all changes authorized thereto:that the foregoing Is a true and corred statement and of the contract amount up to and including the lest day afthe period covered by this estimate and that no part of the AMOUNT DUE CONTRACTOR' has been revised. I further certify that all just end lawful bills against the above npted Contractor,for labor,material and expendable equipment employed In the performance of said contract have been paid in full the contract requirements. m DATE: BY —I—B� . �-:'� RHONDA FAY PIG..., m n� acco -- TITLE: , m� . SIGN d RN before me, Natery in and for the State of Texas Otis day of 2 8Y: _ M'YCOMMISSION f9CP1RES:1a--G_ � "` N- m ENGINEER'S CERTIFICATION FOR PAYMENT In accordance with the contract documents,based on on-site observations and the data comprising the above application,the Engineercertlfies to 0i the Owner that the qua Hy of the Work is in arz:ordance with the Contract Documents, and the Contractors entitled to payment of the AMOUNT DUE CONTRACTOR my N] BY- DATE: f, 9— p L m m m PROJECT NAME: CITY-WIDE SIDEWALK PROJECT 2000-2001 PROJECT NUMBER 2000-4501 CONTRACTOR: BROOKS CONCRETE DATE: 7-Aug-01 Quantity Dollars Installed Installed Total This Previous Total Item Est Unit Estimated This Previous Installed Period Periods Income No. Description of Work Qty. Unit Price Value Period Periods To Date Income Income To Date 1.0 REMOVAL OF SIDEWALK 1979.8 L.F. $ 2.00 $ 3,959.60 855.8 904.2 1760 $ 1,711.60 $ 1,808.40 $ 3,520.00 2.0 PLACEMENT OF SIDEWALK 1387.1 LF $ 10.00 $ 13,871.00 715.5 534.4 1249.9 $ 7,155.00 $ 5,344.00 $ 12,499.00 3.0 WHEELCHAIR RAMPS 39 EA $ 225.00 $ 8,775.00 17 7 24 $ 3,825.00 $ 1,575.00 $ 5,400.00 4.0 0 EA. $ - $ - 0 0 0 $ - $ - $ - $ 26,605.60 $ 12,691.60 $ 8,727.40 $ 21,419.00 .2 ti T�zM city of La Porte Accounts Payable Check Requisition Vendor #: Due Date: Vendor Name: Brooks Concrete 4018 Allen Genoa Pasadena,TX 77504 Yop are required to attach receipts with all check requisitions. Description: City-Wide Sidewalk Repair and Replacement Project—CLP #2000-4501 Construction Account # Project # Invoice # Commodity Date Amount $$ Code 01598927091100 GEN709 Pay App. #3 9-19-01 $9,122.04 Total Amount Due: $ $9,122.04 Remarks: Prepared By: Peggy Lee APPro ed By: Date: Revised 8/15/97 N � APPLICATION AND CERTIFICATION FOR PAYMENT PO.tEC7`- C ymide Sidewalk Repkoeroerd Proied,FY 20062001 TOTAL AktOUNT ytIORK DONE TU__GKTE 571554.60 520605.60 AMOUNTRETAINEf.',1d'61_ 5155.46 (il NETC-ALC0NT CHAT YJUNT: - ----- --- $19.277.10 NET Ci_APY�E BY CHANGE OROER5 _____ . P17J=1110US PAY.---.S: TOTAL US3UC•lONb S3.155.4b ISEL COMTRACT AWUNT: -- ovmem AMOUNT DUE c0RT.^AC Yx= Sq'122 04 Cap a fLa Porte PO t6rx 1115 — La POttu.TX 77517-11t5 Od C 04TRAc-0Rc ESTATENO. 3 Erteom concrote 3 — 401sAIiencerrca Pasadena,TX 77504 (113)967-8440 — ..—. ----- —_ CONTRACT DATE 546/2001 V RKPK,fl WO O[WTF 74 CE C KATE OF THE CONTRACTOR OR HIS To the best of Irri knowledge.I entity That al term.gnanti£ies and prices ofwork and r as elpwn Cl Ilhc face Ofthe estimate are coned:that a4 wol'Y hssbeen performed mid materials rape ed h 1111 aemrt$nrb with the terms esd rardilialu it the cvrtespaldap^ortstrnc0on contractual dncutnt5 between and stihe con7atl agent up tMand trx n4 the test day of the period covered Ws es&mle and that Ib arts 01ae ANAOUNT DUE CONTRACTOR' has has bce'trevised. I katlter sect that aY utsf and lawful bin aga'ahst the above named Contrador,for tabor,nit krfai 9nf r ps rtle a artlpnMlt.r-ptyed in 0 c pedocmnoe of raid contract have been pall In AriYforl"he Ith the contract requkesrmAx my DATE Wt— r` om u A uem SIGNED and SW ORN before me,a Notary.Putttate of Texas thfl_J Z-_ _ t°p o' 2�n t' ja d Tep� � kIY(pe EX hY9S4S10u1 'IR3: 1� fr�0►G616-001: .ti3 C ENGINEER'S CEA'TiFICATION FOR PAYMENT In aax lydancev:tth Cie ttrrtrad docrMrGnl1,based on OtrslTe obsuvalions and the data cump.l3leg I to ah+ve ipp.iaffon.the Engineerce mprtlIes 10 the ownerthatithe c$0aMy of the LVork h in accordance w0h The Contract Documents,and the Contractor is entdrx to payment of the AMOUNT r DUE CONTRACTOR. Fm PROJECT NAME: CITY-WIDE SIDEWALK PROJECT 2000-2001 PROJECT NUMBER 2000-4501 CONTRACTOR: BROOKS CONCRETE DATE: 19-Sep-01 Quantity Dollars Installed Installed Total This Previous Total Item Est Unit Estimated This Previous Installed Period Periods Income No. Description of Work Qty. Unit Price Value Period Periods To Date Income Income To Date 1.0 REMOVAL OF SIDEWALK 1979.8 L.F. $ 2.00 $ 3,959.60 764.8 1760 2524.8 $ 1,529.60 $ 3,520.00 $ 5,049.60 2.0 PLACEMENT OF SIDEWALK 1387.1 LF $ 10.00 $ 13,871.00 680.6 1249.9 1930.5 $ 6,806.00 $ 12,499.00 $ 19,305.00 3.0 WHEELCHAIR RAMPS 39 EA $ 225.00 $ 8,775.00 8 24 32 $ 1,800.00 $ 5,400.00 $ 7,200.00 4.0 0 EA. $ - $ - 0 0 0 $ - $ - $ - $ 26,605.60 $ 10,135.60 $ 21,419.00 $ 31,554.60 ii pF . T�YN City of La Porte Accounts Payable Check Requisition Vendor#: Due Date: Vendor Name: . Brooks Concrete 4018 AIIen Genoa Pasadena,TX 77504 You are required to attach rece!pts with all check iwjuisidons. Description: City-Wide Sidewalk Repair and Replacement Project-CLP #2000-4501 Full &Final Payment for Construction Account # Project # Invoice# Commodity Date Amount$$ Code 01598927091100 GEN709 Pay App. #4-Final 9-25-01 $5,877.26 Total Amount Due: $ $5,877.26 Remarks: Denote"Full &Final Payment"on check. Prepared By: Pe99y Lee / Approved By: Date: Date: 9-27-01 /6-O/--p Revised 8/15/97 APPLICATION AND CERTIFICATION FOR PAYMENT a- PROJECT. City-Wide Sidew elk ReplacertxnlProjed,FY2000.2001 , TOTAL AMOUNT WORKDOttETODATE: $34,776.40 ORIGINAL CONTRACT AMOUNT: $26,605.60 AMOINTRETAINED(10%): SO �NSETCHANGEBYCHANGEORDERS --- $7,670.80 PREVGOLISPAYMENTS: $28,190.14 REVISED CONTRACTA./OUNT: $34,2?6:L0 TOTALOEOUCTION5: _ $0 O• AMOIAJT DUE CONTRACTOR: $5,577.26 ?O Box 11 t S In Porte,TX '17572-1115 CQN-7RAGTOR &r..dks Cono',ih ESTIMATE NO. 4 (FINAL) • 4018 Men Gunoa Panadena,TX T75Q4 F _1713)947-0440 CONTRACT DATE_5182001 VVCRXING DAYS TO DATE 60 CE�TFICATE OFTFt CON LliAC3Oj R 0 AL Atfl jQ8v 7 REPf SE TATIVE To the best olmy bnoMedge,I cer6y that a6 Iknn,quantities and picas of wort and metatals shown on the face ofthe estirrrate are Correct that all work nas been performed and materials supplied In full accordance wdlfi tM rrr9m end condillau of the ceirc5Cfld11g construction contractual da:nme ds bebwean ha Ownorand the Contrador,a0 drmVes a i honed lwrdo;thatthe tbragoftV is a true and corned stffiemeat and o1he ) contrail arnumt up to and including the Iasi day of the peilod covered by this e5Umale and that no part of the,MOUNT DUE CONTRACTOR' has beenredsed. I further-m ifj that eljntsl and lawful bulb egabnst the above flair Co u4rr,fortabar,material and expecdabte oqutfanat employed in the pertomeatoe of sold caabact Mwe been paid In full accoidauee rlrodrequkernarts. v e2 DATE:0-_�J '°� : In SIC-NM and S1} before me,a and for he State of Teems ttYs � day of 2001. 6� 13V k s To pn ,r,4 i11 MYCOMWSS1ON EXPIRES: €/.S`aLb e4GINEER'S CERTIFICATION FOR PAYMENT In accordance wtf i the catactdocanerds,based on on-ale obserraftons and the data conprising the above appllcattn.the Enghteercentres to the Owaerhal the quality of the Work is h accordance w0i the Contract Documents,and the Comrade b added to payment of the ANOINT DUE CONTRACTOR err Q� f?a - DATE: PROJECT NAME: CITY-WIDE SIDEWALK PROJECT 2000-2001 PROJECT NUMBER 2000-4501 CONTRACTOR: BROOKS CONCRETE DATE: 25-Sep-01 - Quantity Dollars Installed Installed Total This Previous -Total Item Est Unit Estimated This Previous Installed Period Periods Income No. Description of Work Qty. Unit Price Value Period Periods To Date Income Income To Date 1.0 REMOVAL OF SIDEWALK 1979.8 L.F. $ 2.00 $ 3,959.60 10.9 2,524.80 2,535.70 $ 21.80 $ 5,049.60 $ 5,071.40 2.0 PLACEMENT OF SIDEWALK 1387.1 LF $ 10.00 $ 13,871.00 0 1,930.50 1,930.50 $ - $ 19,305.00 $ 19,305.00 3.0 WHEELCHAIR RAMPS 39 EA $ 225.00 $ 8,775.00 12 32 44 $ 2,700.00 $ 7,200.00 $ 9,900.1 iiii 0 EA. $ - $ - 0 0 0 $ - $ - $ - $ 26,605.60 $ 2,721.801 $ 31,554.60 J$ 34,276.40 PAGE : 1 ECEIVING REP ' t T SHIP TO: P .O. NO. : 010284 STREET DIVISION DATE: 3/26/01 VENDOR: CRC VENDOR NO. 432245 DELIVER BY SHIP VIA F.O.B. 4/01/01 DESTINATION CONFIRM BY CONFIRM TO REQUISITIONED BY DUANE ERNST GINA FORD FREIGHT CONTRACT NO. REQ. NO. REQ. DATE ------------------------- - --------------------- ---------- ----- --------- ------ LINE QUANTITY NO. RECEIVED UOM ITEM NO. AND DESCRIPTION UNIT COST ----------------- ------------------------------- ---------- ------------- ------ 1 . 1725 .49 SFT 090 010 2 . 5500 CONTRACTED SERVICES ANALYSIS/TESTING RAISE CONCRETE BY INJECTION METHOD 2 94 . 04 FT 090 010 15 . 9500 CONTRACTED SERVICES ANALYSIS/TESTING RESTORE FLOW LINE AT CURB 3 137 . 50 LFT 090 010 ,8 . 0000 CONTRACTED SERVICES ANALYSIS/TESTING LEVELING SIDEWALKS pcS —oi89a--� �;- ► loo ' RECEIVED BY: LANCLOS, MELISA RECEIVED DATE : 3/26/01 Ij Concrete Raising Corporation Invoice 10118 MOERS ROAD HOUSTON, TX 77075 DATE INVOICE# • 3/23/2001 3345 BILL TO — II WORK LOCATION City of LaPorte Sidewalk repairs - Collingswood & Orville Burgess-Street Supervisor Quiet Hill 2963 North 23rd Street LaPorte, TX. 77571 ( P.O. NO. TERMS REP DATE COMPLETE PROPOSAL DATE 010284 -- Net 30 Days 1 I DE /22/2001 02/27/01 DESCRIPTION AMOUNT Raised 1712.50 square feet of sidewalks n $ 2.55 each at the following 4,366.87 locations: 10414 Collingswood 10423 Collingswood: 10434 Collingswood 10410 Quiet Hill Also raised 134 linear feet @ $ 8.00 each in the same areas as above. " - _I,072.00 J Sales-Tax 0.00 Total $5,438.87 Make all checks payable to Concrete Raising Corporation All mail goes to the above address. If you have any questions concerning this invoice,call: Victor Parisian or Alan Gannany. - 713-991-1777 Concrete Raising Corporation Invoice • 10118 MOERS ROAD HOUSTON, TX 77075 DATE INVOICE# 3/23/2001 3344 BILL TO WORK LOCATION City of LaPorte 1 Street repairs- Belfast Orville Burgess-Street Supervisor 2963 North 23rd Street LaPorte, TX 77571 P.O. NO. I TERMS REP DATE COMPLETE PROPOSAL DATE 010284 I Nct30 Days DE 3/22/2001 02/27/01 DESCRIPTION AMOUNT Raised 87 linear feet at $15.95 per linear foot at 10432 Belfast per the 1,387.65 proposal. Sales Tax 0.00 Total $1,387.65 Make all checks payable to Concrete Raising Corporation All mail goes to the above address. if you have any questions concerning this invoice. call: Victor Parisian or Alan Gannanv. - 713-991-1777